Loading...
HomeMy WebLinkAboutDocumentation_Regular_Tab 17_7/10/2025 Agenda Item #17. Regular Council STAFF MEMO x Meeting: Regular Council - Jul 10 2025 Staff Contact: Marjorie Craig, Utilities Director Department: Utilities Consider Approval of BlueTerra, LLC, Authorization of Award and Execution of Contract for Dover Ditch Living Shoreline for an Amount Not-to-Exceed $304,289.80 The Village of Tequesta (VOT or Village) Utilities Department (UD) recommends approval of an authorization of award and execution of the contract for Dover Ditch Living Shoreline (ITB No. UTIL 04-23-2025/AF-1) to the lowest responsive and responsible bidder, BlueTerra, LLC for an amount not to exceed $304,289.80. PROJECT DESCRIPTION The Dover Ditch is a drainage canal that stretches a half mile along the municipal boundary of Tequesta and Jupiter. It provides flood protection for the single-family residential neighborhood to its east. The existing bank consists of sandy soil and a steep slope, leaving it vulnerable to erosion — especially during rain events. Over time, the Dover Ditch has deposited sediment into the Loxahatchee River Estuary, resulting in murky waters that disrupt aquatic wildlife. To combat this, the VOT and Town of Jupiter (TOJ) agreed to launch a project to dredge and stabilize the westernmost 350 feet of the canal, while incorporating a living shoreline element that will provide aesthetic and water quality benefits. By creating a stable meandering stream with a constructed wetland, erosion loss will be eliminated, biodiversity will increase, and nutrient runoff will be filtered by vegetation. FDEP 50% FUNDING GRANT THROUGH THE LRPI (LEGISLATIVE GRANT) Through the Loxahatchee River Preservation Initiative Grant (LRPI), an FDEP grant was secured to cover 50% of the estimated project cost of$350,000, with the remaining $157,500 being the responsibility of the VOT and TOJ. The cost-sharing agreement specifies that the VOT is responsible for 60% or $94,000, and the TOJ is responsible for 40% or$63,000. BIDS RECEIVED The Project was bid on May 13, 2025, a pre-bid meeting was held on May 23, 2025, and the bid opening was on June 18, 2025. Six bids were received: 1. BlueTerra LLC— bid of$304,289.80 (lowest bid) 2. East Coast Industries Corp. — bid of$351,579.50 (15.54% higher than lowest bid) 3. Sea & Shoreline LLC— bid of$544,049.50 (78.79% higher than lowest bid) 4. Close Construction Services, LLC — bid of$610,120 (100.51% higher than lowest bid) 5. Underwater Engineering Services, Inc. — bid of$658,685 (116.47% higher than lowest bid) 6. Razorback LLC— bid of$1,954,102 (542.18% higher than lowest bid) The price for the construction of the living shoreline came in just slightly below the engineer's opinion of probable cost (OPC) of $312,024.00. The Utilities Department recommends approving the authorization of the award and execution of the contract with BlueTerra LLC, for an amount not to exceed $304,289.80. The planned project schedule is outlined below: Page 310 of 369 Agenda Item #17. The partially executed agreement will be available for complete execution by the Mayor, if the Village Council approves this agenda item. BlueTerra has until July 10, 2025, to review and execute their portion of the agreement. The UD did not want to delay the approval process another month. There is a 50% grant tied to the project, and it has already been delayed for months in permitting, so we've included the blank agreement for reference. PLANNED SCHEDULE AND BUDGET The planned project schedule and budget information is outlined below: Bid Project: May 13, 2025 Award Project: July 2025 Issue Notice to Proceed: August 2025 Complete Project: February 2026 STORMWATER FUND -Account 403-411-663.663 R&R Drainage Improvements Budgeted in account: $315,000.00 Available amount: $314,950.00 Amount of this proposal: $304,289.80 Total Remaining: $10,710.20 Amount to be reimbursed by FDEP: $157,500.00 Amount to be reimbursed by TOJ $58,715.92 ATTACHMENTS: • Attachment 1 —agreement with the contractor • Chen-Moore & Associates (CMA) evaluated the six bids received, reviewed the qualifications, and contacted references for the lowest responsive/responsible bidder • Based on the review, CMA provided a letter of recommendation of award to BlueTerra LCC • Attachment 2 — letter from the Engineer recommending the award of the contract to BlueTerra LLC, the lowest responsive and responsible bidder, for$304,289.80, and the required 5% bid bond was provided. • Attachment 3-the Engineer's opinion of probable cost(OPC)was$312,024.00 • Attachment 4 -detailed bid tabulation for the project • Attachment 5- bid form submitted by BlueTerra LLC • Attachment 6-all addenda related to this project This document and any attachments may be reproduced upon request in an alternative format by completing our Accessibility Feedback Form, sending an e-mail to the Village Clerk or calling 561- 768-0443. BUDGET • - • BUDGET AMOUNT $315,000 AMOUNT AVAILABLE EXPENDITURE AMOUNT: $314,950 $304,289.80 FUNDING SOURCES: 403-411-663.663 IS THIS A PIGGYBACK: ❑ Yes ❑x N/A DID YOU OBTAIN 3 QUOTES? Page 311 of 369 Agenda Item #17. ❑ Yes M N/A QUOTE 1 - BUSINESS NAME N/A QUOTE AMOUNT N/A QUOTE 2 - BUSINESS NAME N/A QUOTE AMOUNT N/A QUOTE 3 - BUSINESS NAME N/A QUOTE AMOUNT N/A COMMENTS/EXPLANATION ON SELECTIONThis project was bid through an invitation to bid (ITB No. UTIL 04-23-2025/AF-1) on Demand Star 1) Dover Ditch Living Shoreline Agreement Unexecuted 2) Engineer Bid Reccomendation ITB-UTIL 05-01-2025AF 3) Dover Ditch Cost Estimate 4) Detailed Bid Tab ITB-UTIL 05-01-2025AF 5) BlueTerra Combined Bid 6) Dover Ditch Addenda Combined Page 312 of 369 Agenda Item #17. Agreement (Contract) Between Owner and Contractor This Agreement (Contract) made this day of 2025 by and between the Village of Tequesta,a public agency of the State of Florida hereinafter designated as the"the VILLAGE" and "OWNER", and (INSERT CONTRACTOR'S NAME), (INSERT CONTRACTOR'S ADDRESS), a Corporation, whose Federal I.D. number is , hereinafter designated as "the CONTRACTOR", in consideration of the mutual covenants hereinafter set forth agree as follows: ARTICLE 1. WORK. 1.1 CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: Provide all labor, equipment, materials, and tools necessary to convert the westernmost 350 foot segment of Dover Ditch into a meandering "stream". This work will include dredging, re-aligning, and stabilizing the stream, along with the installation of debris skimmer/manatee barrier and native plant species to create "living shorelines"on the banks of the stream and all other incidentals required to complete the Work in accordance with the Bidding Documents. 1.2 The Project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: DOVER DITCH LIVING SHORELINE FOR THE VILLAGE OF TEQUESTA UTILITIES,TEQUESTA, FLORIDA ARTICLE 2. ENGINEER. 2.1 The specifications and drawings have been designed by: Chen Moore and Associates 500 S Australian Ave, Suite 850 West Palm Beach, FL 33401 ARTICLE 3. CONTRACT TIME. 3.1 The Work will have substantial completion dates and final completion dates after the date when the Contract Time commences to run as provided in Article 4 of the General Conditions, and as outlined below. The work will be completed and ready for substantial and final payments in accordance with Article 15 of the General Conditions and as outlined below: 3.1.(a). Substantial Completion: 180 calendar days from Notice to Proceed 3.2.(a). Final Completion: 210 calendar days from Notice to Proceed Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not substantially complete within the time specified in Article 3.1 above, plus any extensions thereof allowed in accordance with Article 11 of the General Conditions. They also recognize the delays, expense and difficulties involved in proving in a legal or arbitration preceding the actual loss suffered by OWNER if the Work is not substantially complete on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER Seven Hundred and Fifty 00/100 dollars ($750.00) for each day that expires after the Contract Substantial Completion time specified in Article 3.1, and until the Work of the Contract reaches substantial completion, and Five Hundred 00/100 dollars ($500.00) Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 49 Page 313 of 369 Agenda Item #17. for each day that expires after the Contract Final Completion time specified in Article 3.1,and until the Work of the Contract reaches final completion. Liquidated damages under this Contract will be applied to each Contract Milestone Completion date individually until the Work of each respective Contract Milestone identified in Article 3.1 achieves Substantial and Final Completion,as required, by the Contract requirements. OWNER may withhold payment to compensate for liquidated damages either by increasing the amount of money being held in retainage or deducting the amount due in Liquidated Damages from the final payment application. Liquidated damages under this Contract will be applied to each individual Contract Milestone Substantial Completion date and each individual Contract Milestone Final Completion date, identified in Article 3.1 of this Agreement, or as represented in any subsequent executed change order to this Contract for changes in Contract Time, in accordance with Article 11.08 of the EJCDC Standard General Conditions of the Construction Contract. ARTICLE 4. CONTRACT PRICE. 4.1 OWNER shall pay CONTRACTOR for performance of the Work in accordance with the Contract Documents in current funds according to the Contract Unit Prices. ARTICLE 5. PAYMENT PROCEDURES. 5.1 CONTRACTOR shall submit Applications for Payment in accordance with Article 15 of the General Conditions. Applications for payment will be processed by OWNER as provided in the General Conditions. 5.2 The undersigned, acknowledges that payments made by the Village of Tequesta will be made via check and vendor will provide the Village of Tequesta with the information required to establish the CONTRACTOR as a vendor. 5.3 Progress Payments.OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR'S Applications for Payment within 30 days of receipt of each monthly approved application for payment during construction as provided below. All progress payments will be on the basis of the progress of the Work measured by the agreed upon schedule of values provided for in Article 15.01 of the General Conditions. 5.4 Progress payments will be made in an amount equal to 95% of the Work completed, and 95% of materials and equipment not incorporated in the Work but delivered and suitably stored, less in each case the aggregate of payments previously made. OWNER is not obligated to pay for stored materials and may choose to withhold payment until materials are incorporated into the Work. 5.5 OWNER, at its discretion, may further increase payments to 98% of the work completed upon Substantial Completion. OWNER is not obligated to increase payments to 98%of work completed. 5.6 Final Payment. Upon final completion and acceptance of the Work in accordance with Article 15 of the General Conditions, OWNER shall pay the remainder of the Contract Price as provided in said Article 15 of the General Conditions unless liquidated damages are due. ARTICLE 6. INTEREST. 6.1 All amounts not paid when due shall bear interest at the rate of 1 percent per annum. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page SO Page 314 of 369 Agenda Item #17. ARTICLE 7. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following representations: 7.1 CONTRACTOR has examined and carefully studied the Contract Documents, and any data and reference items identified in the Contract Documents. 7.2 CONTRACTOR has visited the Site, conducted a thorough, alert visual examination of the Site and adjacent areas, and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. 7.3 CONTRACTOR is familiar with and is satisfied as to all Laws and Regulations that may affect cost, progress, and performance of the Work. 7.4 CONTRACTOR has considered the information known to CONTRACTOR itself; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents; and the drawings/figures identified in the Contract Documents,with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work; (2) the means, methods, techniques, sequences, and procedures of construction to be employed by CONTRACTOR; and (3) CONTRACTOR's safety precautions and programs. 7.5 Based on the information and observations referred to in the preceding paragraph, CONTRACTOR agrees that no further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract. 7.6 CONTRACTOR is aware of the general nature of work to be performed by OWNER and others at the Site that relates to the Work as indicated in the Contract Documents. 7.7 CONTRACTOR has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that CONTRACTOR has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to CONTRACTOR. 7.8 The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. 7.9 CONTRACTOR's entry into this Contract constitutes an incontrovertible representation by CONTRACTOR that without exception all prices in the Agreement are premised upon performing and furnishing the Work required by the Contract Documents. ARTICLE 8. CONTRACT DOCUMENTS. 8.1 The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR are attached to this Agreement, made a part hereof and consists of the following: 8.1(a) Table of Contents 8.1(b) Invitation to Bid 8.1(c) Instructions to Bidders Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S1 Page 315 of 369 Agenda Item #17. 8.1(d) Bid Proposal (Including Bid Schedule of Values, List of Subcontractors and Qualification Requirements) 8.1(e) Contractor Safety Qualifications/Requirements (Including Contractor Safety Qualification Form) 8.1(f) Contractor E-Verify Affidavit Form 8.1(g) Drug-Free Workplace Certificate 8.1(h) Public Entity Crimes Affidavit 8.1(i) Village Clerks ADA Compliance Statement Form 8.1(j) Sworn Statement 8.1(k) Trench Safety 8.1(1) Bid Bond 8.1(m) Notice of Intent to Award 8.1(n) Notice of Award 8.1(o) Agreement (Contract) between OWNER and CONTRACTOR 8.1(p) Payment Bond 8.1(q) Performance Bond 8.1(r) Opinion of Village Attorney 8.1(s) Notice to Proceed 8.1(t) General Conditions 8.1(u) Supplementary Conditions 8.1(v) Any Modifications, including Change Orders, duly delivered after execution of Agreement. 8.1(w) Technical Specifications including Appendices bearing the title: Dover Ditch Living Shoreline 8.1(x) Drawings bearing the title: Dover Ditch Living Shoreline Project 8.2 There are no Contract Documents other than those listed above in this Article 8. The Contract Documents may only be altered, amended or repealed by a modification described in Article 1 of the General Conditions of the Contract. ARTICLE 9. MISCELLANEOUS. 9.1 Terms used in this Agreement which are defined in Article 1 of the General Conditions shall have the meanings indicated in the General Conditions. 9.2 No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically but without limitation, moneys that may become due and moneys that are due may be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3 OWNER and CONTRACTOR each binds himself, his partners, successors, assigns and legal representatives to the other party hereto, his partners, successors, assigns and legal representatives in respect to all covenants, agreements and obligations contained in the Contract Documents. 9.4 The Inspector General of Palm Beach County has the authority to investigate and audit matters relating to the negotiation and performance of this Contract and in furtherance thereof may demand and obtain records and testimony from the CONTRACTOR and its subcontractors and Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S2 Page 316 of 369 Agenda Item #17. lower tier subcontractors. The CONTRACTOR understands and agrees that in addition to other remedies and consequences provided by law,the failure of the CONTRACTOR or its subcontractors or lower tier subcontractors to fully cooperate with the Office of Inspector General of Palm Beach County when requested may be deemed by the municipality to be a material breach of this contract justifying its termination. The Office of Inspector General in Palm Beach County is established by Palm Beach County Code, Section 2-421 - 2-440. Failure to cooperate with the Inspector General or interfering with or impeding any investigation shall be in violation of Palm Beach County Code, Section 2-421 — 2-440, and be punished pursuant to Section 125.69, Florida Statutes, in the same manner as a second degree misdemeanor. 9.5 This Agreement is subject to and governed by the laws of the State of Florida, including without limitation Chapter 119, Florida Statutes,which generally makes public all records or other writings made by or received by the parties.The CONTRACTOR acknowledges its legal obligation to comply with § 119.0701, Florida Statutes. 9.5(a) A request to inspect or copy public records relating to a public agency's contract for services must be made directly to the public agency. If the public agency does not possess the requested records,the public agency shall immediately notify the CONTRACTOR of the request, and the CONTRACTOR must provide the records to the public agency or allow the records to be inspected or copied within a reasonable time. 9.5(b) If a contractor does not comply with the public agency's request for records, the public agency shall enforce the contract provisions in accordance with the contract. 9.5(c) A contractor who fails to provide the public records to the public agency within a reasonable time may be subject to penalties under s. 119.10. 9.5(d) IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT 561-768-0443, LMCWILLIAMS@TEQUESTA.ORG, OR 345 TEQUESTA DRIVE, TEQUESTA, FL 33469. 9.6 Indemnity 9.6(a) The parties recognize that the CONTRACTOR is an independent contractor. The CONTRACTOR agrees to assume liability for and indemnify, hold harmless, and defend the OWNER, its council members, mayor, officers, employees, agents, and attorneys of, from, and against all liability and expense, including reasonable attorney's fees, in connection with any and all claims, demands, damages, actions, causes of action, and suits in equity of whatever kind or nature, including claims for personal injury, property damage, equitable relief, or loss of use, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the CONTRACTOR, its agents, officers, Contractors, subcontractors, employees,or anyone else utilized by the CONSTRACTOR in the performance of this Contract. The CONTRACTOR's liability hereunder shall include all attorney's fees and costs incurred by the OWNER in the enforcement of this indemnification provision. This includes claims made by the employees of the CONTRACTOR against the OWNER and the CONTRACTOR hereby waives its entitlement, if any, to immunity under Section 440.11, Florida Statutes. The obligations contained in this provision shall survive termination of this Contract and shall not Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S3 Page 317 of 369 Agenda Item #17. be limited by the amount of any insurance required to be obtained or maintained under this Contract. 9.6(b) Subject to the limitations set forth in this Section, CONTRACTOR shall assume control of the defense of any claim asserted by a third party against the OWNER and, in connection with such defense, shall appoint lead counsel, in each case at the CONTRACTOR's expense. The OWNER shall have the right, at its option,to participate in the defense of any third party claim, without relieving CONTRACTOR of any of its obligations hereunder. If the CONTRACTOR assumes control of the defense of any third party claim in accordance with this paragraph, the CONTRACTOR shall obtain the prior written consent of the OWNER before entering into any settlement of such claim. Notwithstanding anything to the contrary in this Section, the CONTRATCOR shall not assume or maintain control of the defense of any third party claim, but shall pay the fees of counsel retained by the OWNER and all expenses, including experts' fees, if(i) an adverse determination with respect to the third party claim would, in the good faith judgment of the OWNER, be detrimental in any material respect to the OWNER's reputation; (ii) the third party claim seeks an injunction or equitable relief against the OWNER; or (iii) the CONTRACTOR has failed or is failing to prosecute or defend vigorously the third party claim. Each party shall cooperate, and cause its agents to cooperate, in the defense or prosecution of any third party claim and shall furnish or cause to be furnished such records and information, and attend such conferences, discovery proceedings, hearings, trials, or appeals, as may be reasonably requested in connection therewith. 9.6(c) It is the specific intent of the parties hereto that the foregoing indemnification complies with Section 725.06, Florida Statutes, as amended. CONTRACTOR expressly agrees that it will not claim,and waives any claim,that this indemnification violates Section 725.06, Florida Statues. Nothing contained in the foregoing indemnification shall be construed as a waiver of any immunity or limitation of liability the OWNER may have under the doctrine of sovereign immunity or Section 768.28, Florida Statutes. 9.7 Governing Law and Remedies 9.7(a) The validity of this Agreement and of any of its terms or provisions, as well as the rights and duties of the parties hereunder, shall be governed by the laws of the State of Florida and venue for any and all disputes related to or arising from this Agreement shall be in Palm Beach County, Florida. 9.7(b) No remedy herein conferred upon any party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given hereunder or now or hereafter existing at law or in equity or by statute or otherwise. No single or partial exercise by any party of any right, power, or remedy hereunder shall preclude any other or further exercise thereof. 9.8 Office of the Inspector General 9.8(a) Palm Beach County has established the Office of the Inspector General,which is authorized and empowered to review past, present, and proposed County programs, contracts, transactions,accounts and records. The Inspector General (IG) has the power to subpoena witnesses, administer oaths, require the production of records, and monitor existing projects and programs. The Inspector General may,on a random basis, perform audits on all OWNER contracts. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S4 Page 318 of 369 Agenda Item #17. 9.9 Insurance 9.9(a) The limits of liability for insurance required by Paragraph 6.03 of the General Conditions shall provide coverage for not less that the following amounts or greater where required by Law and Regulations: 1. Workers' Compensation, and related coverages under Paragraphs 6.03.A.1 and A.2 of the General Conditions: a. State Statutory b. Applicable Federal Statutory C. Employer Liability: Bodily injury, each accident $1,000,000 Bodily injury by disease, each employee $500,000 Bodily injury/disease aggregate $1,000,000 d. Foreign voluntary worker compensation Statutory 2. CONTRACTOR's Commercial General Liability under Paragraphs 6.03.13 and 6.03.0 of the General Conditions: a. General Aggregate $2,000,000 b. Products—Completed Operations Aggregate $2,000,000 C. Personal and Advertising Injury $1,000,000 d. Each Occurrence $1,000,000 (Bodily Injury and Property Damage) 3. Automobile Liability under paragraph 6.03.D of the General Conditions: a. Bodily Injury: Each Person $500,000 Each Accident $1,000,000 d. Property Damage: Each Incident $1,000,000 4. Umbrella of Excess Liability under paragraph 6.03.E of the General Conditions: a. Excess or Umbrella Liability 1) General Aggregate $5,000,000 2) Each Occurrence $1,000,000 5. CONTRACTOR's Pollution Liability under paragraph 6.03.F of the General Conditions: a. CONTRACTOR's Pollution Liability 1) General Aggregate $2,000,000 2) Each Occurrence $1,000,000 6.Additional Insureds include the respective officers, partners,directors,employees,agents, consultants, and subconsultants of the following firms and municipal government(s): a. Village of Tequesta 9.10 Audit By OWNER 9.10(a) The CONTRACTOR shall permit the OWNER, or any authorized representatives of the OWNER,at all reasonable times,access to and the right to examine all records, books, papers or documents related to the CONTRACTOR's performance under this Agreement including, but not limited to, expenses for sub-contractors, agents or assistants, direct and indirect Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page SS Page 319 of 369 Agenda Item #17. charges for work performed and detailed documentation for all such work performed or to be performed under this Agreement. 9.11 Copies of Data/Documents 9.11(a) Copies or original documents prepared by the CONTRACTOR in relation to work associated with this Agreement shall be provided to the OWNER. Data collected, stored, and/or provided shall be in a form acceptable to the OWNER and agreed upon by the OWNER. 9.12 Ownership 9.12(a) Each and every report, draft, work product, map, record, and other document reproduced, prepared, or caused to be prepared by the CONTRACTOR pursuant to or in connection with this Agreement shall be the exclusive property of the OWNER. 9.13 Limitations of Liability 9.13(a) Under no circumstances shall either party be liable to the other for any consequential, incidental, special, punitive, or any other form of indirect or non-compensatory damages. 9.14 Enforcement Costs 9.14(a) All parties shall be responsible for their own attorneys' fees, court costs and expenses if any legal action or other proceeding is brought for any dispute, disagreement, or issue of construction or interpretation arising hereunder whether relating to the Agreement's execution, validity, the obligations provided therein, or performance of this Agreement, or because of an alleged breach,default or misrepresentation in connection with any provisions of this Agreement. 9.15 Copyrights and/or Patent Rights 9.15(a) CONTRACTOR warrants that there has been no violation of copyrights and/or patent rights in the manufacturing, producing or selling of the goods,shipped or ordered,as a result of this Agreement and the CONTRACTOR agrees to hold the OWNER harmless from any and all liability, loss, or expense occasioned by any such violation. 9.16 Protection of Property 9.16(a) The CONTRATOR shall at all times guard against damage or loss to the property of the OWNER of other vendors or contractors and shall be held responsible for replacing or repairing any such loss or damage. The OWNER may withhold payment or make such deductions as deemed necessary to insure reimbursement or replacement for loss or damage to property through negligence of the successful CONTRACTOR or its agents. The CONTRACTOR shall be responsible to safeguard all of their property such as tools and equipment while on site. The OWNER will not be held responsible for any loss of CONTRACTOR property due to theft or vandalism. 9.17 Damage to Persons or Property 9.17(a) The responsibility for all damage to person or property arising out of or on account of Scope of Work done under this Contract shall rest upon the CONTRACTOR. 9.18 Discrimination 9.18(a) The CONTRACTOR warrants and represents that all of its employees are treated equally during employment without regard to race,color, religion,disability,sex,age, national origin, ancestry, political affiliation, marital status, handicap, or sexual orientation. Further, CONTRACTOR shall not discriminate or permit discrimination against any employee or an applicant for employment on the basis of race,color,sex, religion, political affiliation, natural origin, ancestry, marital status, sexual orientation or handicap. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S6 Page 320 of 369 Agenda Item #17. 9.19 Construction Defects 9.19(a) PURSUANT TO SECTION 558.005, FLORIDA STATUTES, ANY CLAIMS FOR CONSTRUCTION DEFECTS ARE NOT SUBJECT TO THE NOTICE AND CURE PROVISIONS OF CHAPTER 558, FLORIDA STATUTES. 9.20 Public Entity Crimes 9.20(a) CONTRACTOR acknowledges and agrees that a person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals,or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier or sub-contractor under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, Florida Statues, for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. The CONTRACTOR will advise the OWNER immediately if it becomes aware of any violation of this statute. 9.21 Scrutinized Companies 9.21(a) CONTRACTOR certifies that it and its subcontractors are not on the Scrutinized Companies that Boycott Israel List and are not engaged in the boycott of Israel. Pursuant to section 287.135, Florida Statutes,the OWNER may immediately terminate this Agreement at its sole option if the CONTRACTOR or any of its subcontractors are found to have submitted a false certification; or if the CONTRACTOR or any of its subcontractors, are placed on the Scrutinized Companies that Boycott Israel List or is engaged in the boycott of Israel during the term of this Agreement. 9.21(b) If this Agreement is for one million dollars or more,the CONTRACTOR certifies that it and its subcontractors are also not on the Scrutinized Companies with Activities in Sudan List, Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List,or engaged in business operations in Cuba or Syria as identified in Section 287.135, Florida Statutes. Pursuant to Section 287.135, the OWNER may immediately terminate this Agreement at its sole option if the CONTRACTOR, or any of its subcontractors are found to have submitted a false certification; or if the CONTRACTOR or any of its subcontractors are placed on the Scrutinized Companies with Activities in Sudan List, or Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or are or have been engaged with business operations in Cuba or Syria during the term of this Agreement. 9.21(c) The CONTRACTOR agrees to observe the above requirements for applicable subcontracts entered into for the performance of work under this Agreement. 9.21(d) The CONTRACTOR agrees that the certifications in this section shall be effective and relied upon by the OWNER for the term of this Agreement, including any and all renewals. 9.21(e) The CONTRACTOR agrees that if it or any of its subcontractors' status changes in regards to any certification herein, the CONTRACTOR shall immediately notify the OWNER of the same. 9.21(f) As provided in Subsection 287.135(8), Florida Statutes, if federal law ceases to authorize the above-stated contracting prohibitions then they shall become inoperative. 9.22 Employment Eligibility 9.22(a) This Agreement is subject to and governed by the laws of the State of Florida, including without limitation Chapter 448, Florida Statutes, which provides for General Labor Regulations, and specifically Section 448.095, Employment Eligibility. The CONTRACTOR acknowledges its legal obligation to comply with §448.095, Florida Statutes. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S7 Page 321 of 369 Agenda Item #17. (i) Pursuant to Section 448.095, Florida Statutes, beginning January 1, 2021, CONTRACTOR shall register with and use the U.S. Department of Homeland Security's E-Verify system, https://e-verifv.uscis.gov/emp, to verify the work authorization status of all CONTRACTOR employees hired on and after January 1, 2021. (ii) Subcontractors— a) CONTRACTOR shall also require all subcontractors performing work under this Agreement to use the E-Verify system for any employees they may hire during the term of this Agreement. b) CONTRACTOR shall obtain from all such subcontractors an affidavit stating the subcontractor does not employ, contract with, or subcontract with an unauthorized alien, as defined in section 448.095, Florida Statutes. c) CONTRACTOR shall provide a copy of all subcontractor affidavits to the Village upon receipt and shall maintain a copy for the duration of the Agreement. (iii) 3. CONTRACTOR must provide evidence of compliance with Section 448.095, Florida Statutes. Evidence shall consist of an affidavit from the CONTRACTOR stating all employees hired on and after January 1, 2021, have had their work authorization status verified through the E-Verify system and a copy of their proof of registration is in the E- Verify system. (iv) 4. Failure to comply with this provision is a material breach of the Agreement and shall result in the immediate termination of the Agreement without penalty to the Village. CONTRACTOR shall be liable for all costs incurred by the Village to secure a replacement Agreement, including but not limited to, any increased costs for the same services, any costs due to delay, and rebidding costs, if applicable. IN WITNESS WHEREOF, the parties hereto have signed two (2) copies of this Agreement. At least one counterpart each has been delivered to OWNER and CONTRACTOR. All portions of the Contract Documents have been signed or identified by OWNER and CONTRACTOR. OWNER CONTRACTOR Village of Tequesta [INSERT CONTRACTOR NAME] 345 Tequesta Drive [INSERT CONTRACTOR ADDRESS] Tequesta, FL 33469 [INSERT CONTRACTOR ADDRESS] By: Molly Young, Mayor (VILLAGE SEAL) (CORPORATE SEAL) ATTEST ATTEST Lori McWilliams,Village Clerk PRINT NAME AND POSITION Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page S8 Page 322 of 369 Agenda Item #17. 500 S.Australian Ave.,Suite 850 West Palm Beach,FL 33401 ' Office:+1(561) 746-6900 chen moore and associates June 24, 2025 SENT VIA E-MAIL(afelsburg@tequesta.org) Village of Tequesta Allyson Felsburg Deputy Director, Utilities Department 345 Tequesta Drive Tequesta, FL 33469 Re: Dover Ditch Living Shoreline Village of Tequesta ITB-UTIL 05-05-2025/AF CMA Project No.492.010 Dear Ms. Felsburg, Chen Moore and Associates, Inc. (CMA) has conducted a review of the three (3) lowest bids received on June 181", 2025 for the Dover Ditch Shoreline Restoration project.The lowest overall bidder was BlueTerra LLC,with a bid cost of$304,289.80.The engineer's lump sum estimate for the base bid was approximately $312,024.00. During the qualification review positive feedback was received on the performance of BlueTerra staff in past projects. In conclusion, BlueTerra LLC was identified as the lowest qualified bidder, has similar project experience that indicate they are capable of performing the work, and submitted bid prices that are reflective of current market conditions. CMA recommends award of this contract to BlueTerra LLC. Respectfully Submitted, CHEN MOORE AND ASSOCIATES Brent Whitfield, P.E. Principal Engineer and Director of Water Resources chenmoore.com Page 323 of 369 Agenda Item #17. Ln N 0 N M N LU V p� O O O O O O O O O O O O O O O O O a o 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 O O O O O O O O O O O O O O O ON N 0 0 0 C � o m Lr 0 0 0 0 0 0 14 0 0 0 0 0 E Z o 00 00 -1 1n LnLr)ro 4 V). ' l? t/l'I O� l0 lL l ri to t/} t/? +./� t/} t4 to t/} �/} iM t/? t/ } t/? ice!} rn X Lu O O O O O O O O O O O O O O o W O O O O o O O O O O O O O O o . . . . . . . . . . . . . . . U o Ln O O Ln O O Ln O O O O O O O o ri Ln o r-I M M M w O ri o ri Ln 0 d o ri N ri ri 0 ri o M Or-I Z try th try th tr)- t4 th th t� try t� try th try th H Z J Ln U U Ln n Ln U U L J Lam/) LQu J J J H O W Z O 0 Z O Z ri lN0 `� p O o ri r4 M Kt r�-1 r-I i V Q Ln ri M N N 1- r, ri LLI Cf C7 Z H o 0 Z_ 0 O r-4 U > LU m >- Z m =) U O = N Z LU H m _ Z (7 O d cc U W LL 1� D O Z >O O E u O Z -0 Ln Ln O Z cn a Z Z O + O Q p a O ago N a- L�I W c N 0 Q L.L_ x J M 0 1 H L�L N c O O O � L cO v N U1 .0- G O Q L cc U vi M E t coO c C O O O Q N >, N a u C, u QCl) Cn a 0 LU c �° O - - v O 0- 0 O O Ua 7 4J i a)m 4J i� -0LnC C O COm N O L co C7 N E LL C p� coLn > E c� N L N L Y u c�� N co O '+� N v c � w UO ^ ^ w N '-E u- 0 O C7 U d i m > s CR cn L.L. d " Lu ri ri r-1 ri ri ri P ! ri N M � Ln lD 1, W IT o ri N M 't Ln Page 324 of 369 Agenda Item #17. O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O W O O Ln lD O O ul O ul O O O O O V O m ti ti n u'f O .--i O .--i ul 0 0 0 O t/} ul t/} t/} O O O O Z � 7 y� O O O O O O O O O O O O O O O O O O O O O O O O O O O O O 11 O O O O O N J O O ID O O O O O O O O .--i N O O O O M j O oo oo N v1 O O O O CO �n w N O O O O V O Il lD ti O O O CO I� M lD O O O O O p V1 ID m m -;I- 'r m O m w l/} M N N u'1 lD O Ln Z Vf W qp x W O O O O O O O O O O O O O O O O O O O O O O O O O O O O 1n 0 0 0 0 0 y Gl C o o tD CO o 0 0 0 0 of o 7 M o 0 o o �. U o m w c-I m O Ln 0 0 i/ Ln {/? N O O o o LL O O c-I c-I v)- c-I N C Ln Co N {/T c C c c w L LM r {!} i/} i/T t/T a N m j H N E +' bo CL 0 0 0 0 0 0 0 0 0 0 0 �n o 0 0 0 o Ln E J Ln J o v o v o 0 0 0 o oo a o 0 0 0 of N Q n oo m oo o 0 o n o o o o n o n cl oo N O O a 0 0 W N v1 .ti lD O W W O 1n V 0 r LA y N Z M d m N X ~ W o o Cl Cl 0 0 0 0 0 Ln o 0 0 0 0 0 o C o Ln o 0 0 0 0 0 0 � o 1n o 0 0 0 0 d W o N Ln N Ln O O O O Ln O Ln c-I O O O o V VI -:T 7 c-I m N Ln Ln Ln Vn O V} 7 0 0 Ln o 00 V} L} V4 L? c-I in Ln W Ln V} O Oo Oo O a V N VT Ln N 7 o Ln r V} tq Z 7 �y oo -;I- oo O O O O O CO O I� m oo O O w O O M : MI;d: 1l Iq O O In CO M 't m O O M 0 C9 J N M N O O CO O O N CO N -;r .--i O O N O m Q q m O M lD lD 01 VI O Ili m O o0 � lD 00 ul M � O �--� � 00 �n O N p O oo m ri -;j- h .--i CO .--i m m m N m O V p tlT l/? VT VT VT VT VT t/F M Z of W X W co N oo tD O m 0 0 Co a m I, n Cl O w O M li M Un M c-I O Un M Un I� If! O O O M O W N M M O Ln M O N N lD O N ID O O N O V V1 M m c-I o0 w vl? Ln c-I c-I N c-I w Vh O c-I O CO M N of O ice/ Z M p � r W QH N c-I in 0 0 0 O Ih C Q ~ � O W N N N c-I ^ M - --I c-I c-I c-I c-I N C W �i 7 � :d U H to C�sr U U N N U Z Q rr U W � L7 ctl It O w a o o � `p o n Co m O c-I cN-I m c--I cm-I D rr, C H W m J Page 325 of 369 Agenda Item #17. y� O O 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 � O O O O O O O O O O O O O O O O O O J o O I- O O O O O O O O Ln O O O O O N j O c O Ln m O O O O O O O O O O O O O c-I lr N lD lD O O O O O N o0 O O o� O ci O N Z1. M n ID �t ID Ln m lD W .--I N VI W -;j- O -zr ly I, lD c-I w m m m Ln I- M .--I .--I N V1 W .--I V1 V1 M N V} V} c-I N V} V} c-I V} V} 11 VT .-I VT VT VT Ol Z W th H X W O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O O W O O Ih O O lh 0 0 0 0 0 u1 0 0 0 0 0 to W m ti O u1 O u1 O 0 0 0 0 0 w O N VT to W h 0 VT O V} N O O W O 1 N VY VT VT VT � N Ol lD � N W C O Y Z u ' n 7 y� O O O O O O O O O O O O O O O O O O J O O w O O O O O O O O N O of N O m Q O m -;I- -;I- 01 " lD lD O O O I, m O -It N O M > m n r, lrm a co N rn C C m v Ln lD m e In 0 m N h w -t M .--I � N N N O M W oo m ci N oo oo VT VT N 7 V} V} V} c-I c-I Ln W 0 V} VT VT VT VT ci VT V} V} V} V} l0 Z VT V1 H X W O O O O O O O O O O O O O O O O O O O O O O O O O O u! 0 0 0 0 0 0 0 W O V1 oo ID I� ID M m O N O O W O w N O {J O ID 7 N O N •--I m O to O ti N 0 V N O M c-I M V} M M N •--I O 1/} .—I V} V} l(1 to 01 O V4 i/} i/T VT 14 c-I V} N N N O oo V} V} th V} V} V} Z y� O O 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 J O O V1 O O O O O O O O Ln O O O O O O ? O w m -:1 Vl Ln O O O O O O O O O O O N O Vl N C o0 r" ci m O o0 Lq N rl O O O O 'i 0 rl O N n Ol lD c-I O O Ln O O O W lD M V} c-I VI VI 1/1, O c-I N .--I V? N • Z V} V} V} V} V} L} V} VT V? V} V} D W � H X W Page 326 of 369 Agenda Item #17. Bid Proposal Bidding Company Name: BlueTerra LLC Village of Tequesta Utilities Department 345 Tequesta Drive Tequesta, FL 33469 Gentlemen: The undersigned, as Bidder, hereby declares that the only Persons, company, or parties interested in the Proposal or the Contract to be entered into, as principals, are named herein; and that this Proposal is made without connection with any other person, company, or parties making a Bid or Proposal; and that it is in all respects fair and in good faith without collusion or fraud. That the Bidder has carefully and to his full satisfaction examined the attached Instructions to Bidders, General Conditions, Supplementary Conditions, detailed Specifications, and Form of Contract and Bond, together with the accompanying plans, and that Bidder has read all addenda issued prior to the opening of Bids; and that Bidder has fully examined the site and the project documents and hereby agrees to furnish, unless otherwise provided, all implements, machinery, equipment, transportation, tools, materials, supplies, labor and other things necessary to the prosecution and completion of the work, to wit: Provide all labor, equipment, materials, and tools necessary to convert the westernmost 350 foot segment of Dover Ditch into a meandering "stream". This work will include dredging, re-aligning, and stabilizing the stream, along with the installation of debris skimmer/manatee barrier and native plant species to create 'living shorelines"on the banks of the stream and all other incidentals required to complete the Work in accordance with the Bidding Documents. It is proposed that the project herein described shall be constructed for the Unit Prices as follows on the Bid Schedule of Values, all in accordance with the requirements and provisions of the Contract Documents. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 20 Page 327 of 369 Agenda Item #17. Proposal (Continued) If awarded the Contract, the undersigned agrees to execute the attached Agreement/Contract and provide required insurance within fifteen (15)calendar days from the date set forth in the Notice of Intent to Award or Notice of Award, which ever one is received first, and to fully complete all necessary work within the Contract Times specified below after date of written Notice to Proceed, with such extensions of time as are provided for in the General Conditions. Substantial Completion: 180 calendar days from Notice to Proceed Final Completion: 210 calendar days from Notice to Proceed The undersigned understands the Contract Time starts on the date of Notice to Proceed.The undersigned understands the Contract Times include Contractor obtaining permits, complete shop drawing submittal, and all other work required to complete the Work in full. The undersigned agrees that all bid documents issued for this project, including addenda, have been reviewed and site visits performed, as necessary to provide a comprehensive bid. The undersigned acknowledges receipt of (insert number)Addenda for this project. The undersigned agrees to provide release of liens for all subcontractors and suppliers during the course of the contract with each payment application. The undersigned acknowledges that payments made by the Village of Tequesta will be made via check and vendor will provide the Village of Tequesta with the information required to make the CONTRACTOR a vendor in the Village of Tequesta system. The undersigned is aware that the Inspector General of Palm Beach County has the authority to investigate and audit matters relating to the negotiation and performance of this contract and in furtherance thereof may demand and obtain records and testimony from the contractor and its subcontractors and lower tier subcontractors. The contractor understands and agrees that in addition to other remedies and consequences provided by law, the failure of the contractor or its subcontractors or lower tier subcontractors to fully cooperate with the Inspector General when requested may be deemed by the municipality to be a material breach of this contract justifying its termination. THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 21 Page 328 of 369 Agenda Item #17. Proposal (Continued) The undersigned states that this bid proposal is the only proposal for this project in which he is interested and certifies that all of the information provided in this bid proposal is true and correct. SUBMITTAL DATE 06/17/25 FIRM NAME BlueTerra LLC FEDERAL EMPLOYER IDENTIFICATION NUMBER (FEIN) 33-2467792 (if the entity has no FEIN, include the Social Security Number of the individual signing this Proposal SIGNATURE OF RESPONSIBLE OFFICIAL PRINT NAME AND TITLE OF RESPONSIBLE OFFICIAL Heather Hreold, CEO EMAIL ADDRESS OF RESPONSIBLE OFFICIAL heatherherold@blueterra.us BUSINESS ADDRESS 865 Rhett St, Winter Garden, 34787 BUSINESS TELEPHONE (321) 626-6760 or(877) 793-4777 STATE OF INCORPORATION Florida FULL NAMES AND ADDRESSES OF PERSONS OR PARTIES INTERESTED IN THE FOREGOING BID,AS PRINCIPALS: Heather Herold, CEO BlueTerra, P.O. Box 783095 , Winter Garden, FL 34778 FULL NAME,TITLE, EMAIL ADDRESS,AND PHONE NUMBER OF PERSON MANAGING THE WORK UNDERTHIS CONTRACT: BlueTerra, P.O. Box 783095, Winter Garden, FL 34778 Kevin Perry, Director of Marine Construction, kevinperry@blueterra.us, (973) 769-5271 Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 22 Page 329 of 369 Agenda Item #17. Bid Schedule of Values Dover Ditch Living Shoreline BIDDING COMPANY NAME: ITEM ESTIMATED NO. ITEM DESCRIPTION UNIT QUANTITY UNIT PRICE EXTENDED VALUE 1 General Conditions LS 1 $ 70,452.38 $ 70.452.38 2 Unclassified Excavation CY 562 $ $33.12 $ 18,613.44 3 Placement and Compaction of Fill CY 51 $ 193.38 $ 9,862.38 4 Filter Fabric SY 1090 $ 10.56 $ 11,510.40 5 Bedding Stone CY 285 $ 85.30 $ 24,310.50 6 Rock Riprap CY 570 $ 83.19 $ 47,418.30 7 Miscellaneous Concrete Sy 20 (as needed) $ 0 $ 0 8 Miscellaneous Asphalt Sy 20 (as needed) $ 52.50 $ 1,050.00 9 Vegetation LS 1 $ 18,112.38 $ 18,112.38 10 Install Sod Sy 720 $ 16.54 $ 11,908.80 11 Remove Bollards EA 3 $ 3,120.79 $ 9,362.37 12 Silt Fence LF 747 $ 12.67 $ 9,464.49 13 Floating Turbidity Barrier LF 114 $ 86.07 $ 9,811.98 14 Protection and Relocation of LS 1 Existing Utilities $ 0 $ 0 15 Debris Skimmer/ Manatee Barrier EA 1 $ 2,500.00 $ $2,500.00 16 Replacement of Existing Fence and LS 1 Gate $ 9.912.38 $ 9,912.38 17 Undefined Conditions Allowance LS 1 $ 50,000 $ 50,000 TOTAL BID PRICE: (ITEMS 1-17)_ $ 304.289.80 TOTAL BID PRICE (ITEMS 1-17) IN WORDS: Three Hundred and Four Thousand, Two Hundred and Eighty Nine Dollars, and Eighty Cents Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 23 Page 330 of 369 Agenda Item #17. Village Clerk's ADA Compliance Statement Form The Village of Tequesta strives to be an inclusive environment. As such, it is the Village's policy to comply with the requirements of Title II of the American with Disabilities Act of 1990 ("ADA") by ensuring that the Contractor's [ agreement/bid documents and specifications] are accessible to individuals with disabilities.To comply with the ADA,the Contractor shall provide a written statement indicating that all [ agreement/bid documents and specifications],from Contractor, including files, images, graphics, text, audio,video, and multimedia, shall be provided in a format that ultimately conforms to the Level AA Success Criteria and Conformance Requirements of the Web Content Accessibility Guidelines 2.0(Dec. 11, 2008) ("WCAG 2.0 Level AA"), published by the World Wide Web Consortium ("MC"), Web Accessibility Initiative ("WAI"), available at the Web Content Accessibility Guidelines page. Required Confirmation: I, BlueTerra LLC (Print or Type Name of Firm), have read the above compliancy statement and confirm the agreement, bid documents and specifications, including files, images, graphics,text, audio,video, and multimedia, contained within this bid packet are accessible to individuals with disabilities and conforms to the Level AA Success Criteria and Conformance Requirements of the Web Content Accessibility Guidelines 2.0. 4 O,al xu, 4 444�z Representative Signature 06/16/2025 Date THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 40 Page 331 of 369 Agenda Item #17. Bid Bond *This page should be clearly marked with a tab for easy identification during the bid opening process. Bidder Surety Name: BLUETERRA LLC Name: Merchants National Bonding, Inc. Phone: (321) 626-6760 Phone: (515) 243-8171 Address (principal place of business): Address (principal place of business): 865 Rhett St. PO Box 14498, Des Moines, IA 50306-3498 Winter Garden, FL 34787 Owner Bid Name: Village of Tequesta Utilities Project(name and location): Department Phone: 561-746-5134 Dover Ditch Living Shoreline,Tequesta, Florida Address(principal place of business): 345 Tequesta Drive Tequesta, FL 33469 Bid Due Date: June 18, 2025 Bond Penal Sum: S% of Total Bid Amount Date of Bond: June 18. 2025 Surety and Bidder, intending to be legally bound hereby,subject to the terms set forth in this Bid Bond, do each cause this Bid Bond to be duly executed by an authorized officer, agent, or representative,. Surety affirms it is authorized to do business in the State of Florida, and the Village of Tequesta, and as -, having an Agent resident therein. Bidder Surety 4 BLUETERRA LLC Merchants National Bo din , Inc: (Full formal name of Bidder) (Full formal ame o uret J(cop t eat)1 BY: Y QiLd By: (Signature) (Signat ttoch Power of Attorney) Name: Heather Herold Name: Jeffrey W. Reich (Printed or typed) (Printed or typed) Title: CEO Title: Attorne -In Fact&FL Lic. Resident A ent Inquiries:407-786-7770 Attest: _ Attest: (Signature) (Signature) Jeff Huenink Name: Name: Meadow Hellandbrand CFO (Printed or typed) (Printed or typed) Title: Title: Witness Notes:(1)Note:Addresses ore to be used for giving any required notice. (2)Provide execution by any additional parties,such as joint venturers,if necessary. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 44 Page 332 of 369 Agenda Item #17. Bid Bond (Continued) 1. Bidder and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors,and assigns to pay to Owner upon default of Bidder the penal sum set forth on the face of this Bond. Payment of the penal sum is the extent of Bidder's and Surety's liability. Recovery of such penal sum under the terms of this Bond will be Owner's sole and exclusive remedy upon default of Bidder. 2. Default of Bidder occurs upon the failure of Bidder to deliver within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds, Power of Attorney(s), and Certificates)of Insurance required by the Bidding Documents. 3. This obligation will be null and void if: a. Owner accepts Bidder's Bid and Bidder delivers within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds, Power of Attorney(s),and Certificate(s)of Insurance required by the Bidding Documents,or b. All Bids are rejected by Owner,or c. Owner fails to issue a Notice of Award to Bidder within the time specified in the Bidding Documents (or any extension thereof agreed to in writing by Bidder and, if applicable, consented to by Surety when required by Paragraph 5 hereof). 4. Payment under this Bond will be due and payable upon default of Bidder and within 30 calendar days after receipt by Bidder and Surety of written notice of default from Owner,which notice will be given with reasonable promptness, identifying this Bond and the Project and including a statement of the amount due. S. Surety waives notice of any and all defenses based on or arising out of any time extension to issue Notice of Award agreed to in writing by Owner and Bidder, provided that the total time for issuing Notice of Award including extensions does not in the aggregate exceed 120 days from the Bid due date without Surety's written consent. 6. No suit or action will be commenced under this Bond prior to 30 calendar days after the notice of default required in Paragraph 4 above is received by Bidder and Surety, and in no case later than one year after the Bid due date. 7. Any suit or action under this Bond will be commenced only in a court of competent jurisdiction located in the state in which the Project is located. 8. Notices required hereunder must be in writing and sent to Bidder and Surety at their respective addresses shown on the face of this Bond. Such notices may be sent by personal delivery, commercial courier, or by United States Postal Service registered or certified mail, return receipt requested, postage pre-paid, and will be deemed to be effective upon receipt by the party concerned. 9. Surety shall cause to be attached to this Bond a current and effective Power of Attorney evidencing the authority of the officer,agent,or representative who executed this Bond on behalf of Surety to execute,seal,and deliver such Bond and bind the Surety thereby. 10. This Bond is intended to conform to all applicable statutory requirements. Any applicable requirement of any applicable statute that has been omitted from this Bond will be deemed to be included herein as if set forth at length. If any provision of this Bond conflicts with any applicable statute, then the provision of said statute governs and the remainder of this Bond that is not in conflict therewith continues in full force and effect. 11. The term"Bid"as used herein includes a Bid, offer,or proposal as applicable. Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 45 Page 333 of 369 Agenda Item #17. MERCHANT BONDING COMPANY- POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC., both being corporations of the State of Iowa,d/b/a Merchants National Indemnity Company(in California only)(herein collectively called the 'Companies')do hereby make,constitute and appoint,individually, Cheryl A Foley;Emily J Golecki;Jeffrey W Reich;Kim E Niv;Lisa A Roseland;Nathan K Reich;Robert P OLinn;Sarah K OLinn;Sonja Amanda Floree Harris;Susan L Reich;Teresa L Durham their true and lawful Attomey(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies In their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attomey Is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company(Mutual)on April 23.2011 and amended August 14, 2015 and April 27.2024 and adopted by the Board of Directors of Merchants National Bonding,Inc.,on October 16,2016 and amended on April 27,2024. 'The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attomeys-In-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof.' "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-In-Fact Includes any and all consents for the release of retained percentages andlor final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It Is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,It Is agreed that the power and authority hereby given to the Attomey-in-Fad cannot be modified or revoked unless prior written personal notice of such Intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this Instrument to be signed and sealed this 24th day of March 2025 - •.•• •., ......... MERCHANTS BONDING COMPANY(MUTUAL) •'••.�PS10Ngt�•• • ��O\NG CQ4A•• MERCHANTS NATIONAL BONDING,INC. Gj:•0(IPO ,,4• p y 00,•0(iP0/� .q . dlbla MERCHANTS NATIONAL INDEMNITY COMPANY 2003 1933c: By '.,v�•........•:i)?:= ••6�1y'' �1�� President STATE OF IOWA •'••.,�. .....••• ••.•...••• COUNTY OF DALLAS ss. On this 24th day of March 2025 before me appeared Larry Taylor, to me personally known,who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL)and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies;and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. �P�tiA�s� Penni Miller Z Commission Number 787952 • • My Commission Expires [OWN January 20,2027 Notary Public (Expiration of notary's commission does not Invalidate this instrument) I, Elisabeth Sandersfeld, Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which Is still in full force and effect and has not been amended or revoked. In Witness Whereof,I have hereunto set my hand and affixed the seal of the Companies on this 18th day of June 2025. 2003 1933 b c, Secretary Page 334 of 369 Agenda Item #17. Drug Free Workplace Certificate I,the undersigned, in accordance with Florida Statute 287.087,hereby certifythat BlueTerra LLC (Print or Type Name of Firm) 1. Publishes a written statement notifying that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace named above, and specifying actions that will be taken against violations of such prohibition. 2. Informs employees about the dangers of drug abuse in the workplace; the firm's policy of maintaining a drug-free working environment and available drug counseling, rehabilitation, and employee assistance programs;and the penalties that may be imposed upon employees for drug- use violations. 3. Gives each employee engaged in providing commodities or contractual services that are under bid or proposal a copy of the statement specified above. 4. Notifies the employees that as a condition of working on the commodities or contractual services under bid or proposal, the employee will abide by the terms of the statement and will notify the employer of any conviction of or plea of guilty or nolo contendere to any violation of Chapter 1893 or any controlled substance law of the State of Florida or the United States for a violation occurring in the workplace,no later than S days after such conviction,and requires employees to sign copies of such written statement to acknowledge their receipt. S. Imposes a sanction on or requires the satisfactory participation in a drug-abuse assistance or rehabilitation program, if such is available in the employee's community, by any employee who is so convicted. 6. Makes a good faith effort to continue to maintain a drug-free workplace through the implementation of the drug-free workplace program. "As a person authorized to sign this statement, I certify that the business,firm,or corporation named above complies fully with the requirements set forth herein." Authorized Signature 06/16/2025 Date Signed State of: Florida County of: Orange Sworn to and subscribed before me this day of,)Sme jEfl2 20 25_ xPersonally known or Produced Identification (Specify Type of Identification) NKXXE AAORUM Signature of N6tary NOWryPublk My Commission Expires-1 1/20/2028 State ofRartda . COMMI!HH614729 E)VkVs13/204028 Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 39 Page 335 of 369 Agenda Item #17. E-Verify Affidavit In accordance with Section 448.095, F.S.,Contractor acknowledges and agrees to utilize the U.S. Department of Homeland Security's E-Verify System to verify the employment eligibility of: 1. All persons employed by the Contractor to perform employment duties within Florida during the term of the contract;and 2. All persons(including SUBCONTRACTORS)assigned by the Contractor to perform work pursuant to the contract.The Contractor acknowledges and agrees that use of the U.S. Department of Homeland Security's E-Verify System during the term of the contract is a condition of the contract with the Village of Tequesta. The contractor further agrees to retain sufficient evidence of their enrollment in the E-Verify System and provide such evidence to the Village of Tequesta upon request.Sufficient evidence shall consist of a printed copy of the completed E-Verify Company Profile page,obtained from https://www.e-verify.gov. Contractor also agrees to obtain from each of its subcontractors/subconsultants an affidavit stating that the subcontractor/subconsultant does not employ,contract with,or subcontract with an Unauthorized Alien,as that term is defined in Section 448.095(1)(k),F.S.Contractor further agrees to maintain a copy of any such affidavit from a subcontractor/subconsultant for, at a minimum,the duration of the subcontract and any extension thereof. By affixing your signature below,you hereby affirm that you will comply with all E-Verify requirements. BlueTerra LLC 33-2467792 Company name Federal Employer Identification No. e� 06/16/2025 Signature Date 06/16/2025 CEO Print Name Title STATE OF FLORIDA COUNTYOF Orange-- The foregoing instrument was acknowledged before me by means of/physical presence or/ online notarization, this 06/16/9095(date) by_Heather Herold agent, title of (name of officer or officer or agent) of BlueTerra LLC (name of contractor company acknowledging),a Florida (state or place of incorporation)corporation,on behalf of the corporation. He/she is personally known to me or has produced (type of identification) as identification. [Notary Sealj Notary Public, NKXIE MORGAN Nicole Morgan NotaryPuMk Name typed,printed or stamped State of Florida Comm#HH614729 My Commission Expires; Expires 11/20/2028 Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 38 Page 336 of 369 Agenda Item #17. Trench Safety Bidder acknowledges that included in the various items of the proposal and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of Fla.) effective October 1, 1990. The bidder further identifies the costs to be summarized below. TRENCH SAFETY MEASURE EXTENDED UNITS OF UNIT UNIT (DESCRIPTION) MEASURE(LF,SY) (QUANTITY) gQ§TJ T A. N/A B. C. D. Failure to complete the above may result in the bid being declared non-responsive. THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 43 Page 337 of 369 Agenda Item #17. List of Subcontractors/Suppliers Bidder shall list below information regarding subcontractors and suppliers who will perform work or labor or render service, or supply materials to the prime contractor in or about the construction of the Work or improvement, or subcontractors licensed by the State who, under subcontract to the prime contractor, specially fabricates and installs a portion of the Work or improvement according to the plans and specifications, in an amount in excess of two percent(2%)of the prime contractor's Total Bid Price. Failure to comply with this requirement may render the Bid non-responsive and may cause its rejection. Work to be Performed/ Subcontractor Percent of Subcontractor's Materials to be Supplied License Number Total Contract Name&Address Note: Provide licenses, certifications, experience, and qualification forms for those subcontractors listed above. Attach additional pages as needed. Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 24 Page 338 of 369 Agenda Item #17. Qualification Requirements (Complete these pages entirety and include with Sealed Bid. Attach copies of applicable Licenses) THE UNDERSIGNED GUARANTEES THE TRUTH AND ACCURANCY OF ALL STATEMENTS AND ANSWERS HEREIN CONTAINED: A. Any information for which OWNER cannot corroborate is grounds for rejection of Bid. (Use additional sheets as needed to provide the required information.) B. State the numbers of years your organization has been doing business in the State of Florida: 1. We typically perform _ % of the work with our own forces. List trades below for which your organization is qualified to self-perform on this project: Marine Construction / Dredging / Rip-Rap / Plantings Nurseries / Geotextiles / Skimmer pera ion 2. Has Bidder ever failed to complete awarded work? No If so, state where,when and why: 3. State the location of the office from which this contract will be managed. P.O. Box 783095, Winter Garden, FL 34778 Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 25 Page 339 of 369 Agenda Item #17. Qualification Requirements (Continued) 4. State the number of employees available to complete the work contemplated by this contract. 5. Provide the name, experience and resume of the Project Manager who will be assigned to this contract, if awarded. Include number of years in this position and with this company. If less than 3 years with this company provide name and contact information for previous employer. (Attach additional pages as necessary). Kevin Perry, Director of Marine Construction Blue Terra team member for 1 year. He has 10 years of marine construction and general Construction experience, completing 48 marine construction projects valued at over$85M. Previously worked for Sea & Shoreline. Employment verification contact is Carol Schwartz (813) 240-8787 6. Provide name, experience and resume of the Project Superintendent who will be assigned to this contract, if awarded. Include number of years in this position and with this company. If less than 3 years with this company provide name and contact information for previous employer. (Attach additional pages as necessary). Kevin Perry, Director of Marine Construction Blue Terra team member for 1 year. He has 10 years of marine construction and general construction experience, completing 48 marine construction projects valued at over $85M. Previously worked for Sea & Shoreline. Employment verification contact is Carol Schwartz (813) 240-8787. 7. List equipment owned by Contractor to be utilized in completion of the Work identified for this contract. (Bidder certifies that all listed equipment meets requirements set forth in instructions to bidders, section 3) (Attach additional pages as necessary). Various Hand Tools 8. List equipment to be rented by Contractor to complete the Work of this contract. (Attach additional pages as necessary). Takeuchi 2150 excavator & Takeuchi TL 10 Skid Loader Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 26 Page 340 of 369 Agenda Item #17. Qualification Requirements (Continued) 9. Bidder shall include with their Bid a proposed schedule for completing the Work. The schedule shall identify tasks for the progression of work and be based on number of days from an assumed mobilization date. This schedule should, at a minimum, include all major milestones as listed in Agreement(Contract)Between Owner and Contractor. 10. Only Bidders and Subcontractor(s) who are deemed qualified by Owner, at Owner's sole discretion, will be considered for contract award. Failure to provide previous experience and qualification information requested by the Bidding Documents with the Bidder's Bid, or if the Owner cannot corroborate the previous experience and qualification information submitted by Bidder in Bidder's Bid, may result in Bid disqualification. NOTE: Bidder shall complete and submit with the Bid the following Bidder Qualification forms for the Prime Contractor and all Major Subcontractors (each whose value of work to be performed is greater than 2%of the Prime Contractor's Total Bid).All information requested on the forms shall be provided in sufficient detail for Owner to perform a comprehensive review of the Bid. For Major Subcontractors, provide previous experience and qualifications for at least three (3) projects completed over the past fifteen (15)years. NOTE: Bidders may provide additional information to assist Owner in evaluating previous experience and qualifications. Copy the forms and attach additional pages as needed. NOTE: In order to be deemed acceptable for the purpose of determining Bidder Qualification, similar projects shall be listed on the following forms and have all information completed (blanks correctly filled in) including contact names and telephone numbers of both the Owner and Engineer. THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 27 Page 341 of 369 Agenda Item #17. Qualification Requirements (Continued) As Bidder,we certify the following: (1) NAME & LOCATION OF PROJECT: Blue Springs Bank Stabilization Phase III (Orange City. FL) SCOPE OF WORK: Placing 1,000 lbs. of rock underwater with rigging for structural integrity of the spring run walls, removal disposal of existing structures, erosion and sediment control and endangered species monitoring. CHECK ONE OF THE FOLLOWING OPTIONS, BIDDER WAS: [ I PRIME CONTRACTOR [ I SUBCONTRACTOR YEAR OF PROJECT: 2022 and 2024 Phase 2: $697,000 CONTRACT VALUE: Phase 3: $885,000 TOTAL VALUE OF CHANGE ORDERS: N/A REASON FOR CHANGE ORDERS: N/A CONTRACT START AND COMPLETION DATES: April 2024 to November 2024 WAS PROJECT COMPLETED ON TIME (IF NOT EXPLAIN THE DELAYS): Yes OWNER OF PROJECT: Florida Fish and Wildlife Conservation Commission (FWC) OWNER CONTACT: NAME:Taylor Kroll, PE PHONE NUMBER: (352)339-6736 EMAIL ADDRESS:taylor.kroll@wsp.com (was with FWC, but is now with WSP) ENGINEERING FIRM (DURING CONSTRUCTION): WSP Environment & Infrastructure, Inc. ENGINEER CONTACT: NAME:John Kiefer PHONE NUMBER: (913)458-2000 EMAILADDRESS�ieferj@bv.com ADDITIONAL INFORMATION: Engineer left WSP to take a new position with Black&Veatch Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 28 Page 342 of 369 Agenda Item #17. Qualification Requirements (Continued) As Bidder,we certify the following: (2) NAME & LOCATION OF PROJECT:Three Sisters Spring Shoreline Stabilization (Crystal River, FL) SCOPE OF WORK: Restored the eroded shoreline surrounding the springs to enhance habitat and water flow. Project involved endangered species monitoring. CHECK ONE OF THE FOLLOWING OPTIONS, BIDDER WAS: [ ] PRIME CONTRACTOR [ ] SUBCONTRACTOR YEAR OF PROJECT: 2023 CONTRACT VALUE: $728,000 TOTAL VALUE OF CHANGE ORDERS: N/A REASON FOR CHANGE ORDERS: N/A CONTRACT START AND COMPLETION DATES: Feb 2024 to June 2024 WAS PROJECT COMPLETED ON TIME (IF NOT EXPLAIN THE DELAYS): Yes OWNER OF PROJECT: Southwest Florida Water Management District OWNER CONTACT: NAME: ,ianie Hagberg PHONE NUMBER:(813) 857-7878 EMAILADDRESS: janie.hagberg@swfwmd.state.fl.us ENGINEERING FIRM (DURING CONSTRUCTION): Stan Tech ENGINEER CONTACT: NAME: PHONE NUMBER: (415)281-5553 EMAIL ADDRESS:robert.terry@stantec.com ADDITIONAL INFORMATION: Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 29 Page 343 of 369 Agenda Item #17. Qualification Requirements (Continued) As Bidder,we certify the following: (3) NAME & LOCATION OF PROJECT: Estuarine Habitat Enhancements at FSUCML (St. Teresa, FL) SCOPE OF WORK: Oyster/Rip-rap reefs as well as embankment renourishment CHECK ONE OF THE FOLLOWING OPTIONS, BIDDER WAS: [ ] PRIME CONTRACTOR [ ] SUBCONTRACTOR YEAR OF PROJECT: 2022 CONTRACT VALUE: $227,163.00 TOTAL VALUE OF CHANGE ORDERS: $30,000 REASON FOR CHANGE ORDERS: To add sand - change requested by project owner CONTRACT START AND COMPLETION DATES: June 2022 to October 2022 WAS PROJECT COMPLETED ON TIME (IF NOT EXPLAIN THE DELAYS): Yes OWNER OF PROJECT: Florida Fish and Wildlife Conservation Commission OWNER CONTACT: NAME: Taylor Kroll PHONE NUMBER: (352) 339-6736 EMAIL ADDRESS: taylor.kroll@wsp.com ENGINEERING FIRM (DURING CONSTRUCTION): Amec Foster ENGINEER CONTACT: NAME: Amec Foster PHONE NUMBER: (610)828-8100 EMAIL ADDRESS: cuong.vu@amecfw.com ADDITIONAL INFORMATION: Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 30 Page 344 of 369 Agenda Item #17. Qualification Requirements (Continued) 11. BIDDER shall demonstrate the ability to complete projects on time within the contract completion dates. List ALL projects completed within the last three years that were not completed on schedule and for which liquidated damages (LD)were not incurred. Attach additional pages as needed: PROJECT NAME: OWNER NAME/CONTACT INFO: CONTRACT COMPLETION DATE: ACTUAL COMPLETION DATE: 12. List ALL projects within the past five years (started, underway, or completed) in which liquidated damages (LD) are accumulating or were incurred, either directly or indirectly.Attach additional pages as needed: PROJECT/OWNER: TOTAL LD AMOUNT ASSESSED: REASON FOR LDs: 13. List ALL projects within the past five years (underway or completed) in which adverse litigation, including but not limited to mediation, involving the Owner of the project, occurred, either directly or indirectly with the Bidder or his/her subcontractors. Attach additional pages as needed: PROJECT: OWNER: TYPE OF LITIGATION: REASON FOR LITIGATION: 14. A copy of Bidder's most recent audited financial statement may be requested as additional information after bids are received during the bid evaluation process. Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 31 Page 345 of 369 Agenda Item #17. Qualification Requirements (Continued) 15. Describe any significant or unique accomplishment in previous contracts. Include any additional data pertinent to firm's capabilities. BlueTerra team members have 10 years experience procuring, designing, permitting, Constructing, funding, and monitoring 48 marine construction projects valued at over $85M. Projects included dredging, shoreline stabilizations, rip rap, wave attenuation, living shorelines, oyster reefs, seagrass restoration, upland plantings, installation of geo ex I es, etc. (Attach additional pages as necessary) I HEREBY CERTIFY THAT THE INFORMATION SUBMITTED HEREWITH, INCLUDING ANY ATTACHMENTS, IS TRUE TO THE BEST OF MY KNOWLEDGE AND BELIEF. NAME OF ORGANIZATION: BlueTerra LLC BY: Heather Herold TITLE: CEO DATED: 06/16/2025 NOTARY ATTEST: SUBSCRIBED AND SWORN TO BEFORE ME THIS 16th DAY OF June ,2025 NICOLE MORGAN "rV Public NOTARY PUBLIC-STATE OF Florida Show OfRorwa *. . Comma HH614729 MY COMMISSION EXPIRES:11/20/2028 Expires11/20/2028 THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 32 Page 346 of 369 Agenda Item #17. Contractor Safety Qualifications/Requirements 1. APPLICABILITY 1.1 Any contractors performing maintenance, repair,turnaround, major renovations,or specialty work is subject to the contractor safety requirements of the Environmental Protection Agency Risk Management Program (40 CRF 68.87) and the Occupational Safety and Health Administration's Process Safety Management Program (29 CRF 1910.119(h)). 1.2 CONTRACTOR SHALL SUBMIT A COMPLETED COPY OF THE ATTACHED "CONTRACTOR SAFETY QUALIFICATION FORM" WITH THEIR BID. FAILURE TO INCLUDE THIS FORM WITH THE BID IS GROUNDS FOR DISQUALIFICATION. 2. OWNER RESPONSIBILITY 2.1 Selecting a Contractor: 2.1.1 When selecting a contractor, obtain and evaluate information regarding the contractor's safety program. 2.2 Informing a Contractor: 2.2.1 Inform the contractor of the known potential fire, explosion, or toxic release hazards related to the contractor's work and regulated process. 2.2.2 Explain to the contractor the applicable provisions of the facilities emergency response program (i.e. alarms, evacuation routes, etc.) 2.2.3 Inform the contractor of the facility's safe work practices of operations such as: 2.2.3.1 Confined space entry 2.2.3.2 Equipment/line opening 2.2.3.3 Lockout/tagout Program 2.2.3.4 Control over entry into regulated (i.e. hazardous) process areas 2.2.3.5 Hot Work Permit 2.3 Evaluating a Contractor's Performance 2.3.1 Evaluate the contractor's performance in fulfilling their requirements under this regulation. 3. CONTRACTOR RESPONSIBILITY 3.1 Assure that each of the contractor's employee's is trained in the work practices to safely perform his/her job, and to document that each employee understood the training. This documentation will include the name of employee, date of the training, and means used to verify that the employee understood the training. 3.2 Assure that each of the contractor's employees are instructed in the known potential fire, explosion, or toxic release hazards related to his/her job and the process, and the applicable provisions of the emergency response plan. 3.3 Assure that Contractor's employees and subcontractor's/laborers follow the facility's safety rules including safe work practices such as lockout/tagout, equipment/line opening,confined space safety, and hot work permit. 3.4 Advise the facility owner of any unique hazard presented by the contractor's work, or of any hazards found by the contractor. 3.5 Obtain and evaluate information pertaining to subcontractor's safety programs. 3.6 Assure that subcontractor's and laborers are trained in their work practice to safety perform their jobs. Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 33 Page 347 of 369 Agenda Item #17. 3.7 Maintain an active list of all workers on site at all times and provide list to Owner immediately upon request. 4. CONTRACTOR SUBMITTALS 4.1 Records Maintenance 4.1.1 The Contractor shall maintain a record of those employees who successfully completed safety training. These records must include the following information: 4.1.1.1 Name of the employee 4.1.1.2 Contents of training 4.1.1.3 Date of training 4.1.1.4 Means used to verify that the employee understood the training 4.2 Additional Responsibilities 4.2.1 Contractor must immediately inform the Owner of all contract employee injuries or illness resulting from work performed on or around and hazardous chemical process. 4.2.2 Contractor must immediately inform the Owner of any injuries resulting from any work at the facility. THIS SPACE WAS INTENTIONALLY LEFT BLANK PROCEED TO NEXT PAGE Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 34 Page 348 of 369 Agenda Item #17. Contractor Safety Qualification Form SECTION 1: COMPANY INFORMATION Company Name:BlueTerra LLC Address 1:P.O. Box 783095 Address 2: City, State,Zip:Winter Garden, FL 34778 Telephone No.:(321) 626-6760 or(877) 793-4777 Fax No.: N/A SECTION 2: NAME(S)AND RELATIONSHIPS OF PARENT COMPANY,AFFILIATES,SUBSIDIARIES, PARTNERS Company Name: N/A Address: City, State,Zip: Relationship: Company Name: Address: City, State,Zip: Relationship: SECTION 3: INSURANCE COVERAGE 3.1 Please attach certificates showing the extent of coverage, exclusions and deductibles for the following: - General Business Liability Insurance - Professional Liability Insurance - Contractors Pollution Liability Insurance - Worker's Compensation Insurance 3.2 How long have you been covered by your current provider of Worker's Compensation Insurance? 1 year 3.3 List the Experience Modification Ratio (EMR)that has been applied to your company's worker's compensation insurance policy for the past five years: Year Intrastate EMR Interstate EMR Comments 2025 1.00 See below As a first year company, we have a flat 1.00 EMR. We have only done projects in Florida so do not have an Interstate EMR. Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 35 Page 349 of 369 Agenda Item #17. Contractor Safety Qualification Form (Continued) 3.4 List the contact information for an insurance broker who can verify your EMR's: Name: Sean Crane, Baldwon Group Address 1: 4211 W Boy Scout Blvd Address 2: Suite 800 City, State,Zip:Tampa, FL 33607 Telephone No.: (866) 279-0698 If you do not have an EMR, please explain: As a first year company, we have an EMR of 1.00. We do not currently do projects out of Florida so we do not have an interstate EMR. SECTION 4: INJURY AND FATALITY INFORMATION 4.1 Please transfer the numbers and rates of injuries and illnesses from your firm's OSHA No. 200 Logs to the table below: Year: Year: Year: Statistic No. Rate No. Rate No. Rate Lost Workday Cases Restricted Workday Cases Medical Treatment (not First Aid) Cases Total Illness Cases Total Recordable Cases Fatalities 4.2 If your company has had fatalities in the past three years include location, cause and corrective actions in the space below: N/A Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 36 Page 350 of 369 Agenda Item #17. Contractor Safety Qualification Form (Continued) SECTION 5:SAFETY MEETINGS 5.1 Do you require that documented safety meetings be held for: - Field Supervisors?_Yes_No Frequency: Daily - Employees? X Yes— No Frequency: Daily - New Hires? x Yes—No Frequency: Daily - Subcontractors? Yes_No Frequency: Daily SECTION 6:SAFETY AUDITS 6.1 Will a representative of your company audit safety practices on this job? —Yes —No Name: Kevin Perry Title: Director of Marine Construction How frequently will the representative visit the project site? Weekly SECTION 7: HEALTH AND SAFETY PROGRAM 7.1 Does the company have a health and safety program? If yes, please give details below. (The contractor is encouraged to attach a copy of the program to satisfy this requirement). We require Superintendents to have OSHA 30 certification and crew members to have OSHA 10 certifications. 7.2 Please give the name and telephone number of your company's health and safety officer, if any: Name: Kevin Perry Title: Director of Marine Construction Telephone No.: (973) 769-5271 SECTION 8: HEALTH AND SAFETY CITATIONS 8.1 Attach a list of any State or Federal Health and Safety citations received during the past three years. N/A SECTION 9:SIGNATURE OF COMPANY OFFICER I certify that to the best of my knowledge, information, and belief formed after reasonable inquiry, the information submitted is true, accurate, and complete. Name (print): Heather Herold Title: CEO Signature: �6i4a&/ Date:06/16/2025 Village ofTecluesta Utilities Department Dover Ditch Living Shoreline Page 37 Page 351 of 369 Agenda Item #17. 4 BlueTerra Dover Ditch Living Shoreline Proposed Project Schedule No. Item Start Date End Date Work Days 1 General Conditions 14-Jul 12-Sep Duration of Project 2 Unclassified Excavation 14-Jul 25-Jul 10 3 Placement and compaction 28-Jul 30-Jul 3 of fill 4 Filter Fabric 31-Jul 15-Aug 12 5 Bedding stone 31-Jul 15-Aug 12 6 Rock rip rap 31-Jul 15-Aug 12 7 Miscellaneous Concrete 1-Sep 5-Sep 5 8 Miscellaneous Asphalt 1-Sep 5-Sep 5 9 Vegetation 18-Aug 22-Aug 5 10 Install Sod 25-Aug 29-Aug 5 11 Remove Bollards 14-Jul 14-Jul 1 12 Silt Fence 14-Jul 12-Sep Duration of Project 13 Turbidity Barriers 14-Jul 12-Sep Duration of Project 14 Protection / relocate utilities 14-Jul 12-Sep Duration of Project 15 Debris skimmer/ manatee 8-Sep 12-Sep 5 barrier 16 Undefined conditions 14-Jul 12-Sep Duration of Project allowance 17 Remove and reinstall fence 8-Sep 12-Sep 5 Page 352 of 369 gen a item . .L 0 Z O c Q �' J o N D w C7 LE W a' Cn � c Q m ? � Q o z o Q � � o O Z w � o 40. � J �� An CV N 0 Q E f oo o Q W W �Cie M cf M J 0 LL V LL,U O U c+Ln ~ncz L J CN — LL LLJ � F- U o o +J OW a z rll� a 2 a U M lu Q wcj� �+ m V) °= Ow0 W LL Z o � oO o W _ Z � Z W U = LLJ O NN OQ v w Z 2 z `J N O z o � }' V z u w r 3 m p U r J a o V J z LL + W U �O � z > VLI Q Qj o Z w O W C7 0 O w V H V F- o I 4' I Q o s I o W H i � � I 4WRIp9 . 'Cry ❑� pio, [ Agenda Item BlueTerra Kevin Perry/Director of Marine Construction Contact Information Phone: 973-769-5271 Email: kevinperry@blueterra.us Office: P.O Box 783095,Winter Garden, FL 34778 Office Phone: 877.793.4777 Website: blueterra.us Areas of Specialization Dredging, Diving,Welding, Bank Stabilizations, Oyster Reef Restorations, Buoy Installations,Seagrass Restorations, Rip Rap, Drainage, Grading, Grassing, Seeding,Sodding, Landscaping, Roadway Signage Educational background Institution Field of Study Degree Year Commercial Diving Technologies Diving Certification 2018 Mansfield University Science B.S. 2006 Employment BlueTerra LLC Director of Marine Construction 2024-Present Sea &Shoreline, LLC Diver,Senior Project Manager—Marine 2019-2024 Anchor Diving and Construction Diver 2019 Bolt Underwater Services Diver 2019 KDP Designs Owner/Operator-General Construction 2012-2018 Peluso Home Improvement Contractor 2008-2012 Training and Certifications Licenses and Permits • Occupational Diver Certification (DCBC) • Nitrox Diver Certification (NAUI) • TWIC card (Transportation Worker • Assoc.Of Divers Contractors Certification Identification Credential) (ADCI) • Underwater OXY-ARC Cutting/BROCO- • Open Water Scuba Diver(NAUI) Firewire-Oxylance • Basic Life Support CPR and First Aid (DAN) • Exothermic&Tubular Electrodes • Oxygen first aid (DAN) • Exceeds IMCA,ADCI,ANSI guidelines • Unrestricted Surface Supplied Air Diver • OPITO approved BOSIET&CA-EBS • Underwater Welding for Commercial Divers • Top Side Welding for Commercial Divers • Qualified Rigging for Commercial Diving • Non-Destructive Testing API/ASNT Visual Inspection Mag Particle and Ultrasonic • Job Safety/Hazard Analysis(JSA)Certificate • Hazmat/Hazwoper • Active Diver Medical Projects Executed • Managed marine construction crew for the following projects: o Tampa Bay Marina Dredge 2024 o Oyster Reef Enhancement at the FSU Coastal & Marine Laboratory 2024 o Titusville Causeway Multitrophic Restoration and Living Shoreline Resileincy Action Project 2024 o Weedon Island Preserve Salt Marsh Restoration 2024 o Blue Springs Bank Stabilization 2024 o New Pass Terminal Groin Restoration 2024 Page 354 of 369 Agenda Item #17. o Boggy Bayou Headwaters Restoration Project 2023 o FWC M/V El Dorado Grounding Area Fill &Grade 2023 o City of Naples Oyster Reef Restoration o Three Sisters Springs Canal Shoreline Stabilization Construction Project 2023 o Catalpa Cove Maintenance Dredging 2022 o Sebastian Inlet State Park Coconut Point Emergency Stabilization 2022 o FWC Fruit Farm Tidal Creek Restoration Phase 2 2022 o FWC Warm Mineral Springs Restoration and Enhancement 2022 o Palma Sol Boat Ramp Navigation Maintenance Dredging 2022 o Hayward Canal Dredging 2022 o FWC Estuarine Habitat Restoration 2022 o Hornsby Spring Restoration 2022 o Marquesas Seagrass Mitigation 2022 o FWC Blue Springs Bank Stabilization 2021 o Mayport Naval Station Dredge 2021 o City of Fort Walton Beach Lake Earl Maintenance Dredge 2021 o City of Naples Oyster Reef Site 3 Restoration 2020 o City of Holmes Beach Navigational Dredge 2020 o John Pennekamp Coral Reef State Park Buoy Installation 2020 o Kings Bay Restoration Project 2019 Page 355 of 369 �II�JJJm #17. DATE(MM/DD/YYYY) CERTIFICATE OF LIABILITY INSURANCE 3/20/2025 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Rebecca Oberpriller The Baldwin Group Southeast LLC PHONE FAX 4211 W Boy Scout Blvd Ste 800 A/C No EXt: 713463-2120 vc,No): Tampa FL 33607 ADDRESS: rebecca.oberpriller@baldwin.com INSURER(S)AFFORDING COVERAGE NAIC# License#:L002281 INSURERA: United Fire&Casualty Company 13021 INSURED BLUELLC-04 INSURERB:American Equity Insurance Comp 43117 BlueTerra, LLC 865 Rhett Street INSURER C: Winter Garden FL 34787 INSURERD: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:793897619 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR I POLICY NUMBER MM/DD/YYYY MM/DDIYYYY A X COMMERCIAL GENERAL LIABILITY OMS2500225101 2/4/2025 2/4/2026 EACH OCCURRENCE $1,000,000 CLAIMS-MADE OCCUR DAMAGE TO RENTED PREMISES Ea occurrence $50,000 MED EXP(Any one person) $5,000 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY PRO LOC PRODUCTS-COMP/OP AGG $1,000,000 X JECT OTHER:El $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ Ea accident ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident UMBRELLALIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ B WORKERS COMPENSATION ALMA-031325-050856-01 3/15/2025 3/15/2026 X PER OTH- B AND EMPLOYERS'LIABILITY YIN 1598937Y 3/15/2025 3/15/2026 STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE [-W] E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? NIA (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Waiver of Subrogation in favor of the Certificate Holder applies to State Act Workers Compensation(#1598937Y)if required by written contract,and subject to terms,conditions,and exclusions of the policy. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Paychex PEO Holdings, LLC 911 Panorama Trail South AUT ORIZEDREPRE ENT TVE Rochester NY 14625 r @ 1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD Page 356 of 369 Agenda Item #17. WORKERS COMPENSATION AND EM1PL0YERS'Ll`A 1IUTY INSURANCE POLICY-INFORMATION PAGE INSURER: POLICY NO- 202501-15-96-93-7Y MA'NUEA,CTURERS ALLIANCE !NSURA14CE COMPANY NEW BUSINESS NCO Cornpany No- 20737 Account No,. 1598937 N.J.Tagpayer identli~eation No. ITLI 11, NAMED INSURED AND MAILING ADDRESS; PRODUCER NANE A KD ADDRESS; BLUE TtF RA, LLC THE AMERICAN EQUITY UNIDZR BITERS, INC. P,0. I3o `783095 11 NORTH WATER STREET WINTER GARDEN FL 34767 32ND FLOOR MBILE AL 36602-0000 PRODUCER NO.: 1137 LEGAL ENTITY LIMITED LIABILITY CO Y OTHER WORKPLACES NOT SHOWN ABOVE.- {See Exfenslon Of Infon a ton I} } rTEM 2, PC OCY PERIOD: ROM'. 03-15-2025 To; 03-15-2026 Effer,tive 12:01 AM. Slwdard Trw at the I.nsured's nailing address. ITEM 3. COVERAGE, A. Workers Compensallon Insuranoe; Pert One of Ow palky spplles to the Workers Cessation Law of the Mates listed here: FL A Emplayers' Liability Instar Cart Two of the polity applies to work in each sta4a listed in Ilem 3.A. The tirnits of liabibty under Part Two we: Soddy Injury byAc nt: S 1,000,000 each aecidenl Roddy Injury by Chsease: S 1,00G,000 polwylirrit Boddy injury by 101sme, $ 1,000,000 each employee C_ Other SISIBs Insurance: Part Three of the policy applilas to the states.if my. listed here: PAL AK AZ AR CA CO CT DE AC GA fiI TZ III 1N IA KS KY LA h+M Mb MA MT W MS M lam' NE t+TSJ" M NJ NM NY NC OE OR PA RX SC SD TN TX UT VT VA wv wr D_ This Policy includes these Endorsements and-S u1 es: See Schedule of Foy and Endorsenvents. rT4uM 4, PREMIUM: The premium#car this Policy wall be delerminad by our Manuals of Rules, Clwsi6cations,Rates and Rating Plans. All informant..required on the 1uVorkers Compensation Classification Schedule is subpmt to Yarifir,ation and change by audit See Cla:s5ifi on Sct"U6, FL VYorkers Cornp- Insurance "nimum Premium: $ 1 71 Guaranty Assoc. Surcharge; FL 4'4L'JlRKERS CLOMP. INSUR,AN Audit Period:ANNUAL Total Es&nalad GUARANTY ASSOC, SURC HAM ,Annuat Prondorn: 542 cDmufli M". Issued At_ 23 ATLANTA . Date: 0 4-07-25 Counlersigreed by VC 00 Ott 111 A CupyTighl 1907 f- tivnal GDurcil em Compv�fivn lr=nnW ;i Page 357 of 369 Agenda Item #17. Sworn Statement On Public Entity Crimes THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. 1. This sworn statement is submitted to City of Tequesta [print name of the public entity] by Heather Herold, CEO [print individual's name and title] for BlueTerra LLC [print name of entity submitting sworn statement] whose business address is P.O. Box 783095, Winter Garden FL 34778 and (if applicable) its Federal Employer Identification Number(FEIN) is: 33-2467792 (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn Statement: ) 2. 1 understand that a "public entity crime" as defined in Paragraph 287.133(1)(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to, any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. 1 understand that "convicted" or "conviction" as defined in Paragraph 287.133(1)(b), Florida Statutes, means a finding or guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment or information after July 1, 1989, as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere. 4. 1 understand that an "affiliate" as defined in Paragraph 287.133(1)(a), Florida Statutes, means: 1. A predecessor or successor of a person convicted of a public entity crime: or 2. An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term affiliate includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement,shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. 1 understand that a "person" as defined in Paragraph 287.133(1)(e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the Village of Tequesta Utilities Department Dover Ditch Living Shoreline Page 41 Page 358 of 369 Agenda Item #17. provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. 6. Based on information and belief,the statement which I have marked below is true in relation to the entity submitting this sworn statement. [indicate which statement applies.] X Neither the entity submitting this sworn statement, nor any officers,directors,executives, partners,shareholders,employees,members,or agents who are active in the management of the entity, nor any affiliate of the entity, has been charged with and convicted of a public entity crime subsequent to July 1, 1989. _The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity,or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1,1989. _The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity,or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1,1939. However,there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order] I UNDERSTAND THATTHE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH 1 (ONE)ABOVE IS FOR THAT PUBLIC ENTITY ONLY AND,THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED, I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017,FLORIDA STATUTES FOR CATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. �a [signature] Sworn to and subscribed before me this 16th day of June _2025 Personally known OR Produced identification Notary Public—State of Florida My commission expires 11/20/202R (Printed typed or stamped commissioned name notary public) NICOLE MORGAN Notary Public State of Florida Comm#HH614729 .10 Expires 11/20/2028 Village ofTequesta Utilities Department Dover Ditch Living Shoreline Page 42 Page 359 of 369 Agenda Item #17. Village of Tequesta 345 Tequesta Drive 561-768-0700 Tequesta, FL 33469 www.tequesta.org BID NO ITB-UTIL 05-01-2025/AF ADDENDUM NO. 1 TO CONTRACT DOCUMENTS ISSUED: 5/30/2025 PROJECT TITLE: DOVER DITCH LIVING SHORELINE (ITB-UTIL 05-01-2025/AF) TO: ALL PLAN HOLDERS OF RECORD This addendum shall modify, clarify, change, or add information and become part of the above referenced Contract Documents. Acknowledge receipt of this Addendum in the space provided on the Bid Proposal form. The Contract Documents shall include the following: GENERAL PRE-BID MEETING MINUTES ADD the Prebid Meeting Minutes and Sign-In Sheet to the Bid Documents. PLANS GN-1: GENERAL NOTES ADD item 16 to the "Summary of Quantities", "Replacement of Existing Fence and Gate". ADD bullet 16 to the "MEASUREMENT AND PAYMENT" section to read: Payment for the replacement of existing fence and gate shall be made on a lump sum basis, which shall include all efforts related to the removal and disposal of the existing fence and gate and installation of a new fence and gate with the same material and components as existing. REST-2: RESTORATION PLAN ADD the landscape specifications to the sheet. CHANGE detail 1, "SHRUB/GROUND COVER PLANTING & SPACING" to reflect design information not to be included. This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 360 of 369 Agenda Item #17. CHANGE detail 2, "SMALL TREE PLANTING: LESS THAN 2" CALIPER" to reflect design information not to be included. ADD detail 3, "SOD PLANTING" to the sheet. TECHNICAL SPECIFICATIONS MEASUREMENT AND PAYMENT SECTION 01150 CHANGE section 1.06 bullet 16 to read: 16. REPLACEMENT OF EXISTING FENCE AND GATE Payment for the replacement of existing fence and gate shall be made on a lump sum basis, which shall include all efforts related to the removal and disposal of the existing fence and gate and installation of a new fence and gate with the same material and components as existing. ADD bullet 17 in section 1.06 to read: 17. UNDEFINED CONDITIONS ALLOWANCE Included in this item is work associated with unforeseen conditions associated with the Work of this Contract. This is an allowance, to be used solely at the discretion of the Owner and any work to be completed under this item must be specifically approved in writing by the Owner, prior to the Work being initiated. Owner must approve in writing the mutually agreed upon cost and additional time (if any) associated with any Work performed under this Item.Any work completed by the Contractor, under this Item, without the Owner's prior written approval is at the Contractor's sole risk and may not be approved for payment. The Owner reserves the right to award any, all, or none of this Allowance. END OF ADDENDUM 1 This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 361 of 369 Agenda Item #17. Village of Tequesta 345 Tequesta Drive 561-768-0700 Tequesta, FL 33469 www.tequesta.org BID NO ITB-UTIL 05-01-2025/AF ADDENDUM NO. 2 TO CONTRACT DOCUMENTS ISSUED: 6/10/2025 PROJECT TITLE: DOVER DITCH LIVING SHORELINE (ITB-UTIL OS-01-2025/AF) TO: ALL PLAN HOLDERS OF RECORD This addendum shall modify, clarify, change, or add information and become part of the above referenced Contract Documents. Acknowledge receipt of this Addendum in the space provided on the Bid Proposal form. The Contract Documents shall include the following: GENERAL SUBMISSION OF BID THROUGH DEMANDSTAR Bidders are advised that the following documents are listed on DemandStar to be submitted with a bid but are not required to be submitted. Certification of these items is included within other forms required to be submitted. Please submit a blank page for these documents with your bid. Non-submission of these documents will not disqualify a bidder or result in a non-responsive bid. • Statement of Disputes • Noncollusion affidavit • Scrutinized Companies Certification Form FRONT END DOCUMENTS REPLACE the cover sheet of the bid documents with the cover sheet included in this Addendum. CONTRACTOR QUESTIONS AND VILLAGE ANSWERS ADD the Contractor Questions to the Bid Documents. This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 362 of 369 Agenda Item #17. PLANS GN-1: GENERAL NOTES REPLACE bullet 3 in the "MEASUREMENT AND PAYMENT" section to with bullet 3 below: Payment for placement and compaction of fill shall be measured per cubic yard of fill placed and compacted on the site per FDOT standard specification 120-8. This includes cleanup and finished grading of the site. TYP-1: TYPICAL SECTIONS ADD "BEDDING STONE BELOW HIGH TIDE WATERLINE" and "BEDDING STONE ABOVE HIGH TIDE WATERLINE" to the legend. DET-1: DETAILS CHANGE detail 3, "DEBRIS SKIMMER/MANATEE BARRIER", to become detail 2. CHANGE detail 2, "BANK STABILIZATION", to become detail 3, and REPLACE it with the South Florida Water Management District construction detail for bank stabilization included in the revied Detail sheet provided in this addendum. TECHNICAL SPECIFICATIONS MEASUREMENT AND PAYMENT SECTION 01150 REPLACE section 1.06 bullet 3 with bullet 3 below: 3. PLACEMENT AND COMPACTION OF FILL Payment for placement and compaction of fill shall be measured per cubic yard of rill placed and compacted on the site per FDOT standard specification 120-8. This includes cleanup and finished grading of the site. END OF ADDENDUM 2 This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 363 of 369 Agenda Item #17. Village of Tequesta 345 Tequesta Drive 561-768-0700 Tequesta, FL 33469 www.tequesta.org BID NO ITB-UTIL 05-01-2025/AF ADDENDUM NO. 3 TO CONTRACT DOCUMENTS ISSUED: 6/13/2025 PROJECT TITLE: DOVER DITCH LIVING SHORELINE (ITB-UTIL 05-01-2025/AF) TO: ALL PLAN HOLDERS OF RECORD This addendum shall modify, clarify, change, or add information and become part of the above referenced Contract Documents. Acknowledge receipt of this Addendum in the space provided on the Bid Proposal form. The Contract Documents shall include the following: GENERAL CONTRACTOR QUESTIONS AND VILLAGE ANSWERS ADD the Contractor Questions and Village Answers to the Bid Documents. END OF ADDENDUM 3 This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 364 of 369 Agenda Item #17. Village of Tequesta 345 Tequesta Drive 561-768-0700 Tequesta, FL 33469 www.tequesta.org BID NO ITB-UTIL 05-01-2025/AF ADDENDUM NO. 4 TO CONTRACT DOCUMENTS ISSUED: 6/16/2025 PROJECT TITLE: DOVER DITCH LIVING SHORELINE (ITB-UTIL 05-01-2025/AF) TO: ALL PLAN HOLDERS OF RECORD This addendum shall modify, clarify, change, or add information and become part of the above referenced Contract Documents. Acknowledge receipt of this Addendum in the space provided on the Bid Proposal form. The Contract Documents shall include the following: GENERAL FRONT END DOCUMENTS REPLACE the Bid Schedule of Values in the bid documents with the Bid Schedule of Values included in this Addendum. END OF ADDENDUM 4 This document may be reproduced upon request in an alternative format by contacting the Village Clerk's Office at 561-768-0440 or by completing our accessibility form: https://bit.ly/3mnfeU4 Page 365 of 369