Loading...
HomeMy WebLinkAboutAgreement_General_10/9/2025_Holtz Consulting Engineers, Inc. r � ORIGINAL GENERAL CONSULTING SERVICES CONTINUING CONTRACTS RFQ-PW/Utilities - 03-10-2025/MC Holtz Consulting Engineers, Inc. EXECUTED MAY 2025 MOLLY YOUNG MAYOR RICK SARTORY VICE-MAYOR JAYSON E. FRENCH COUNCIL MEMBER LAURIE BRANDON COUNCIL MEMBER PATRICK PAINTER COUNCIL MEMBER JEREMY ALLEN VILLAGE MANAGER MARJORIE G. CRAIG UTILITIES DIRECTOR DOUG CHAMBERS PUBLIC WORKS DIRECTOR WAYNE CAMERON BUILDING DIRECTOR 2.3 The Village and Engineer will confer prior to the issuance of any WA to discuss the scope of the Work,the time needed to complete the Work, including phasing, if any, and the fees for services to be rendered in connection with the Work. Thereafter, Engineer will submit a proposed WA to Village which shall state with specificity and detail the scope of Work, the time for completion, including phasing, if any, and the fees. WAs may divide the Work into individual tasks or phases, as discussed between the Village and Engineer prior to the issuance of the WA. At the discretion of Village Manager, WAs for certain general utility and civil services of minimal scope (those that .... do not exceed $15,000.00 total cost per WA) may be issued verbally for purposes of expediency but shall be followed up by Engineer with a written WA as soon as practical. Additionally, at the discretion of Village, a written WA for general Work services to be performed over a specified period (months, or years) may be issued. In such event, Engineer shall invoice Village from time to time, pursuant to Article 3 hereinbelow, against the agreed fees based on authorization from the Village Manager. Engineer shall commence no Work prior to receipt of Village authorization. Engineer shall not exceed the fee amount in any WA without prior Village authorization. Village agrees to cooperate with Engineer at all times with the provision of plans or other data in the possession of Village and available in Village files for any Work authorized hereunder. 2.4 Means, Methods & Safety. The Engineer will neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences or procedures, or for the safety precautions and programs in connection with the construction of the subject project(s). ARTICLE 3. COMPENSATION 3.1 The Village shall pay Engineer in accordance with each individual WA; however, such WA shall be based upon the Fee Schedule attached hereto as Exhibit"A"and incorporated by reference as part of this Agreement.Compensation based upon such Fee Schedule will be negotiated as a lump sum price or as an hourly rate for each individual WA as set forth in Article 2 hereinabove. Payments shall be made by Village to Engineer on a monthly basis, pursuant to the Engineer's invoice for Work completed. 3.2 All requests for payment of "out-of-pocket" expenses which may be eligible for reimbursement shall be included in the individual WA applicable to the project.Copies of paid receipts, invoices or other documentation acceptable to the Village Manager may be requested by the Village for _ documentation sufficient to establish that the expense was actually incurred. No payment will be made for items not listed on the WA unless approved by the Village Manager prior to the expenditure by Engineer. 3.3 All fees presented in the Fee Schedule will remain in effect for the duration of the Agreement term. If the Agreement is renewed for any additional terms, as outlined in Article 1 of this agreement, the Engineer may request, through a formal amendment, a change in fees by mutual consent of both parties. ARTICLE 4. INSURANCE 4.1 During the performance of the services under this Agreement, Engineer shall maintain the following insurance policies written by an insurance company authorized to do business in Florida: 1. Professional liability of$2,000,000 per claim and $2,000,000 aggregate. 2. Commercial General Liability limits of$1,000,000 each occurrence and$2,000,000 aggregate. 3. General and Automobile liability insurance with bodily injury limits of not less than$500,000 for each person and not less than$500,000 for each accident and with property damage limits - Page 2 of 9 of not less than $1,000,000 for each accident, and any greater limits as may otherwise be required by law. 4. Workers' Compensation insurance in accordance with statutory requirements. 4.2 Engineer shall furnish the Village certificates of insurance which shall include a provision that policy cancellation, non-renewal or reduction of coverage will not be effective until at least thirty (30) days written notice has been made to the Village. Engineer shall include the Village as an additional insured on the general and automobile liability insurance policies required by the Agreement. All of Engineer's subcontractors shall be required to include the Village and Engineer as additional insureds on their general and automobile liability insurance policies. Engineer shall not commence work under this Agreement or any WA issued hereunder until all insurance required as stated herein has been obtained and certificates evidencing same are on file with the Village. ARTICLE S. STANDARD OF CARE 5.1 Engineer shall exercise the same degree of care, skill and diligence in the performance of the services as is ordinarily provided by a comparable professional under similar circumstances and shall be obligated to correct services which fall below such standards at no additional cost to the Village. Engineer agrees that all services shall be performed by skilled and competent personnel. ARTICLE 6. INDEMNIFICATION 6.1 Engineer agrees to protect, indemnify, and hold harmless the Village, its employees and representatives,from and against any and all claims and liabilities, including all attorneys'fees and court costs recoverable under applicable law, including appeals, for which the Village, its employees and representatives, can or may be held liable as a result of injury(including death)to persons or damage to property to the extent caused by the negligence, recklessness, or intentionally wrongful acts or omissions of Engineer, its employees or agents, including subcontractors, in the performance of services under this Agreement. Engineer shall not be required to indemnify the Village or its agents, employees or representatives when an occurrence results from the wrongful acts or omissions of the Village or its agents, employees or _ representatives.The terms and conditions of this Article shall survive the completion of all services, obligations and duties provided for in this Agreement as well as the termination of this Agreement for any reason. ARTICLE 7. INDEPENDENT CONTRACTOR 7.1 Engineer undertakes performance of the services as an independent contractor and shall be wholly responsible for the methods of performance utilized. Engineer shall not pledge the Village's credit or make it a guarantor of payment of surety for any contract, debt, obligation,judgment, lien or any form of indebtedness. Engineer further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Agreement. ARTICLE 8. AUTHORITY TO PRACTICE 8.1 Engineer hereby represents and agrees that it has and will continue to maintain all professional licenses and approvals required to conduct its business, and that it will at all times conduct its business activities in a reputable manner. Page 3 of 9 ARTICLE 9. COMPLIANCE WITH LAWS 9.1 In performance of the services, Engineer will comply with applicable and published regulatory requirements, including federal, state, special district and local laws, rules, regulations, orders, codes, criteria and standards. ARTICLE 10. SUBCONTRACTING 10.1 The Village reserves the right, in its sole discretion,to accept or reject the use of a subcontractor and to inspect all facilities of any subcontractor to insure that the selected subcontractors will be able to perform properly under this Agreement. If a subcontractor fails to perform or make progress as required by any WA and it becomes necessary to replace the subcontractor in order to complete the work in a timely fashion, Engineer shall promptly provide a replacement, subject to acceptance of the new subcontractor by the Village. ARTICLE 11. FEDERAL AND STATE TAXES 11.1 The Village is exempt from federal tax and state sales and use taxes. Upon request,the Village will provide an exemption certificate to Engineer. Engineer is not exempt from paying sales tax to its suppliers for materials to fulfill contractual obligations with the Village, nor shall Engineer be authorized to use the Village's Tax Exemption Number in securing such materials. ARTICLE 12. AVAILABILITY OF FUNDS 12.1 The obligations of the Village under this Agreement and any WA are subject to the availability of funds lawfully appropriated for its purpose by the Village Council of the Village of Tequesta. Engineer may rely on the execution of an individual WA as evidence that funds have been appropriated. ARTICLE 13. TERMINATION OF AGREEMENT _ 13.1 This Agreement, or any WA issued hereunder, may be terminated by either party with or without cause upon thirty (30) days prior written notice to the other. Unless Engineer is in breach of this Agreement, Engineer shall be paid for services rendered to the Village's reasonable satisfaction through the date of termination. Notice as required hereunder shall be sufficient when provided in accordance with Article 14 herein below. ARTICLE 14. NOTICE 14.1 Any notice, demand, communication or request required or permitted hereunder shall be in writing and delivered in person, by facsimile or sent by certified mail as follows: AS TO VILLAGE WITH COPY TO AS TO ENGINEER Jeremy Allen Keith W. Davis, Esq. Stephen Fowler Village Manager Village Attorney Vice President Village of Tequesta Davis&Ashton, P.A. Holtz Consulting Engineers, Inc. 345 Tequesta Drive 701 Northpoint Parkway, Suite 205 270 South Central Blvd,Suite 207 Tequesta, FL 33469 West Palm Beach, FL 33407 Jupiter FL 33458 14.2 Notices shall be effective when received at the addresses as specified above. Facsimile transmission is acceptable notice effective when received, however, facsimile transmissions received (i.e., printed) after 5:00 p.m. on weekends or holidays will be deemed received on the next business day.The original of the notice must additionally be sent by certified mail.Changes in the respective addresses to which such notice is to be directed may be made from time to time by either party by written notice sent by regular mail or facsimile to the other party. Page 4 of 9 ARTICLE 15. UNCONTROLLABLE FORCES 15.1 Neither Village nor Engineer shall be deemed in default of this Agreement if delays or failure of performance is due to uncontrollable forces, the effect of which, by the exercise of reasonable diligence,the nonperforming party could not avoid.The term "uncontrollable force(s)"shall mean _.. any event which results in the prevention or delay of performance by a party of its obligations under this Agreement which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage and governmental actions. The nonperforming party shall, within a reasonable time of being prevented or delayed from performance by an uncontrollable force,give written notice to the other party describing the circumstances and uncontrollable forces preventing continued performance of the obligations of this Agreement. Notice as required hereunder shall be sufficient when provided in accordance with Article 14 hereinabove. 15.2 Neither party shall, however, be excused from performance if nonperformance is due to forces which are preventable, removable,or remediable and which the nonperforming party could have, with the exercise of reasonable diligence, prevented, removed or remedied with reasonable dispatch. ARTICLE 16. OWNERSHIP OF DOCUMENTS 16.1 Engineer shall be required to cooperate with other consultants relative to providing information requested in a timely manner and in the specified form. All instruments of professional services, including, but not limited to, documents, records, disks, original drawings or other information created or procured by Engineer for any project which is the subject of this Agreement and an individual WA shall,upon completion of the work and payment of all monies due Engineer,become the property of the Village for its use and/or distribution as may be deemed appropriate by the Village. However, both parties specifically acknowledge and agree that any re-use of such documents by the Village, for other than the specific purpose intended, without written verification and adaption by Engineer for such specific purpose will be at the sole risk of the Village and without liability or legal exposure to Engineer. ARTICLE 17. ACCESS AND AUDITS 17.1 Engineer shall maintain adequate records to justify all charges and costs incurred in performing work authorized under this Agreement and individual WAs for at least three (3) years after completion of the applicable project. The Village shall have access to such books, records and documents as required in this section for the purpose of inspection or audit during normal working business hours at Engineer's place of business. ARTICLE 18. NON-DISCRIMINATION 18.1 Engineer represents that all of its employees are treated in a fair and equitable manner without regard to race, color, religion,gender,age or national origin. ARTICLE 19. ENFORCEMENT COSTS 19.1 If any legal action or other proceeding is brought for the enforcement of this Agreement, or because of an alleged dispute, breach, default or misrepresentation in connection with any provisions of this Agreement, the successful or prevailing party or parties shall be entitled to recover reasonable attorneys' fees, court costs and all expenses (including taxes) even if not taxable as court costs(including,without limitation,all such fees,costs and expenses incidental to Page 5 of 9 appeals), incurred in that action or proceeding, in addition to any other relief to which such party or parties may be entitled. ARTICLE 20. GOVERNING LAW AND VENUE 20.1 This Agreement shall be governed by the laws of the State of Florida. Any and all legal action necessaryto enforce the Agreement will be held in the state orfederal courts in and for Palm Beach County and the Agreement will be interpreted according to the laws of Florida. ARTICLE 21. SUCCESSORS AND ASSIGNS 21.1 The Village and Engineer each binds itself and its partners, successors, assigns and legal _ representatives to the other party in this Agreement and to the partners, successors, executors, administrators,assigns and legal representatives. Engineer shall not assign this Agreement without the express written approval of the Village. ARTICLE 22. SEVERABILITY 22.1 The invalidity, illegality or unenforceability of any provision of this Agreement, or the occurrence of any event rendering any portion or provision of this Agreement void, shall in no way affect the validity or enforceability of any other portion or provision of the Agreement. Any void provision shall be deemed severed from the Agreement and the balance of the Agreement shall be construed and enforced as if the Agreement did not contain the particular portion or provision held to be void. ARTICLE 23. PUBLIC ENTITY CRIMES _ 23.1 Contractor acknowledges and agrees that a person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor,supplier or sub- contractor under a contract with any public entity;and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, Florida Statues,for _ CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list.The Contractor will advise the OWNER immediately if it becomes aware of any violation of this statute. ARTICLE 24. SCRUTINIZED COMPANIES 24.1 Contractor certifies that it and its subcontractors are not on the Scrutinized Companies that Boycott Israel List and are not engaged in the boycott of Israel. Pursuant to section 287.135, Florida Statutes,the Owner may immediately terminate this Agreement at its sole option if the Contractor or any of its subcontractors are found to have submitted a false certification; or if the Contractor or any of its subcontractors, are placed on the Scrutinized Companies that Boycott Israel List or is engaged in the boycott of Israel during the term of this Agreement. 24.2 If this Agreement is for one million dollars or more,the contractor certifies that it and its subcontractors are also not on the Scrutinized Companies with Activities in Sudan List, Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged in Page 6 of 9 business operations in Cuba or Syria as identified in Section 287.135, Florida Statutes. Pursuant to Section 287.135,the Owner may immediately terminate this Agreement at its sole option if the Contractor, or any of its subcontractors are found to have submitted a false certification;or if the Contractor or any of its subcontractors are placed on the Scrutinized Companies with Activities in Sudan List, or Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or are or have been engaged with business operations in Cuba or Syria during the term of this Agreement. 24.3 The Contractor agrees to observe the above requirements for applicable subcontracts entered into for the performance of work under this Agreement. 24.4 The Contractor agrees that the certifications in this section shall be effective and relied upon by the OWNER for the term of this Agreement, including any and all renewals. 24.5 The Contractor agrees that if it or any of its subcontractors'status changes in regards to any certification herein,the Contractor shall immediately notify the Owner of the same. 24.6 As provided in Subsection 287.135(8), Florida Statutes, if federal law ceases to authorize the above-stated contracting prohibitions then they shall become inoperative. ARTICLE 25. EMPLOYMENT ELIGIBILITY 25.1 This Agreement is subject to and governed by the laws of the State of Florida, including without limitation Chapter 448, Florida Statutes,which provides for General Labor Regulations, and specifically Section 448.095, Employment Eligibility.The Contractor acknowledges its legal obligation to comply with §448.095, Florida Statutes. -- L Pursuant to Section 448.095, Florida Statutes, beginning January 1, 2021,Contractor shall register with and use the U.S. Department of Homeland Security's E-Verify system, https://e- verifv.uscis.gov/emp,to verify the work authorization status of all Contractor employees hired on and after January 1, 2021. ii. Subcontractors— a. Contractor shall also require all subcontractors performing work under this Agreement to use the E-Verify system for any employees they may hire during the term of this Agreement. b. Contractor shall obtain from all such subcontractors an affidavit stating the subcontractor does not employ, contract with, or subcontract with an unauthorized alien,as defined in section 448.095, Florida Statutes. c. Contractor shall provide a copy of all subcontractor affidavits to the Village upon receipt and shall maintain a copy for the duration of the Agreement. iii. Contractor must provide evidence of compliance with Section 448.095, Florida Statutes. Evidence shall consist of an affidavit from the CONTRACTOR stating all employees hired on and after January 1, 2021, have had their work authorization status verified through the E- Verify system and a copy of their proof of registration is in the E-Verify system. iv. Failure to comply with this provision is a material breach of the Agreement and shall result in the immediate termination of the Agreement without penalty to the Village. CONTRACTOR Page 7 of 9 shall be liable for all costs incurred by the Village to secure a replacement Agreement, including but not limited to, any increased costs for the same services, any costs due to delay, and rebidding costs, if applicable. r ARTICLE 26. OFFICE OF THE INSPECTOR GENERAL 26.1 Pursuant to Article XII of the Palm Beach County Charter, the Office of the Inspector General has jurisdiction to investigate municipal matters, review and audit municipal contracts and other transactions, and make reports and recommendations to municipal governing bodies based on such audits, reviews or investigations. All parties doing business with the Village shall fully cooperate with the inspector general in the exercise of the inspector general's functions,authority and power.The inspector general has the power to take sworn statements, require the production of records and to audit, monitor, investigate and inspect the activities of the Village, as well as contractors and lobbyists of the Village in order to detect, deter, prevent and eradicate fraud, waste, mismanagement, misconduct and abuses. ARTICLE 27. PUBLIC RECORDS 27.1 In accordance with Sec. 119.0701, Florida Statutes, Engineer must keep and maintain this Agreement and any other records associated therewith and that are associated with the performance of the work described herein and in Engineer's proposal. Upon request from Village's custodian of public records, Engineer must provide Village with copies of requested records, or allow such records to be inspected or copied, within a reasonable time in accordance with access and cost requirements of Chapter 119, Florida Statutes. Should Engineer fail to provide the public records to Village, or fail to make them available for inspection or copying, within a reasonable time, Engineer may be subject to attorney's fees and costs pursuant to Sec. 119.0701, Florida Statutes, and other penalties under Sec. 119.10, Florida Statutes. Further, Engineer shall ensure that any exempt or confidential records associated with this Agreement or associated with the performance of the work described herein and in Engineer's proposal are not disclosed except as authorized by law for the duration of the Agreement term, and following completion of the Agreement if Engineer does not transfer the records to the Village. Finally, upon completion of the Agreement, Engineer shall transfer, at no cost to the Village, all public records in possession of Engineer, or keep and maintain public records required by the Village. If Engineer transfers all public records to the Village upon completion of the Agreement, Engineer shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. Engineer shall be entitled to retain a copies of documents it creates for record purposes, pursuant to the requirements of this Article and Chapter 119, Florida Statutes. If Engineer keeps and maintains public records upon completion of the Agreement, Engineer shall meet all applicable requirements for retaining public records. Records that are stored electronically must be provided to Village, upon request from Village's custodian of public records, in a format that is compatible with Village's information technology systems. IF ENGINEER HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO ENGINEER'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, PLEASE CONTACT THE VILLAGE CLERK, RECORDS CUSTODIAN FOR THE VILLAGE, AT (561) 768-0685, OR AT Imcwilliams@tequesta.org OR AT 345 TEQUESTA DRIVE, TEQUESTA, FLORIDA 33469. Page 8 of 9 r ARTICLE 28. ENTIRETY OF AGREEMENT 28.1 The Village and Engineer agree that this Agreement, including Exhibit "A" "Fee Schedule" and Engineer's Proposal submitted in response to Village's RFQ, which is hereby incorporated into this Agreement;and all required insurance, licenses and approvals required by this Agreement sets forth the entire agreement between the parties, and that there are no promises or understandings other than those stated herein. None of the provisions, terms and conditions contained in this added to, modified, superseded or otherwise altered except by written instrument executed by the parties hereto. IN WITNESS WHEREOF, the parties hereto have signed two (2) copies of this Agreement. At least one counterpart each has been delivered to OWNER and CONTRACTOR. All portions of the Contract Documents have been signed or identified by OWNER and CONTRACTOR. OWNER CONTRACTOR Village of Tequesta Holtz Consulting Engineers, Inc. 345 Tequesta Drive 270 South Central Blvd, Suite 207 Tequesta, FL 33469 Jupiter, FL 33458 By Molly Young, or Stephen Fowle , ce President ,0 FT,,,,,,,,,, 1p o (VILLAGE SEAL) (CORPORATE SEAL) ATTEST e INCORPORATED:` ATTEST l oz1.2«� Lori McWilliams,Village Clerk P INT NAME AND POSITION Page 9 of 9 2025 HCE RATE SCHEDULE FOR THE VILLAGE OF TEQUESTA Principal Engineer - Acquires, plans, supervises, and coordinates professional $225 engineering projects by developing proposals and directing and controlling project _ elements. Requires Professional Engineer (PE) license and minimum 20 years' experience. _ Associate Engineer - Supervises engineering projects and project staff. Requires $215 Professional Engineer(PE) license and minimum 15 years'experience. Senior Project Manager - Completes engineering projects by organizing and $195 controlling project elements. Requires Professional Engineer (PE) license and minimum 10 years' experience. Project Manager - Completes engineering projects by organizing and controlling $185 project elements and overseeing project engineers. Requires Professional Engineer(PE) license and minimum 8 years' experience. Senior Project Engineer - Assists with project responsibilities by completing $175 project phases and elements as requested by Project Manager. Requires Professional Engineer(PE) license and minimum 5 years' experience. Project Engineer(PE) - Assists with project responsibilities by completing project $165 phases and elements as requested by Project Manager. Requires Professional _ Engineer(PE) license and minimum 4 years' experience or 3 years with a Masters Degree. Project Engineer (EI) - Assists with engineering projects by aiding in the $135 completion of project elements. Requires Engineer Intern (El) certificate. .. Construction Manager—Administers the construction contract and ensures the $180 project is constructed according to the technical and administrative contract documents. Minimum 8 years' experience required. Construction Inspector—Assists the Project Manager and Construction Manager $150 by performing project site inspections during construction to ensure the project is being constructed according to the technical plans and specifications. Senior Designer-CADD technician responsible for generating preliminary layouts, $150 creating and updating engineering drawings under the supervision of engineers, enforcing CADD standards,and supervising drafters. Minimum 5 years experience required. 1 Administrative Assistant-Provides office services by implementing administrative $90 systems, procedures, and policies, and monitoring administrative projects. - The above rates will be valid for 3 years from the contract date. - Revisions will be based on the Consumer Price Index (CPI) for the following year. - Subconsultants will be billed at cost plus 10%markup. - Postage, mileage, and reproduction costs are included in the hourly rates. �, 2 Opinion of Village Attorney This is to certify that I have examined the attached Agreement,that after such examination, I am of the opinion that such documents conform to the laws of the State of Florida,that the execution of the Agreement is in due and proper form,that the representative of the respective Contracting Parties have full power and authority to execute such Contract on behalf of the respective Contracting Parties and that —� the foregoing agreements constitute valid and binding obligations on such parties. ADavVis, Esqquire Attorney for Village of Tequesta This the day of 6VUa r 20 a 5 — Notice to Proceed (NTP) October 10, 2025 Stephen Fowler,Vice President Holtz Consulting Engineers, Inc. 270 South Central Blvd, Suite 207 Jupiter FL 33458 PROJECT:General Consulting Services Continuing Contracts Dear Mr. Fowler, One fully executed copy of your Agreement is enclosed. The commencement date is October 10, 2025. The following completion dates apply: Final Completion:October 10, 2028(3 calendar years duration from Notice to Proceed) -- Your attention is invited to the provision whereby you shall start to perform your obligations under this Agreement on the commencement date, which shall begin the Agreement time. Village of Tequesta Utilities will monitor the progress of the work and conformance with the Agreement. We look forward to working with you. Sincerely, VILLAGE OF TEQUESTA Marjorie Craig, PE Village of Tequesta `" Director, Utilities Department /'-Oqs HOLTCON-04 SNELSON ' . 6- O CERTIFICATE OF LIABILITY INSURANCE DATE D/YYYY)`� 91 512 0 2 5 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER NONTACT Suzanne Nelson Acrisure Southeast Partners Insurance Services, LLC PHONE FAX 1317 Citizens Blvd (A/C,No,Ext):(305)722-2663 (A/C,No): Leesburg, FL 34748 ADoRI .snelson acrisure.com INSURE S AFFORDING COVERAGE NAIC# INSURER A:Crum&Forster Specialty ' INSURED INSURERB:Auto-Owners insurance Company Company 8988 Holtz Consulting Engineers, Inc.270 S.Central Boulevard INSURER C:Travelers Casualty and Surety Company 19038 Suite 207 INSURERD: Jupiter,FL 33458 INSURERE: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: ' THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP ' TYPE OF INSURANCE POLICY NUMBER LIMITS A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 2,000,000 CLAIMS-MADE �X OCCUR EPK1'1078 5/15/2025 5/15/2027 DREMGETO RENTED $ 100,000 X General Aggregate ap 10,000 MED EXP An one person) $ ' PERSONAL&ADV INJURY $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIESPER: GENERAL AGGREGATE $ 4,000,000 POLICY JE LOC PRODUCTS-COMP/OP AGG $ 4,000,000 ' OTHER: $ B AUTOMOBILE LIABILITY COMBId.DSINGLE LIMIT nt) $ 1,000,000 X ANY AUTO 5339611700 6/9/2025 6/9/2026 BODILY INJURY Per n $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ ' HIRES NON WNEp PROPERTY AMAGE AUTOS ONLY AUTO ONLY Per accident $ PIP $ 10,000 A UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ _ 4,000,000 X EXCESS LIAB CLAIMS-MADE EFX130005 5/15/2025 5/15/2027 AGGREGATE $ 4,000,000 DED RETENTION$ C WORKERS COMPENSATION X PER TATUTE OTH- ER AND EMPLOYERS'LIABILITY YIN iUB9K5640 71 2 54 7G 5/15/2025 5115/2026 1,000,000 ANY PROPRIETOR/PARTNER/EXECUTIVE ❑ E.L.EACH ACCIDENT $ OFFICER/MEMBEREXCLUDED? NIA (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If es,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ A E&O EPK153078 5/15/2025 5/15/2027 Ea Wrongful Act 2,000,000 A Pollution EPK153078 5/15/2025 5/15/2027 Ea Polu Condition 2,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) The certificate holder is included as an additional insured for ongoing and completed operations for general liability per forms EN0111&EN0320 when required by written contract and a designated insured on the auto to the extent provided by form 58504 0115,General Liability&Auto are primary and non-contributory when required by written contract.Waiver of subrogation applies to general liability,auto and workers compensation when required by written contract.Excess Liability extends over General Liability,Employers Liability and Pollution Liability. Cancellation per policy terms and conditions. ' CERTIFICATE HOLDER CANCELLATION ' SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Village of Tequesta THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 9 q ACCORDANCE WITH THE POLICY PROVISIONS. 345 Tequesta Drive Tequesta,FL 33469 AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD