Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Agreement_General_06/16/2013
ARCADIS ARCADIS U.S., Inc. Infrastructure - Water • Environment Buildings 2081 Vista Parkway Enclosed are three copies of Change Order No. 1 for the referenced project. West Palm Beach This change order covers `time' only. The additional time has been requested due to Florida 33411 a manufacturing delay in the tanks that delayed installation. We have recommended Tel 561 697 7000 Village of Tequesta Fax 561 697 7751 www.arcadis-us.com 345 Tequesta Drive Phone: Tequesta, FL 33469 561-697-7069 Attn: Michael Couzzo, Village Manager WATER RESOURCES Subject: WTP NaOCI Storage Tank Replacement Dear Mr. Couzzo: Date: April 17, 2014 Enclosed are three copies of Change Order No. 1 for the referenced project. This change order covers `time' only. The additional time has been requested due to Contact: a manufacturing delay in the tanks that delayed installation. We have recommended William D. Reese, P.E. approval on the basis of this being beyond the control of the Contractor. If Phone: acceptable, please execute and return two copies. One is for your records. We will 561-697-7069 forward one to the Contractor. Email: For your general information, this project is essentially complete at this time william.reese@arcadis-us.com with only final closeout paperwork items remaining. Our ref: W F900188.0000 Should you have any questions or require anything further, please call. Florida License Numbers Very truly yours, Engineering EB00007917 ARCADIS U.S., Inc. Geology GB564 Surveying William D. Reese, P.E. LB7062 Vice President encls. Imagine the result tV g:\aprojects\wr\wf projects\900188-vot naocl tank replcemnt\docs\couzzo 04172014.doc CHANGE ORDER PROJECT: WTP NaOCI Storage Tank Replacement DATE OF ISSUANCE: April 8, 2014 OWNER: Village of Tequesta No. EFFECTIVE DATE: Upon Execution by Last Party OWNER's Contract No. CONTRACTOR:TLC Diversified, Inc. ENGINEER: ARCADIS-US, Inc. You are directed to make the following changes in the Contract Documents. Description: Time Extension Reason for Change Order: Refer to Contractor's Request Attachments: Contractor's Letter Dated 4/3/14 and Updated Schedule CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIMES: Original Contract Price Original Contract Times Substantial Completion: 120 days (1/1/14) $177,600 Ready for final payment 135 days (1/16/14) Net changes from previous Change Orders No. =to No. Net change from previous Change Orders No. =to No.= -0- -0- days Contract Price prior to this Change Order Contract Times prior to this Change Order Substantial Completion: 120 days (1/1/14) $—1 77,600 Ready for final payment: 135 days (1/16/14) Vet (increase) of this Change Order Net Increase of this Change Order 6 -0- 83 days to Substantial Completion 88 days to Final Completion �ontract Price with all approved Change Orders Contract Times with all approved Change Orders Substantial Completion: 203 days (3/25/14) 6 177,600 Ready for final payment: 223 days (4/14/14) RECOMMENDED: ARCADIS-U c. By: Date : `1 io I L4, APPROVED: d - APPROVED: Village of Tequesta By: 1—�1 Date: 4 L 3 • ACCEPTED: TLC Diversified, Inc. BY ' 1a (weim, Date: 411411 i 4/314 William D. Reese, P.E. ARCADIS 2081 Vista Parkway West Palm Beach, FL 33411 Phone: 561-697-7000 Re: Tequesta WTP NaOCI Storage Tanks Request for Contract Time Extension TLC Project No. 131801 Dear Mr. Reese: In respond to ARCADIS letter dated 3/3/14, TLC would like to formally request a time extension in our contract as follows: • 83 calendar days (substantial completion) from original contract specified date of 1/1/14. • 20 calendar days (to final completion) from actual substantial completion date reached by March 25, 2014. New final completion date: April 14, 2014. • 103 calendar days total request for time extension in our contract. This is as result of construction delay incurred with ASME RPT -1 tank equipment fabrication process with Manufacturer Plas-Tanks. Original lead time offered by selected and approved Tank vendor and Manufacturer was significantly less than actual time taken for final delivery of equipment to TLC. Unfortunately this issue forced us to pass our contract substantial and final completion time. As you may recall lead time offered by Diamond Fiber Glass Tanks manufacturer at bid time was 24 weeks (6 months) for fabrication process while Plas-tanks offered 10-12 weeks and that is the reason why TLC requested your office to allow us using this Manufacturer at beginning of the project for the interest to meet contractual time. Even using Plas-Tanks Manufacturer with their 10-12 weeks lead time for fabrication process of this equipment and excluding submittal procurement and estimated installation period of two weeks as originally planned, this job could not have been completed to meet original contractual substantial completion time as specified by 1/1/14. Request for additional time extension was not previously submitted to ARCADIS since this Contractor tried to push hard and force vendor/equipment manufacturer to maintain original commitment but it was very difficult to obtain an agreement due to manufacturers backlog with other orders and issues with end of the year holidays. Christmas and New Year were in the middle of this process and neither helped us with progress to reach contract target dates. TLC made all possible efforts to expedite procurement of contract documents, submittals, permitting and final release of equipment and material orders to perform contract scope of work under the specified contract time. Attached please find an updated schedule based on time used during the process of this contract and reflecting current status of completed scope. Please review critical path associated with time line for this project so you can note the significant impact on schedule due to tank equipment fabrication and delivery of tank equipment. TLC respectfully requests ARCADIS and Village of Tequesta your understanding on this regard. Should you have any additional questions or comments please do not hesitate to contact me at earliest convenience. SincerelA �Juli Pr lect Manager Cc: 131801 -ITC Pile TLC Diversified, Inc Hone Office 2719 17i1 St. Fast Palmetto. FL 34221 Tel. 941.722.0621 Fax 941.722.1382 Fns/ Q.1 Office 7233 Southem Blvd., Suite B-1 W"t Palm Beach, FL 33413 Tel. 561.478.2025 Fax 561.478.7159 CG 0041816 www.ticclivenified.com 3 D D D D D➢ j D D D D D D D D D D> D D D D r D D➢ j CO o N n �i'o `'`d'i'oN Sno...°o'Soob'vi < O ti B o030 o oo Dov D o n m a d H 3 3 n O D to W to c C C M r r n z T z oc m N o $$(+ $g[ Q - 3 4 ;it r10 O 1 Il f& 4: m x 0 7S a N Baa-��-'3"- _-�R���_���Rao o" m oz Z s p N m -m -� a 1 O - g v r N p m A d � Q 7 7 a O H � � A 7 F O+ N N ++ + +++ ++ Yn w o O o O Vt o O P P P P m o o T T a n o m m jN w T T T r �+ r Z z r Z o G O 0 0 0 Doo O er d a • 6i d O a 3• ......... ............--.........:_........... ....... ...... 6 r ---------, .� @ ir St Er a CHANGE ORDER No. 1 PROJECT: WTP NaOCI Storage Tank Replacement DATE OF ISSUANCE: April 8, 2014 EFFECTIVE DATE: Upon Execution by Last Party OWNER: Village of Tequesta OWNER's Contract No. CONTRACTOR:TLC Diversified, Inc. ENGINEER: ARCADIS-US, Inc. You are directed to make the following changes in the Contract Documents. Description: Time Extension Reason for Change Order: Refer to Contractor's Request Attachments: Contractor's Letter Dated 4/3/14 and Updated Schedule CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIMES: Original Contract Price Original Contract Times $177,600 Substantial Completion: 120 days (1/1/14) Ready for final payment 135 days (1/16/14) Net changes from previous Change Orders No. =to No. - Net change from previous Change Orders No. =to No.= $ -0- -0- days Contract Price prior to this Change Order Contract Times prior to this Change Order Substantial Completion: 120 days (1/1/14) 3177,600 Ready for final payment: 135 days (1/16/14) Vet (increase) of this Change Order Net Increase of this Change Order 83 days to Substantial Completion -0- 88 days to Final Completion �ontract Price with all approved Change Orders Contract Times with all approved Change Orders 6 177.600 Substantial Completion: 203 days (3/25/14)_ Ready for final payment: 223 days (4/14/14) RECOMMENDED: APPROVED: ACCEPTED: ARCADIS-US, Inc. Village of Tequesta TLC Diversified, In . By: By: v O rt .ate I � Date : �� l�wJ—� �(r, Date: 41 Date:_ 4I 4/314 William D. Reese, P.E. ARCADIS 2081 Vista Parkway West Palm Beach, FL 33411 Phone: 561-697-7000 Re: Tequesta WTP NaOCI Storage Tanks Request for Contract Time Extension Dear Mr. Reese: TLC Project No. 131801 K�c oiveas In respond to ARCADIS letter dated 3/3/14, TLC would like to formally request a time extension in our contract as follows: • 83 calendar days (substantial completion)_ from original contract specified date of 1/1/14. • 20 calendar days (to final completion) from actual substantial completion date reached by March 25, 2014. New final completion date: April 14, 2014. • 103 calendar days total request for time extension in our contract. This is as result of construction delay incurred with ASME RFT -1 tank equipment fabrication process with Manufacturer Plas-Tanks. Original lead time offered by selected and approved Tank vendor and Manufacturer was significantly less than actual time taken for final delivery of equipment to TLC. Unfortunately this issue forced us to pass our contract substantial and final completion time. As you may recall lead time offered by Diamond Fiber Glass Tanks manufacturer at bid time was 24 weeks (6 months) for fabrication process while Plas-tanks offered 10-12 weeks and that is the reason why TLC requested your office to allow us using this Manufacturer at begimung of the project for the interest to meet contractual time. Even using Plas-Tanks Manufacturer with their 10-12 weeks lead time for fabrication process of this equipment and excluding submittal procurement and estimated installation period of two weeks as originally planned, this job could not have been completed to meet original contractual substantial completion time as specified by 1/1/ 14. Request for additional time extension was not previously submitted to ARCADIS since this Contractor tried to push hard and force vendor/equipment manufacturer to maintain original commitment but it was very difficult to obtain an agreement due to manufacturer's backlog with other orders and issues with end of the year holidays. Christmas and New Year were in the middle of this process and neither helped us with progress to reach contract target dates. TLC made all possible efforts to expedite procurement of contract documents, submittals, permitting and final release of equipment and material orders to perform contract scope of work under the specified contract time. Attached please find an updated schedule based on time used during the process of this contract and reflecting current status of completed scope. Please review critical path associated with time line for this project so you can note the significant impact on schedule due to tank equipment fabrication and delivery of tank equipment. TLC respectfully requests ARCADIS and Village of Tequesta your understanding on this regard. Should you have any additional questions or comments please do not hesitate to contact me at earliest convenience. Sincerely, Juli etta Pr lect Manager Cc: 131801-11C File TLC Diversified, Inc Hary Office 2719 17i1 St. East Palmetto, FL 34221 Tel. 941.722.0621 Fax 941.722.1382 Erin Coad Office 7233 Southem Blvd., Suite B-1 Nest Palm Beach, FL 33413 Tel. 561.478.2025 Fax 561.478.7159 CG C041816 Nww.tlediversified.com j �D�+ D D D> 3 d o o -y b"o'`b'n �0000 oSZi 'o S"d 'oo�(�'y oomop'o3a� S, 2.4 'o y � D — a o 3 n N D C o D o n fp Ani �aN �oo.�o n Cnsz6lns �zvn �. Q. „ 3 3 fq 3 B. N G z SL N H p A F wwA a m. 14 N 7i 3 $ o d � � n A 3 CD E 0 0 8 ti, — —— BEo 6 d S o N'o o o' > Y e& 8 e o 0 aTg4g�=4 dT r r i z a o Z � S B. N ._ ... ..... .. ................ j .. 'w a, m D � .............. .. .. ... . 'o ............ .: ....... ... .. - ... .._. _.............. ........... AB. �. q • t �p. s ..--- - ---...._...................................... -_. D I gi � 3 m 6 - D ................ j .. 'w a, m D � .............. .. .. ... . 'o QQ ... .._. _.............. ........... AB. �. q • t s ..--- - ---...._...................................... -_. $} I gi � m ................ j .. :i . 'o QQ ... .._. _.............. ........... AB. �. q � m CHANGE ORDER PROJECT: WTP NaOCI Storage Tank Replacement DATE OF ISSUANCE: April 8, 2014 OWNER: Village of Tequesta OWNER's Contract No. No. EFFECTIVE DATE: Upon Execution by Last Party CONTRACTOR:TLC Diversified, Inc. ENGINEER: ARCADIS-US, Inc. You are directed to make the following changes in the Contract Documents. Description: Time Extension Reason for Change Order: Refer to Contractor's Request Attachments: Contractor's Letter Dated 4/3/14 and Updated Schedule CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIMES: Original Contract Price Original Contract Times $177,600 Substantial Completion: 120 days (1/1/14) Ready for final payment 135 days (1/16/14) Net changes from previous Change Orders No. =to No. - Net change from previous Change Orders No. =to No.= $ -0- -0- days Contract Price prior to this Change Order Contract Times prior to this Change Order Substantial Completion: 120 days (1/1/14) 9 177,600 Ready for final payment: 135 days (1/16/14) Net (increase) of this Change Order Net Increase of this Change Order -0 83 days to Substantial Completion 88 days to Final Completion :�ontract Price with all approved Change Orders Contract Times with all approved Change Orders 6 177,600 Substantial Completion: 203 days (3/25/14) Ready for final payment: 223 days (4/14/14) RECOMMENDED: ARCADIS-US, Inc. By: Date APPROVED: Village of Tequesta ACCEPTED: TLC Diversified, Inc. By: : io d4 Date: � Date: 4/314 William D. Reese, P.E. ARCADIS 2081 Vista Parkway West Palm Beach, FL 33411 Phone: 561-697-7000 Re. Tequesta WTP NaOCI Storage Tanks Request for Contract Time Extension Dear Mr. Reese: TLC Project No. 131801 Emironineatal Construction Profirsionals Seraing the f I fitter 1lrasteuw&r LrdushT In respond to ARCADIS letter dated 3/3/14, TLC would like to formally request a time extension in our contract as follows: • 83 calendar days (substantial comvletion) from original contract specified date of 1/1/14. • 20 calendar days (to final completion) from actual substantial completion date reached by March 25, 2014. New final completion date: April 14, 2014. 103 calendar days total request for time extension in our contract. This is as result of construction delay incurred with ASME RPT -1 tank equipment fabrication process with Manufacturer Plas-Tanks. Original lead time offered by selected and approved Tank vendor and Manufacturer was significantly less than actual time taken for final delivery of equipment to TLC. Unfortunately this issue forced us to pass our contract substantial and final completion time. As you may recall lead time offered by Diamond Fiber Glass Tanks manufacturer at bid time was 24 weeks (6 months) for fabrication process while Plas-tanks offered 10-12 weeks and that is the reason why TLC requested your office to allow us using this Manufacturer at beginning of the project for the interest to meet contractual time. Even using Plas-Tanks Manufacturer with their 10-12 weeks lead time for fabrication process of this equipment and excluding submittal procurement and estimated installation period of two weeks as originally planned, this job could not have been completed to meet original contractual substantial completion time as specified by 1/1/14. Request for additional time extension was not previously submitted to ARCADIS since this Contractor tried to push hard and force vendor/equipment manufacturer to maintain original commitment but it was very difficult to obtain an agreement due to manufacturers backlog with other orders and issues with end of the year holidays. Christmas and New Year were in the middle of this process and neither helped us with progress to reach contract target dates. TLC made all possible efforts to expedite procurement of contract documents, submittals, permitting and final release of equipment and material orders to perform contract scope of work under the specified contract time. Attached please find an updated schedule based on time used during the process of this contract and reflecting current status of completed scope. Please review critical path associated with time line for this project so you can note the significant impact on schedule due to tank equipment fabrication and delivery of tank equipment. TLC respectfully requests ARCADIS and Village of Tequesta your understanding on this regard. Should you have any additional questions or comments please do not hesitate to contact me at earliest convenience. Sincerely, T Jule Ba Pr lect Manager Cc 131801 -PLC File TLC Diversified, Inc H— Office 2719 17-1 St. Fast Palmetto, FL 34221 Tel. 941.722.0621 Fax 941.722.1382 Earl C—i Office 7233 Southern Blvd., Suite B -I \fest Palm Beach, FL 33413 Tel. 561.478.2025 Fax 561.478.7159 CG C041816 twvw.tlediversi6ed.com k x iqiui � $ L r"A91 & n o N N i N N j 0 0 s� �a .. _..... ........ .-.-._ _ .. .... .. ..... ............. -.. _ ..................i................-_--- ......... 4 " ---..__................---__;....... i 3 0 m _ V - FVj: a m 3'N $ 'D y gm y�5: y :...... �...q S ..... . .. ;....... 3: ..................i................-_--- ......... m _ V - FVj: m 3'N $ � AR AD 1 C � ARCADIS U S,Inc. ��r �-�;;;r��Water�Environment Buildings 208�vista Parkway West Palm Beach Florida 33411 Tel 561 697 7000 Village of Tequesta Fax 561 697 7751 www.arcadis-us.com 345 Tequesta Drive Tequesta, FL 33469 Attn: Michael Couzzo, Village Manager WATER RESOURCES Subject: WTP NaOCI Storage Tank Replacement Dear Mr. Couzzo: �ate: April 10, 2014 Enclosed are three original certificates of substantial completion for the referenced project. Please execute and return two of them. The third one is for your Contact: records. William D. Reese, P.E. Phone: Should you have any questions or require anything further, please call. 561-697-7069 Very truly yours, Email: william.reese@arcadis-us.com ARCADIS U.S., Inc. --- Our ref: !i ` _ - ��_- W F900188.0000 William D. �2eese, P.E. Florida License Numbers Vice President Engineering E600007917 encls. Geology G6564 Surveying LB7062 �l 0� �- . - Imagine the result g:\aprojects\wr\wf projects\900188-vot naocl tank replcemnfldocs\couzzo 04162014.doc �,�\ CERTIFICATE OF SUBSTANTIAL COMPLETION PROJECT: Tequesta WTP NaOCI Storage Tank DATE OF ISSUANCE: Apri14,2014 OWNER: Village of Tequesta OWNER's Contract No.: n/a CONTRACTOR: TLC Diversified,Inc. ENGINEER: ARCADIS-US,Inc. This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: All parts. To: TLC Diversified,Inc. And To: Village of Tequesta The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR and ENGINEER,and that Work is hereby declared to be substantially complete in accordance with the Contract Documents on March 25,2014 DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected will be provided subsequent to inspection.This list may not be all- inclusive,and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. EJCDC No. 1910-8-D(1990 Edition) Prepared by the Engineers Joint Contract Documents Committee and endorsed by The Associated Genera]Contractors of America. From the date of Substantial Completion, the responsibilities between OWNER and CONTRACTOR for security, operation,safery,maintenance,heat,utilities,insurance and warranties and guarantees shall be as follows: L � RESPONSIBILITIES: OWNER: All per contract. CONTRACTOR: All per contract. The following documents are attached to and made a part of this Certificate: Contractor's request for Substantial Completion. This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR's obligation to complete the Work in accordance with the Contract Documents. Executed by ENGINEER on iQ Prcrc, /� ,2014 ARCADIS-US,Inc. $y; � ���al-v William D�.�eese,P.E. •(7� CONTRACTOR accepts this Certificate of Substantial Completion ���� � � ,2014, TLC Diversified,Inc. '��. By: vL�o Ca���t •C�,�,T�c>�t��E��� � � OWNER accepts this Certificate of Substantial Completion on ,2014 Village of Tequesta By: � _. - �-� �--- - --- ARCADIS ARCADIS U.S., Inc. Infrastructure Water Environment Buildings 2081 Vista Parkway West Palm Beach Florida 33411 Tel 561 697 7000 Fax 561 697 7751 Village of Tequesta www.arcadis- us.com 345 Tequesta Drive Tequesta, FL 33469 Attn: Michael Couzzo, Village Manager Subject: WTP — NaOCI Storage Tank Replacement WATER RESOURCES Dear Mr. Couzzo: Enclosed are three original contract sets for the referenced project. Please Date: execute and return two sets. The other one is for your use /records. We will distribute July 1, 2013 a fully executed set to the Contractor and issue a notice to proceed. Please also date the contracts (two locations as marked) at the time they are executed. contact: William D. Reese, P.E. Should you have any questions or wish to discuss further, please call. Phone: 561 - 697 -7069 Very truly yours, Email: ARCADIS U.S., Inc. william.reese @arcadis- us.com Our ref: W F900188.0000 William D. Reese, P.E. Vice President Florida License Numbers Engineering encl. EB00007917 Geology GB564 Surveying LB7062 Imagine the result g:\aprojects \wr \wf projects \900188 -vot naod tank replcemnt \docs \couzzo hypochlorite tank 07012013.doc 1 i 1 1 PROJECT MANUAL FOR VILLAGE OF TEQUESTA WATER TREATMENT PLANT NaOCI Storage Tank Replacement MARCH, 2013 ARCADIS US 2081 Vista Parkway West Palm Beach, FL 33411 Ph. 561- 697 -7000 Fax 561- 697 -7751 TABLE OF CONTENTS INVITATION TO BID INV -1 only INSTRUCTIONS TO BIDDERS IB -1 thru IB -8 i SPECIAL REQUIREMENTS SR -1 only BID B -1 thru B -4 plus attachments CONSTRUCTION AGREEMENT 1 thru 5 PERFORMANCE BOND, PAYMENT BOND 4 pages GENERAL CONDITIONS 1 thru 42 SUPPLEMENTARY CONDITIONS TO THE GENERAL CONDITIONS SGC -1 thru SGC -11 OWNER DIRECT SPECIAL CONDITIONS SC -1 thru SC -8 TECHNICAL SPECIFICATIONS 1 DIVISION 1 - GENERAL REQUIREMENTS Section 01019 General Requirements 01019 -1 thru 01019 -5 Section 01150 Measurement & Payment 01150 -1 only Section 01300 Submittals 01300 -1 thru 01300 -2 Section 01400 General Quality Control 01400 -1 thru 01400 -2 Section 01720 Record Drawings 01720 -1 only DIVISION 2 - SITE WORK Section 02050 Demolition 02050 -1 thru 02050 -3 i Section 02610 Pipe and Fittings 02610 -1 thru 02610 -4 DIVISION 6 — WOOD AND PLASTICS Section 06610 Fiberglass Storage Tanks 06610 -1 thru 06610 -5 DIVISION 9 - FINISHES Section 09800 ' Coatings 09800 -1 thru 09800 -7 DIVISION 15 - MECHANICAL Section 15100 , Mechanical Equipment General 15100 -1 thru 15100 -2 1 1 t t 1 1 1 1 INVITATION TO BID VILLAGE OF TEQUESTA WATER TREATMENT PLANT NaOCI STORAGE TANK REPLACEMENT Sealed bids will be received at the office of the Engineer (ARCADIS US, Inc.) 2081 Vista Parkway, Suite 200, West Palm Beach, FL 33411 until 2:30 P.M. on April 18, 2013, at which time and place they will be publicly opened and read aloud. Receipt of a bid in any other office does not satisfy this requirement. The work for which this bid is to be submitted includes the replacement of two (2) sodium hypochlorite storage tanks. All work performed shall be in accordance with the Contract Documents pertaining thereto, which may be examined at the office of ARCADIS US, Inc., 2081 Vista Parkway, West Palm Beach, Florida 33411. One copy of the contract documents including blank bid forms may be obtained at the office of ARCADIS US, Inc. upon payment of $75.00, which will not be refunded. A certified or cashier's check on a national or state bank or a bid bond in a sum not less than five percent (5 %) of the amount of the base lump sum bid amount, made payable to the Village of Tequesta, Florida, shall accompany each bid as a guarantee that the bidder will not withdraw from the competition after the opening of bids. In the event that the contract is awarded to the bidder, he will enter into the contract and furnish and pay for the required performance and payment bonds. Failure to do so may result in the Owner retaining the bid deposit for liquidated damages. Bids shall be prepared, addressed and submitted in compliance with detailed instructions as set forth in the Instructions to Bidders. The performance and payment bonds in the full amount of the Contract price shall be written by a surety company, acceptable to the Owner, licensed to do business in the State of Florida listed in the Department of Treasury Federal Register. All bonds (bid, performance, payment) shall be countersigned by a Florida resident agent and otherwise satisfy the requirements of Paragraph 5.01 of the General Conditions. Surety shall have a rating of "A +" or "A" by Best's Rating Guide The Owner reserves the right to reject any or all bids with or without cause, to waive technical errors and informalities, or to accept the bid which in his judgment best serves the Owner. Owner: Village of Tequesta Publish on: March 24, 2013 March 31, 2013 INV -1 WF900188 INSTRUCTIONS TO BIDDERS 1.01 SEALED BIDS: Sealed bid will be received at the time and place designated and then publicly opened and read aloud for furnishing all transportation, labor, materials, tools, supplies, plant equipment and machinery necessary, and performing all operations required for the completion of the Work specified and as shown on the drawings. The bid date and time shall be scrupulously observed. Under no circumstances shall bids received after the date and time specified be considered. Such bids will be returned to the bidder unopened. 1.02 DELIVERY OF BIDS: All bids, whether mailed or delivered in person, shall be submitted in sealed envelopes bearing on the outside the words "BID ENCLOSED" and, the name of the bidder and his address and clearly marked: "Bid for the Village of Tequesta Water Treatment Plant NaOCI Storage Tank Replacement" and addressed to: ARCADIS 2081 Vista Parkway Suite 200 West Palm Beach, FL 33411 1.03 BID FORMS: Submit bid in triplicate on the forms, or an exact copy of the forms, furnished herewith. The blank spaces shall be filled in correctly for each item and every item for which a bid is tendered. State the price, typewritten or written in black ink and insert numerals for which he proposes to do each item of the Work; in case of conflict, words will take precedence. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. Failure to complete all indicated blanks in the designated manner may result in the bid being declared non - responsive. Declaration of the non - responsiveness of a bidder shall be at the sole discretion of the Owner. I 1.04 SIGNATURE ON BID: Sign bid correctly. If the bid is made by an individual, his name and post office address shall be shown. If made by a firm or partnership, the name and post office address of each member of the firm or partnership shall be shown. If made by a corporation, the person signing the bid shall show the name of the state under the laws of which the corporation was chartered, also the names and business addresses of its President, Secretary, and Treasurer. The proposal shall bear the seal of the corporation attested by the Secretary. Anyone signing the bid as agent shall file with the bid, legal evidence of his authority to do so. Signing and submitting a bid for this work will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of these Documents, that without exception the Bid is premised upon performing and furnishing the Work required by the Contact Documents and that such means, methods, techniques, sequences, procedures of construction and all other information as may be indicated in or required by the Contract Documents are sufficient in scope and detail to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. 1 1.05 FAMILIARITY WITH LAWS: The bidder is assumed to be familiar with all federal, state and local laws, ordinances, rules and regulations that may in any manner affect the Work. The failure to be familiar with applicable laws will in no way relieve him from responsibility. 1.06 EXAMINATION OF SITE AND CONTRACT DOCUMENTS: The bidder is required, before submitting their proposal, to visit the site of the proposed Work and familiarize themselves with the nature and extent of the Work and any local conditions including, but not limited to, surface and sub - surface conditions, that may in any manner affect the cost, progress or performance of the Work to be done, including the equipment, materials and labor required. Upon receipt by the 113-1 W F900188 Engineer of request in advance, Owner will provide each bidder access to the site to conduct such explorations and tests as each bidder deems necessary for submission of a Bid. Bidder shall fill all holes, clean up, and otherwise restore the site to its former condition upon completion of such explorations. The Bidder is required to examine carefully the Contract Documents and form of performance and payment bonds and to be informed thoroughly regarding any and all conditions and requirements that may in any manner affect the Work to be performed under this contract. Failure on the part of the bidder to fully understand the existing site conditions, or contract documents, shall not relieve him of the obligations and responsibilities of the Agreement, and will not be cause for additional compensation or , extension of time. 1.07 CONFIDENTIAL FINANCIAL STATEMENT: If requested by the Owner, a bidder under consideration for award shall furnish a confidential certified financial statement, current within the past year, which must be a complete report of the financial resources and liabilities, equipment available, past performance record, personnel and organization experience. At the Owner's discretion a different time period for the confidential financial statement may be requested. 1.08 QUALIFICATION OF BIDDER: The contract will be awarded only to a responsible contractor qualified by experience to do the Work specified. The bidder shall submit, prior to award of contract, satisfactory evidence of his experience in like Work and that he is fully prepared with the necessary organization, capital, equipment and machinery to complete the Work to the satisfaction of the Owner within the time limit stated. In addition to the above, the Contractor shall satisfy the following criteria: 1. Have been in the General Contracting business under the present name of the organization for a minimum of the previous ten (10) years. 2. Be properly licensed to perform work as a General Contractor in the State of Florida, Palm Beach County and the Village of Tequesta. 3. Have been awarded and performed as a General Contractor on a minimum of five (5) similar projects during the past ten (10) years. For purposes of this discussion, a "similar" project shall be considered to include installation or construction of water or wastewater treatment equipment and mechanical piping systems. "Similar" projects shall have a minimum value of $100,000. 4. During the lifetime of the organization, as presently named, the Contractor shall not have defaulted to a bonding company for the completion of all or any projects referenced under item 3, above. Failure to satisfy any of the above criteria shall be grounds for rejection of the bid, at the Owner's discretion. At the Owner's sole discretion, portions, or all, of the above criteria may be waived. However, bidders are advised that it is the general intent of the Owner to adhere to the stipulated criteria. The Owner will consider all known qualifications of the Contractor in awarding the bid. At their discretion, the Owner may elect to consider the percentage of work the Bidder proposes to perform with personnel in their direct employ as opposed to subcontractor. More weight and value will be generally given to Contractor performing work with their own personnel. Bidders are advised that the Owner reserves the sole right to award the project to the bidder which, in the Owner's sole opinion, best serves the interest of the Owner. By submitting a bid, the Contractor and Owner acknowledge that this evaluation process is to some degree subjective. The Contractor further acknowledges that the Owner may apply substantial weight to qualifications and the anticipated ability to perform in a timely fashion in the selection process. IB -2 WF900188 1.09 SUBCONTRACTORS: For the Owner to be assured that only competent and qualified subcontractors will be employed on this project, each Bidder shall submit in the bid (or show on the bid form) a list of the subcontractors performing work on this project. This subcontractors list shall include each firm's name, address, telephone number, contact person and work to be performed. Subcontractors shall be properly registered or licensed with the State of Florida, Palm Beach County and the Village of Tequesta. Subcontractors shall, in the Owner's opinion, be qualified both technically and financially to perform the work. The Owner reserves the right to reject any subcontractor who is deemed by the Owner to be unacceptable technically or financially, or has previously performed work which the Owner believes to be unsatisfactory. No change may be made to this list of subcontractors by the Contractor, before or after contract award, without the express written consent of the Owner. If, prior to award, the Owner rejects any subcontractor, the Contractor shall be afforded the opportunity to submit qualifications for an alternate subcontractor with no attendant increase in the base lump sum bid amount, adjustment of contract time or alteration of the bid documents. Such qualifications will be due within ten (10) days of receipt of notification of subcontractor rejection. Failure to submit an acceptable alternate subcontractor may result in rejection of the bid. In this event, the bid bond shall be returned to Contractor without claim by the Owner and with forfeiture of all claim rights by the Contractor. 1.10 DISQUALIFICATION OF BIDDER: The submittal of more than one bid from an individual, firm, partnership, corporation or association under the same or different names will not be considered and will be cause for rejection of all bids submitted by a bidder. 1.11 AWARD OF CONTRACT: The award of the contract, if it is awarded, will be to the lowest and most responsible bidder. Award will be to the bidder deemed to be the best interest of the Owner and whose bid shall comply with the requirements of the Contract Documents. Also, the Owner reserves the right to reject the Bid of any bidder if the Owner believes that it would not be in the best interest of the Owner to make and award to the bidder. The determination of lowest responsible bidder will be based on the base lump sum bid amount. In evaluating bids, the Owner will consider whether or not the bids comply with the prescribed requirements. Time is of the essence for this project and the perceived ability of the bidder to complete the project within the prescribed time frame will be accorded weight by the Owner in the determination of the best bid. The Owner may consider the qualifications and experience of subcontractors, suppliers and other persons and organizations proposed for those portions of the Work. The Owner also may consider operating costs, maintenance requirements, performance data, and guarantees of major items of materials and equipment proposed for incorporation in the Work. The Owner may conduct such investigations as the Owner deems necessary to assist in the evaluation of any bid and to establish responsibility, qualifications and financial ability of bidders, proposed subcontractors, suppliers, and other persons and organizations to perform and furnish the Work in accordance with the Contract Documents to the Owner's satisfaction. In no case will the award be made until all necessary investigations have been made into the responsibility of the low bidders and subcontractors and the Owner is satisfied that the bidders and subcontractors are qualified to do the Work and have the necessary organization, capital, experience and equipment to carry out the provisions of the contract to the satisfaction of the Owner within the time specified. The Owner reserves the right, at the Owner's discretion, to reject any or all bids with or without cause, to waive technical errors and informalities, to negotiate contract terms with the successful bidder, to disregard all non - conforming, non - responsive, unbalanced or conditional bids and to accept the bid which in his judgment best serves the Owner. 1.12 RETURN OF BID GUARANTY: As soon as the bids have been compared, the Owner may, at his discretion, return the guaranty deposit accompanying such bids as in his judgment I13-3 WF900188 would not likely be considered in making the award. All other b id g uaranties will be held until the contract and bonds have been executed, after which they will be returned to the respective bidders whose bids they accompany. 1.13 FAILURE TO EXECUTE THE CONTRACT: Failure on the part of the successful bidder to execute the contract as required will be just cause for the amount of guaranty deposited with the bid, either in the form of a certified or cashier's check or a bid bond, to be retained or be paid upon demand by the Owner, not as a forfeiture, but rather will be for liquidated damages, it being agreed to by each bidder in advance that the Owner will sustain certain damages by reason of the failure of the bidder to sign the contract and that such damages equal the amount of the bid security, or exceed the same, and in no event shall the bidder thereafter be permitted to contest to the contrary and does waive such right upon submitting a bid. 1.14 INTERPRETATIONS AND CLARIFICATIONS OF THE CONTRACT DOCUMENTS: All questions about the meaning or intent of the Contract Documents shall be submitted to Engineer in writing. Replies will be issued by Addenda if the reply alters the documents to all parties recorded by the Engineer as having received the Bidding Documents. Questions received less than ten days prior to the date for opening of Bids will not be answered. Only questions answered by formal written Addenda will be binding. Receipt of all addenda must be acknowledged in the space provided on the bid form. Oral and other interpretations or clarifications will be without legal effect. 1.15 TIME OF AWARD AND AGREEMENT EXECUTION: The Owner reserves the right to hold all proposals and bid guaranties for a period not to exceed sixty (60) days after the date of bid opening stated in the Invitation to Bid. If project is to be awarded, the Owner will issue a Notice of Award within 60 days of the bid date, unless said time is extended at the request of the Owner and with the concurrence of the bidder. The Owner shall, in a timely manner subsequent to the issuance of the Notice of Award prepare and deliver to the bidder a suitable number of unsigned Agreements and other Contract Documents. Within 15 days thereafter, the Contractor shall execute and deliver all provided copies of the Agreement and Contract Documents to Owner or Engineer with the required Bonds and other relevant items. 1.16 BID MODIFICATIONS AND WITHDRAWAL: Modifications or bid withdrawal requests will be received from bidders prior to opening of first bid. Modifications or bid withdrawal requests may be telegraphic or in other written or printed form, but shall be sealed and dated with time stamp before delivery to the Owner. If, within twenty -four hours after bids are opened, any bidder files a duly signed, written notice with Owner and promptly thereafter demonstrates to the reasonable satisfaction of Owner that there was a material and substantial mistake in the preparation of its bid, that bidder may withdraw its bid and the bid security will be returned. Thereafter, that bidder will be disqualified from further bidding on the Work to be provided under the Contract Documents. 1.17 MANUFACTURERS: The Contractor shall use only the named manufacturers. 1.18 CONTRACT SECURITY: Sections 5.01 and 5.02 of the General Conditions set forth the Owner's requirements with regard to performance and payment bonds. Properly executed performance and payment bonds shall be delivered to the Owner with the executed agreement. All performance and payment bonds for this project shall be in an amount equal to 100% of the Contract Price. The bonds must be executed on the forms provided in these documents and be countersigned by a Florida resident agent. Bonds must accompany the Agreement when delivered to the Owner for execution. 1.19 EXISTING PLANS: Copies of available Owner's records of existing facilities which may impact the proposed construction are available for review at the offices of ARCADIS US, Inc. I B -4 W F900188 and the Village of Tequesta Water Treatment Facility. No guaranty as to the completeness or accuracy of this information is made, or implied, by the Owner or the Engineer. 1.20 PUBLIC ENTITY CRIMES: A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Bid on a Contract to provide any goods or services to a public entity, may not submit a Bid on a Contract with a public entity for the construction or repair of a public building or public work, may not submit Bids on leases of real property to a public entity, may not be awarded to perform Work as a Contractor, supplier, subcontractor, or consultant under a Contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. Vendors doing business with the Village are prohibited from discriminating against any employee, applicant, or client because of race, creed, color, national origin, sex, or age with regard to but not limited to the following: employment practices, rates of pay or other compensation methods, and training selection. Lack of knowledge by the Bidder shall in no way be a cause for relief from responsibility, or constitute a cognizable defense against the legal effect thereof. 1.21 SITE USAGE AND SECURITY: Security at the construction site(s) is given a very high priority by the Owner. The Contractor shall recognize that this project is sensitive in nature as a result of homeland security concerns and the security criteria stipulated herein constitutes a material inducement of the Owner to enter into this contract with the Contractor. It is acknowledged that the project will require construction activities at multiple locations on the project site. However, in recognition of the Owner's security focus and the fact that this is an active and functioning facility, the Contractor shall take reasonable scheduling steps to minimize the degree to which the entire facility is simultaneously impacted by this construction project. The Owner reserves the right to require timing adjustment of certain activities where the impact is judged to have a comparatively minor, or no, effect on efficiency. The Contractor shall restrict all parking, office placement and equipment trailers, stored material storage, lay -down areas, pre- fabrication work areas and other related items strictly to the Contractor staging area shown on the drawings. The existing WTP site is fully secured. The integrity of the perimeter fence must be maintained at all times. It is further noted that the Owner has implemented site security measures which restrict and control entrance to and exit from the site. The Contractor shall anticipate and work within the requirements of the Owner's security measures. The Owner reserves the right to require the Contractor to perform a background check on all agents, licensees, invitees, employees, subcontractors, material -men, workers and suppliers entering the site and supply the results to the Owner. Should this occur, the Contractor shall secure appropriate releases and authorizations from the affected parties prior to performing the background checks. All background checks shall be performed prior to allowing the workers on to the project site. The Owner reserves the right but not the obligation to disallow entrance to the work site of any persons or entities as a result of the background check or other relevant information, regardless of the result of such background check or other relevant information. Background checks shall be in such form and fashion as is acceptable to the Owner but at a minimum shall be performed through the Palm Beach County Sheriff's Department and the Florida Department of Law Enforcement or such other entity, firm or individual acceptable to the Owner, in its' sole discretion. The Contractor shall allow for the time to perform the necessary background checks within the project schedule. I B -5 W F900188 Nothing herein shall confer liability upon the Owner as a result of the security steps and provisions set forth in this contract. Each party who has had a background check performed shall be required to carry photo identification and a clearance tag. Such identification and clearance tag shall be required to enter the site and shall be maintained with the person at all times while on site. Regardless of whether the Owner elects to require the Contractor to perform or take other security measures, the Contractor shall provide to the Owner a complete roster of all parties to enter the work site pursuant to this construction and to keep said roster updated and current on at least a monthly basis. 1.22 PERMITS: The Contractor shall be responsible for securing building permits and licenses r from applicable entities, including the Village of Tequesta for this project. The Owner shall make no separate payment to the Contractor for expenses associated with securing the required licenses, permits or related approvals, however, fees due to the Village for a permit shall be waived. All associated fees will be the Contractor's obligation. The Contractor will be responsible for securing all occupational licenses, or other licenses as set forth elsewhere in this specification, as necessary to perform work in Palm Beach County and the Village of Tequesta. The Contractor shall be responsible for complying with the terms and conditions of all permits issued pursuant to the construction of this project. 1.23 OSHA COMPLIANCE: By submitting a bid, bidders agree that the products furnished and construction methods used will comply with the Williams- Steger Occupational Safety and Health Act of 1970 and /or the Florida Division of Safety, whichever is applicable. 1.24 MATERIAL SAFETY DATA SHEETS: The selected bidder shall provide a copy to the Owner through the Engineer of the Material Safety Data Sheets (MSDS) for all chemicals used in the execution of their work in compliance with Chapter 442, Florida Statutes. 1.25 TIE BIDS: Tie bids may be awarded to one of the bidders based on the following: 1. Availability or completion period. 2. Service availability or facility. 3. Previous vendor record. 4. Drug -Free Workplace (as evidenced by completion of a suitable confirmatory form supplied by the Village). 5. Closeness to the delivery point. Where tie bids are between bidders one of which is a business whose principal place of business is located in Palm Beach County and the other bidder is not, the recommended award shall be to the local bidder. If all conditions are equal, the award shall be determined by drawing lots or flip of a coin. 1.26 DISPUTES: Any actual or prospective Bidder who disputes the reasonableness, necessity or competitiveness of the terms and conditions of the Invitation to Bid, bid selection or contract award recommendation shall file such protest in form of a petition in compliance with Rule 13A- 1.006 Florida Administrative Code. Failure to file a protest within the time prescribed in Section 120.53(5), Florida Statutes shall constitute a waiver of proceedings under Chapter 120, Florida Statutes 1.27 AVAILABILITY OF FUNDS: The obligations of the Village to make a Bid award and sign an agreement under the terms of this "Invitation to Bid" are contingent upon funds lawfully I B -6 W F900188 appropriated for this ur purpose. Should funds n p p of be appropriated for this purpose, the Village, at its sole discretion, shall have the right to reject all bids. 1.28 BIDDING DOCUMENTS AND SPECIFICATION CROSS - REFERENCING: Complete sets of Bidding Documents must be used in preparing bids; neither Owner nor Engineer assumes any responsibility for errors or misrepresentations resulting from the use of incomplete sets of Bidding Documents. The Contractor is advised that the specification is not fully cross referenced. Any section may have information relevant to each trade or equipment requirement. 1.29 WORK AREAS: The lands upon which the Work is to be performed, rights -of -way and easements for access thereto and other lands designated for use by Contractor in performing the Work are identified in the Contract Documents or otherwise assumed to be within public rights -of -way or on the work site owned by the Village. The Contractor shall, as directed by the Engineer, minimize the disruptive impact of his activities on the normal day -to -day operational needs of the Owner. 1.30 DRAWING SCALES: The Contractor is cautioned that scales indicated on the drawings are based on full size (24" X 36 ") plans. Reduce size plans do not have the indicated scales adjusted to reflect the actual plan size. 1.31 ADDENDA: The Owner reserves the right to revise or amend the Contract Documents prior to the bid receipt. Any addenda issued prior to bid receipt shall be binding as if originally written into the Contract Documents. Receipt of all addenda must be acknowledged on the bid form. IB -7 WF900188 DRUG FREE WORKPLACE given to businesses with drug-free Preference shall beg -free workplace programs. Whenever two 9 or more Bids which are equal with respect to price, quality, and service are received by the Village for the procurement of commodities or contractual services, a Bid received from a business that certifies that it has implemented a drug -free workplace program shall be given preference in the award process. Established procedures for processing tie Bids will be followed if none of the tied vendors have a drug -free workplace program. In order to have a drug -free workplace program, a business shall: 1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3. Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in subsection (1). 4. In the statement specified in subsection (1), notify the employees that, as a condition of working on the commodities or contractual services that are under Bid, the employee will abide by the terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community, by any employee who is so convicted. 6. Make a good faith effort to continue to maintain a drug -free workplace through implementation of this section. As the person authorized to sign the statement, I certify that this firm complies fully with the above requirements. Contractor's Signature Date SUBMIT THIS FORM WITH BID. I13-8 WF900188 SPECIAL REQUIREMENTS A. SCOPE OF WORK: The project consists of the replacement of two (2) sodium hypochlorite storage tanks. This project will also include the application of coatings to the new and existing sodium hypochlorite piping system. Equipment tags and markings for the sodium hypochlorite system damaged or removed during construction are also to be replaced as part of this project. B. AGENCY NOTIFICATIONS: The Contractor shall be responsible for notifying the appropriate agencies prior to the start of the work. It should be noted that these agencies may require an on -site meeting prior to commencing this portion of the work. The Contractor shall be responsible for meeting these agencies requirements, and informing the Engineer accordingly. C. SEQUENCE OF WORK: The two sodium hypochlorite tanks shall be removed and replaced sequentially. One of the tanks shall be in service at all times. An interruption in the chemical provided is unacceptable and will result in liquidated damages owed by the Contractor. The tank to be removed must be drained, disconnected and prepared for removal. The tank is not to be removed until the new storage tank is onsite. The time allowed to elapse from the tank being drained until the new tank is placed and being tested shall not exceed 48 hours. The Contractor shall submit for approval a detailed construction schedule that outlines the proposed sequence of work for this project prior to the commencement of construction. This schedule is subject to Engineer approval and work shall not proceed prior to securing approval. The Owner /Engineer reserve the right to change the sequence of work or instruct the Contractor to stop work in one area and commence work in another area of the project, with minimal or no notice to the Contractor. This change in work sequence /direction shall be done in writing by the Owner /Engineer at no additional cost to the Owner. Changes to the work sequence by the Contractor will not be considered only as a substitution under the criteria set forth in Section 01019, 104. D. THE CONTRACTOR SHALL ALSO BE RESPONSIBLE FOR THE FOLLOWING: 1. Complete restoration of disturbed areas to a condition equal to or better than the condition of the area before work began. The restored area shall be maintained by the Contractor through final completion of the project. 2. Complete testing of all the newly installed tanks with the entirety of the chemical feed system for complete functionality. Testing shall be performed in accordance with these specifications. 3. Reviewing the project site prior to the bid. It shall be the Contractors obligation to restore any landscaping that is not a pay item that may be disturbed or damaged to the same condition prior to the start of the work at no cost to the Owner. 1 4. The Contractor shall restore all areas of the facility to their original, or better, condition where disturbed or damaged by construction activity. 5. The Contractor shall schedule all inspections at least 24 -hours in advance. SR -1 WF900188 C OP Y BID VILLAGE OF TEQUESTA WATER TREATMENT PLANT NaOCI STORAGE TANK REPLACEMENT Bid of TLC DIVERSIFIED, INC. (Name) 2719 17th Street East, Palmetto, FL 34221 (Address) to furnish all materials, equipment and labor and to perform all Work in accordance with the Contract Documents for the Village of Tequesta Water Treatment Plant NaOCi Storage Tank Replacement. To: Village of Tequesta c/o ARCADIS US, Inc. 2081 Vista Parkway, Suite 200 West Palm Beach, FL 33491 Gentlemen: F The undersigned bidder has carefully examined the Contract Documents and the site of the i proposed Work and is familiar with the nature and extent of the Work and any local conditions r that may in any manner affect the Work to be done. i The undersigned agrees to do all the Work and furnish all materials called for by the Contract Documents, in the manner prescribed therein and to the standards of quality and performance established by the Engineer for the lump sum listed in the spaces herein provided, for each of the items or combination of items stipulated. The undersigned accepts all of the terms and conditions of the advertisement and /or Invitation 9 #aeon I to Sid and Instructions to Bidders, including, but not limited to, those dealing with disposition of bid security. The undersigned represents that this bid is genuine and not made in the interest of, or on behalf of, any undisclosed person, firm or corporation; bidder has not directly or indirectly induced or solicited any other bidder to submit a false or sham bid; bidder has not any person firm or corporation to refrain from bidding; bidder has not sought by collusion to obtain for itself any advantage over other bidder or over Owner. The undersign covenants that it is qualified to do business in the State of Florida and has { attached evidence of bidders qualification to do business in the State of Florida, or if not attached, bidder covenants to obtain and deliver such evidence within five days of request by ' Owner to produce such evidence. t 8�1 r t . WF900188 i= f BASE LUMP SUM BI© AMOUNT The base lump sum bid amount for the Village of Tequesta Water Treatment Plant NaOCI Storage Tank Replacement including all work specified in these documents is: ' b e.➢ n l 1" o Spa S a c C r i O M dollars and �o- - - - cents. 00 Accompanying this bid is a certified or cashier's check or a bid bond in the amount of $ 5% of Bid Amount (n less than 5% of the bid) made payable to the Village of Tequesta which is to be forfeited as liquidated damages if, in the event this bid is accepted, the undersigned fails to execute the agreement and furnish and pay for satisfactory performance and payment bonds under the conditions and within the time specified in the bid; otherwise said i J' certified or cashier's check or bid bond is to be returned to the undersigned. Additional requirements for the bid bond are set forth in the Invitation to Bid and instructions to Bidders. The undersigned agrees within fifteen (15) days from the date of acceptance of this bid, to ! �. execute the agreement and furnish and pay for satisfactory performance and payment bonds, in the amount of 100% of the Contract price, guaranteeing the faithful performance of the work and payment of bills. Said bonds shall be in accordance with the requirements of Section 255.05, Florida Statutes and satisfy all criteria set forth in this document. The undersigned also agrees to substantially complete the entire project within one hundred and twenty (120) days after the date when the Contract Time commences to run and to be completed and ready for final payment within one hundred and thirty -five (135) days after the Contract Time commences to run. The undersigned further agrees to reimburse the Owner, for each calendar day elapsing between the date herein specified as the date of substantial completion and the actual date of such substantial completion of the contract Work in the amount of $250 per calendar day as liquidated damages. The undersigned further agrees to reimburse the Owner, for each calendar day elapsing between the date herein specified as the date of final completion and the actual date of such final completion of the Contract Work in the amount of $1.50 per calendar day as liquidated damages. The undersigned further agrees to reimburse the Owner for each hour elapsing between the times contractually allocated for total or partial shutdowns and the actual plant shutdown period ff in the amount of $100 /hour for each full hour. The Contractor acknowledges existence of, and guarantees full compliance with the Florida Trench Safety Act. The Bidder acknowledges the receipt of Addenda No's. B -2.. WF000188 t I The following is a complete list of the subcontractors to be used if the undersigned is awarded the Contract for this project. Failure to list all subcontractors will give the Owner the right to require a change in subcontractors without any change in the contract time or cost, or rejection of the bid. List subcontractors other than for the indicated disciplines to the extent necessary to satisfy this criteria. Subcontractors named below may not be changed by the Contractor. The Owner may request a change under the terms of applicable sections of the General Conditions. If a work type category listed below is to be performed by the General Contractor, write the words "blot by Subcontractor" on the applicable line. - type of Work Name, address, and telephone number of Subcontractor Coatings P FL Electrical Poo -I - e_' ► f - [)C- FL ! 9 t t The Contractor shall circle the name of the manufacturer for the following equipment items that will be used and was used in the computation of the Base Lump Sum Bid Amount. Circle only one of the named manufacturers for each item. Failure to circle one of the named t manufacturers in each category may result in rejection of the entire bid. 3 f FRP Storage Tanks Diam =1ndustnes Pla s Tanks is is 1 B' r WF900188 i C i i This bid is submitted by: Name (print) Thurston Lamberson, Pr esident who is an Officer of the above firm duly authorized to sign bids and enter into contracts. I certify that this bid is made without prior understanding, agreement, or connection with any corporation, firm, or � person submitting a bid for the same materials, supplies, or equipment, and is in all respects fair and without collusion or fraud. I understand collusive bidding is a violation of State and Federal law and can result in fines, prison sentences, and civil damage awards. I agree to abide by all conditions of this bid. Dated this 18 day of April 2013 5 (month) i i` Contractor: TLC Dive r s ified, Inc. Address. 2719 17th Street East Palme tto, FL 34221 ` i L `.. By: `I Thurston Lamberson is Title: Pr esident If this bid is rendered by a corporation, the corporate seal attested by the secretary small be ' affixed below. Any agent signing this bid shall attach to this form evidence of legal authority. At ed: Joanne Lam rson, Secretary Seal i B -4 l WF900188 k f 4 , r DRUG FREE WORKPLACE Preference shall be given to businesses with drug -free workplace programs. Whenever two ' or more Bids which are equal with respect to price, quality, and service are received by the Village for the procurement of commodities or contractual services, a Bid received from a business that certifies that it has implemented a drug -free workplace program shall be given preference in the award process. Established procedures for processing tie Bids will be followed if none of the tied vendors have a drug -free workplace program. in order to have a r drug -free workplace program, a business shall: 1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. i 2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation, and ' employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. F 3. Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in subsection (1). 4. In the statement specified in subsection (1), notify the employees that, as a condition working on the commodities or contractual services that are under Bid, the employee will r abide by the terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo contenders to, any violation of Chapter 893 or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community, by any employee f j who is so convicted. G. Make a good faith effort to continue to maintain a drug -free workplace implementation of this section. p e through As the per authorized to sign the statement, I certify that this firm complies fully with the above req it ments. ( l April 18, 2013 Contra tot's Signature Date Thurston Lamberson, President SUBMIT THIS FORM WITH BID. i6 -8 WF000188 1 PUBLIC ENTITY CRIME FORM SWORN STATEMENT UNDER SECTION 287.133(3) (a), FLORIDA STATUTES ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICER AUTHORIZED TO ADMINISTER OATHS. 1. This sworn statement is submitted to Village of Tequesta, FL Thurston Lambeison, President (print individual's name and title) for TLC Diversified Inc. (print name of entity submitting sworn statement) whose business address is 2719 17` St. E., Palmetto FL 34221 and (if applicable its Federal Employer Identification Number (FEIN) is 59- 2513308 2. 1 understand that a "public entity crime" as defined in Para. 287.133(1)(g), Florida Statutes, means a violation of any state or federal law by a. person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or with the United States, including, but not limited to, any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that "convicted" or "conviction" as defined in Para. 287.133(l)(b), Florida Statutes means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment of information after July 1, 1989, as a result of a jury verdict, non jury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an "affiliate" as defined in Para. 287.133(1)(a), Florida Statutes means: a. A predecessor or successor of a erson conic . or P convicted of a public entity crime, b. An entity under the control of an natural person Y p on who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint- venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. I understand that a "person" as defined in Para. 287.133(l)(e), Florida Statute means any natural person or entity organized under the Iaws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. Please indicate which statement applies: X Neither the entity submitting ty ttrng this sworn statement, nor any officers, directors, executives, partners, shareholders, employees, members, or agents who are active in management of the entity, nor any affiliate of the entity have been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of the officers, directors, executives, partners, shareholders, employees, members or agents who are active in management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of the officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list (attach a copy of the final order). I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE t CONTRACTING OFFICER FOR THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH ONE ABOVE IS FOR THAT PUBLIC ENTITY ONLY AND, THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017 FLORIDA STATUTES FOR CATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. r (Signature) Thurston Lamberson, President Sworn to and subscribed before me this 18 to day of April_ ,2013 Personally known to me Notary Public — State of Florida (; (Signature of Notary) tis : DARLEZ CHARLES s= Commission # EE 144526 Notary Stamp: ,:4= Expires February 24, 2016 EonM - Rn 7my F* lneura WO- 305.7019 THE AMERICAN INSTITUTE OF ARCHITECTS BID BOND KNOW ALL MEN BY THESE PRESENTS, that we TLC Diversified, inc,. as Principal, hereinafter called the Principal, and Westfield Insurance Company a corporation duly organized under the laws of the State of Ohio as Surety, hereinafter called the Surety, are held and firmly bound unto Village of Tequesta as Obligee, hereinafter called the Obligee, in the sum of FIVE PERCENT 15 %) OF PROPOSED BID - Dollars for the payment of which sum well and truly to be made, the said Principal and the Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for Tequesta WTP NaOCI Storage Tank Replacement NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 5th day of April 2013 . ;r" TL iyersifled Inc (Seal) X , r ,` (Witness) t r President �j A (Title) Westfield Insurance Company (Seal) L (Witness) Theodore J Jpolick, Agent & ' Attorney-in-Fa c t Printed in cooperation with the American Institute of Architects (AIA) by CANF&D . CANF &D vouches that the language in this document conforms exactly to the language used in AIA Document A310 Bid Bond - AIA, February 1970 ED - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D. C. 20006. THIS POWER OF ATTORNEY SUPERCEDES ANY PREVIOUS POWER BEARING THIS SAME POWER # AND ISSUED PRIOR TO 04/15/10, FOR ANY PERSON OR PERSONS NAMED BELOW. POWER NO. 0992202 04 General Power Westfield insurance Co. of Attorney Westfield National insurance Co. CERTIFIED COPY O hio Farmers insurance Co. t W Center, Ohio Know All Men by These Presents, That WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, corporations, hereinafter referred to individually as a "Company" and collectively as "Companies," duly organized and existing under the laws of the State of Ohio, and having its principal office in Westfield Center, Medina County, Ohio, do by these presents make, constitute and appoint THEODORE J. JEDLICK of DAVIE and State of FL its true and lawful Attorney(s) -in -Fact, with full power and authority hereby conferred in its name. place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings, or other instruments or contracts of suretyship - - - - - - - -- - - - - - - - - - - - - - - - - - - - - - - -- - - - - - - - - - - - - - - - - - - - - - - -- - - - • . LIMITATION: THIS POWER OF ATTORNEY CANNOT BE USED TO EXECUTE NOTE GUARANTEE, MORTGAGE DEFICIENCY, MORTGAGE GUARANTEE, OR BANK DEPOSITORY BONDS. and to bind any of the Companies thereby as fully and to the same extent as if such bonds were signed by the President, sealed with the corporate seal of the applicable Company and duly attested by its Secretary, hereby ratifying and confirming all that the said Attorney(s) -in -Fact may do m the premises. Said appointment is made under and by authority of the following resolution adopted by the Board of Directors of each of the WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY: 'Be it Resolved, that the President, any Senior Executive, any Secretary or any Fidelity & Surety Operations Executive or other Executive shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s) -in -Fact to represent and act for and on behalf of the Company subject to the following provisions: The Attorney -in -Fact, may be given full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge anc deliver, any and all bonds, recognizances, contracts, agreements of indemnity and other conditional or obligatory undertakings and any and ar' notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -in -Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Corporate Secretary.' "Be it Further Resolved, that the signature of any such designated person and the seal of the Company heretofore or hereafter affixed to arir power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signatures or facsim: seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." (Each adopted at a mee tRv held on February 8, 2000). In Witness Whereof, WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANC= COMPANY have caused these presents to be signed by their Senior Executive and their corporate seals to be hereto affixed this 15th day of APRIL A.D., 2010. � ,,,u.uu.n roa Corporate �y$,� ��t7N�11, r ^Vjj$' WESTFIELD INSURANCE COMPANY Seats f . °� >•.., �P,.• NSG r .:°y WESTFIELD NATIONAL INSURANCE COMPANY w63+ 4 Affixed v. ,; s Q: '••� .�� tQ� �" ac '�>a1�►RT R�•A OHIO FARMERS INSURANCE COMPANY =t•� '��, SEAL _ ®; 1848 Z e ll State of Ohio 'w By: County of Medina ss.: Richard L. Kinnaird, Jr., Senior Executive On this 15th day of APRIL A.D., 2010 , before me personally came Richard L. Kinnaird Jr. to me known, who, being by me duly sworn, did depose and say, that he resides in Medina, Ohio; that he is Senior Executive of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, the companies described in and which executed the above instrument; that he knows the seals of said Companies; that the seals affixed to said instrument are such corporate seals; that they were so affixes by order of the Boards of Directors of said Companies; and that he signed his name thereto by like order. Notarial e�" •a•nneaere ha , Seal Affixed �! A L ` ••''• , • William J. Kahelin, A rney at Law, Notary Public State of Ohio i tit ' o My Commission Does Not Expire (Sec. 147.03 Ohio Revised Cc -e, County of Medina ss.: ?F (} F I, Frank A. Carrino, Secretary of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARM SS INSURANCE COMPANY, do hereby certify trial the above and foregoing is a true and correct copy of a Power of Attorney, executed by sa =o Companies, which Is still in full force and effect; and furthermore, the resolutions of the Boards of Directors, set out in the Power of Ato:{ •y a'e in full ford; and effect. In Witness Whereof, I have hereunto set my hand and affixed the seals of said Companies at Westfield Center, Ohio, this c ! A.D., V 2 �N Ji ,F« ,- ,,.e•,a,f P � t ntont r / * ^ '�0o, v� •' +tip K �: : Q `Gp = e .' :•' ��C3 •b l S 6j � • v J SEAL 3 1ti� , cn - r� ; �•' 1848 �+�'•',�• rars �, =: y' :: �,,� ; � Frank A. �arrino, ecret 1 - °ate /', r„•„ aF' /' r �, .a •••.• ' saga e• ���•,� STATE OF FLORIDA F f�� DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION e CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487 -1395 1940 NORTH MONROE STREET TALLAHASSEE FL 32399 -8783 L,AMBERSON, THURSTON T L.C. DIVERSIFIED INC 2719 17TH STREET EAST PAL14IET'TO FL 34221 Ocngratulations! With this license you become one of the nearly one million ;A'r o FLORIDA , Floridians licensed by the Department of Business and Professional Regulation. 1 PEPART24ZNT OF BUSINESS . AND Our professionals and businesses canoe from archi tects to yacht brokers, atomR3FBSSICNAZ� . t� Gt9LAI I03 boxers to barbeque restaurants, and they keep Florida's economy strong. CGC041816 33p 1621 Every day we Work to improve the way we do business in order to serve you better For information about our services, please log onto wwyjj myfloridailcense.corn. CERTIFIED GENR?�L CC?s�"TRACTOR There you can find more information about our divisions and the regulations that LIAMBEx SON', ` -"' - - TO ;d impact you, subscribe to department newsletters and learn more about the T L C D-I EBSI IT`D. II G Department's initiatives. Our mission at the Department is: License Efficiently, Regulate Fairly. We constantly strive to serve you better so that you can serve your customers. Thank you for doing business in Florida, and congratulations on your new license! ; as C under the provisions o�- ch,89 - 3xpizaelon eacei AUG 31, 2014 L1205060' 290 DE TACH HERE !AC#6 154368 STATE OF FLORIDA DEPARTMEN OF BUSINESS: AND PROFESSION REGULATION CONSTRUCTION INDUSTRY LICENSING BOAtZx7 SEQ L12o60601290 LiCENS;v NB ; t i 06J05/2012. 110415241 .ICGC041815_. The GENERA, CQNTr,ACTO . Panted be16-4 IS CERTIFIED Under the prom. of Chatar 4 Expiration date: AUG 31 2014 ��.�� , � L:- � `f LAMBERSON, THURSTON �� T L C' 1) RS �'IED INC ��W 2713 17TH STREET EAST PALMETTO FL 34221 '' RICK SCOTT GOVERNOR KEN LAWSON SECRETARY AS RFfOt liR�r) RY i AIAI A NNF M. P.O. Box 3353, West Palm Beach, FL 33402 -3353 LOCATED AT CCIPIiTMITIVA.Al TAX CO13E www. taxcoliectorpbe.com Tel: (561) 355 -2272 stnnx Palm 110.4 li com? tg 7233 SOUTHERN BLV B 1 10 WEST PALM BEACH, FL 33413- 1648 TYPE OF BUSINESS OWNER CERTIFICATION # RECEIPT #IDATE PAID AMT PAID BILL # 23 -0102 CW GENERAL CONTRACTOR LAMBERSON THURSTON CGC041816 W2.725503-09/202 $369.60 840088476 This document is valid only when receipted by the Tax Collector's Office. STATE OF FLORIDA PALM BEACH COUNTY , 2012/2013 LOCAL BUSINESS TAX RECEIPT T L C DIVERSIFIED INC LBTR Number: 199100688 T L C DIVERSIFIED INC EXPIRES: SEPTEMBER 30.2013 2719 17TH ST E This receipt does not constitute a franchise, PALMETTO, FL 34221 -9314 agreement, permission of authority to perform the n�f u�nlrr0rin�r�rrr� 'Ir�nu�Iranl�slnl services or operate the business described herein when a franchise, agreement or other county commission, state or federal permission of authority is required by county, state of federal law. � / ` /\�m� P.O. � FL 33402-3353 "'LOCATED AT** Tel: (56V355-2272 7233 SOUTHERN BLVB1 WEST PALM BEACH, PL 33413' 1648 This � c--'--- o nly �~ 11^=v=""v the Tax comc-cmrnnnme - ) STATE 8FFLORIDA ! PALM BEACH COUNTY � Be_4*9 3O121%01% LOCAL BUSINESS TAX RECEIPT TLC DIVERSIFIED INC ' TLCD|VERGiF{EO INC L��l[1� y6ur�ber: 10@509966 � � 271817TH ST EXPIRES' SEPTEMBER 30.2Q PALMETTO, FL3422i^Q314 This | does not constitute a w�m/'/o///o"���`�m''/�,n`�/jo� =o�eme»� permission o'oomow�mpam�m�e . , serwceow operate 'the business when _ franchise, agreement o other count Commission, state o.e"vra/ permission au th o r i t y m�nu�dbynoun�o��u/�de�|��� ! � N� Dear Business owner: Your new local business hmre�ip(�nn the evemm�do�\e,�,Mh���nnaUonandd�p|ayhoonop|cuouu|y��yuurp�ueofbumineuo - m««'v�w the public. ,open This receipt ain addition tn and not in lieu \u any license required by law or city ordinance and iu subject (o regulations ofzoning health and ~..'~"= =,.=a"".w/y (Cvvng/Ordinance Number 72-7) ' — Receipts may be transferred to a new owner when evidence Of a sale is provided, the original receipt is surrendered and a transfer fee is paid. Receipts may be transferred to a new location when proof of zoning approval is provided, the original receipt is surrendered and a transfer fee Business name change requires e new Local Business Tax Reooipt Thnm�reu new LOCAL BUSINESS TAX APPL0AT| #05).pnmfnf business name change rog�t��onwith the state and 'proper fees would berequired, ON, (PBCTCFORM This receipt expires on September 30, 2013. Renewal notices arc sent at the end of June. If you do not receive a notice by the end ofJuly, | lope you lave aaucceonfu|year. Constitutional Tax Collector, Serving Palm Beach County CORPORATE RESOLUTION February 25, 2011 RE: Authority to Sign Legal Documents TO WHOM IT MAY CONCERN; i TLC Diversified, Inc., being a legal Corporation organized under the Laws of the State of Florida in April, 1985 Mr. Thurston Lamberson and Mrs. Joanne R. Lamberson and having 300% of the outstanding shares of said Corporation owned since March of 89 declares the following as a matter of record. Mr. Thurston Lamberson, President, shall have full power and authority to sign any and all Legal and Binding Documents and make all commitments of whatever nature for TLC Diversified, Inc. Signed this 25th day of Feb, 2011: Thurston Lamberson panne R. amberson President Vice - President Sworn to and subscribed before me 'Thurston Lamberson, and .Dianne R. Lamberson rhom I know this 25th day of Feb, 2011. Lind, ore Notary Public My Commission Expires: March 20, 2012 LINDA KATY MOORE PAY CC1MM18610N # W770038 €" XPIfZES March 20, 22012 (407) 39E -0153 krFd a4ulnmml l2 om t s i lo State o F�tda Department of State 1 I certify from the records of this office that T.L.C. DIVERSIFIED, INC. is a corporation organized under the laws of the State of Florida, filed on April 4, 1985. The document number of this corporation is H51364. I further certify that said corporation has paid all fees due this office through December 31, 2013, that its most recent annual report /uniform business report was filed on January 28, 2013, and its status is active. I further certify that said corporation has not filed Articles of Dissolution. Given under my hand and the Great Seal of the State of Florida at Tallahassee, the Capital, this is the Twenty eighth day of January, 2013 CA t ' � Secretary of to e Authentication ID. CC2267063797 To authenticate this certificate,visit the following site,enter this ID, and then follow the instructions displayed. https:Herile.sunbiz.org/certauthver.htmi '``� ° CERTIFICATE OF LIABILITY INSURANCE F- 06/26/2013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 1- 813 - 229 -8021 CONTACT Diana Defreeuw M. E. Wilson Co., Inc. PHO N . 813 - 229 -8021 aC No: 300 W. Platt St. E-MAIL Ste 200 ADDRESS: ddefreeuw@mewilson.com Tampa, FL 33606 INSURERS AFFORDING COVERAGE NAIC# INSURERA: WESTFIELD INS CO 24112 INSURED INSURER B FCCI INS CO 10178 TLC Diversified, Inc. INSURER G : 2719 17th Street East INSURER D: Palmetto, FL 34221 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER 34434650 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR A DL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE IM wVD POLICY NUMBER MM/DD/YYYY MM/DD/YYYY LIMITS A GENERAL LIABILITY TRA3972460 04/01/1 04/01/14 EACH OCCURRENCE $ 1,000,000 X COMMERCIAL GENERAL LIABILITY PREM DAMA RENTED 150, 000 PREMISES Ea occurrence $ CLAIMS -MADE IJ OCCUR MED EXP (Any one person) $ 10,000 X Contractual Liability PERSONAL & ADV INJURY $ 1 X $50 Prop Dmg Ded GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $ 2,000,000 POLICY X PRO- X LOC $ A AUTOMOBILE LIABILITY TRA3972460 COMBINED SINGLE LIMIT Ea accident 1, 00 0 , 0 00 X ANY AUTO BODILY INJURY (Per person) $ ALL OWNED SCHEDULED BODILY INJURY (Per accident) $ AUTOS AUTOS NON -OWNED PROPERTY DAMAGE X HIRED AUTOS Ix AUTOS Per accident $ A X UMBRELLA LIAB X OCCUR TRA3972460 04/01/1 04/01/14 EACH OCCURRENCE $ 5 EXCESS LIAB CLAIMS -MADE AGGREGATE $ 5,000,000 DED I X I RETENTION $ 0 $ B WORKERS COMPENSATION 001WC13A61661 WCSTATU- OTH- AND EMPLOYERS' LIABILITY YIN 04/01/1 04/01/14 X ANY PROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $ 500, 000 OFFICEWMEMBER EXCLUDED? N❑ N/A (Mandatory In NH) E.L. DISEASE - EA EMPLOYE $ 500, 000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE -POLICY LIMIT $ 500,000 A Installation Floater TRA3972460 04/01/1 04/01/14 Any One Site: 1,000,000 Transit & Storage: Included Deductible: 1,000 DESCRIPTION OF OPERATIONS I LOCATIONS /VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more apace Is required) Certificate Holder is Listed as Additional Insured RE: WTP NaOCI Storage Tank Replacement TLC Job # 13 -18 -01 CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Village of Tequesta THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 345 Tequesta Drive AUTHORIZED REPRESENTATIVE Tequesta, FL 33469 �t _"t 0. USA :; ✓ ✓JJ ©1988 -2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) The ACORD name and logo are registered marks of ACORD JL002 34434650 CONSTRUCTION AGRET�T THIS AGREEMENT is dated as of the��� day of in the year 2013 by and between THE VILLAGE OF TEQUESTA (hereinafter ca ed R) and TLC Diversified, Inc. (hereinafter called CONTRACTOR). OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: For the complete construction of the Project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: Village of Tequesta, Water Treatment Plant NaOCI Storage Tank Replacement. Article 2. ENGINEER. The Project has been designed by: ARCADIS US, Inc. 2081 Vista Parkway West Palm Beach, FL 33411 ARCADIS US, Inc. is hereinafter called ENGINEER and will act as O)VNER's representative, assume all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. Article 3. CONTRACT TIME. ' 3.1. The Work will be substantially completed within 120 days from the date when the Contract Time commences to run as provided in paragraph 2.3 of the General Conditions, and completed and ready for final payment in accordance with paragraph 14.13 of the General Conditions within 135 days from the date when the Contract Time commences to run. 3.2. Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. They also recognize the delays, expense and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER Two Hundred Fifty Dollars ($250.00) for each day that ' expires after the time specified in paragraph 3.1 for Substantial Completion of the Work. After substantial completion if Contractor shall neglect, refuse or fail to complete the remaining work within the Contract time or any proper extension granted by Owner, Contractor shall pay Owner ' One Hundred Fifty Dollars ($150.00) for each day that expires after the time specified in paragraph 3.1 for completion and readiness for Final payment. The Contractor further agrees to reimburse the Owner, as liquidated damages, for each hour elapsing between contract times allocated for total or partial plant shutdown and actual periods the amount of $100 per full hour. Article 4. CONTRACT PRICE. 4.1. OWNER shall pay CONTRACTOR for completion of the Work in accordance with the Contract Documents the lump sum amount of one hundred seventy seven thousand six hundred dollars ($177,600). i WF900188 Article 5. PAYMENT PROCEDURES. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1. Progress Payments. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR's Applications for Payment as recommended by ENGINEER, on or about the 10th day of each month during construction as provided below. All progress payments will be on the basis of the progress of the work measured by the schedule of values established in paragraph 2.9 of the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no schedule of values, as provided in the General Requirements. 5.1.1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions. 90% of work completed. 90% of materials and equipment not incorporated in the Work (but delivered, suitably stored and accompanied by documentation satisfactory to OWNER as provided in paragraph 14.2 of the General Conditions). 5.1.2. Upon Substantial Completion, in an amount sufficient to increase total payments to CONTRACTOR to 95% of the Contract Price, less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions. ' 5.2. Final Payment. Upon final completion and acceptance of the Work in accordance with paragraph 14.13 of the General Conditions, OWNER shall pay the remainder of the Contract t Price as recommended by ENGINEER as provided in said paragraph 14.13. Article 6. INTEREST - N/A Article 7. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into this Agreement CONTRACTOR makes the following representations: 7.1. CONTRACTOR has familiarized itself with the nature and extent of the Contract Documents, Work, site, locality, and all local conditions and Laws and Regulations that in any ' manner may affect cost, progress, performance or furnishing of the Work. 7.2. CONTRACTOR has reviewed and checked all information and data shown or indicated on , the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports, studies or similar information or data in respect of said Underground Facilities are or will be required by CONTRACTOR in ' order to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of paragraph 4.03 of the General Conditions. 7.3. CONTRACTOR has correlated the results of all such observations, examinations, investigations, explorations, tests, reports, and studies with the terms and conditions of the Contract Documents. 2 WF900188 ' 7.4. CONTRACTOR has given ENGINEER written notice of all conflicts, errors or discrepancies that he has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR. Article 8. CONTRACT DOCUMENTS. The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR concerning the Work consists of the following: 8.1. This Agreement (pages 1 to 4, inclusive). 8.2. Performance, other Bonds, consisting of 4 pages. 8.3. General Conditions (pages 1 to 42, inclusive). 8.4. Supplementary Conditions (pages SGC -1 to SGC -11, inclusive). 8.5. Owner Direct Special Conditions (pages SC -1 to SC -7 inclusive). 8.6. Specifications bearing the title Village of Tequesta, Water Treatment Plant NaOCI Storage ' Tank Replacement and consisting of 6 divisions as listed in the table of contents thereof. 8.7. Drawings consisting of a cover sheet and sheets numbered 1 through 5 inclusive with each sheet bearing the following general title: Village of Tequesta, Water Treatment Plant NaOCI Storage Tank Replacement. Refer to General Requirements. 8.8. CONTRACTOR's Bid (pages B -1 to B -4, inclusive), plus attachments as submitted. 8.9. The following which may be delivered or issued after the Effective Date of the Agreement and are not attached hereto: All Written Amendments and other documents amending, modifying, or supplementing the Contract Documents pursuant to paragraphs 3.04 and 3.05 of the General Conditions. 8.10 The documents listed in paragraphs 8.2 et seq. above are attached to this Agreement (except as expressly noted otherwise above). There are no Contract Documents other than those listed above in this Article 8. The Contract Documents ' may only be amended, modified or supplemented as provided in paragraphs 3.04 and 3.05 of the General Conditions. Article 9. MISCELLANEOUS. 9.1. Terms used in this Agreement which are defined in Article 1 of the General Conditions will have the meanings indicated in the General Conditions. 9.2. No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically but without limitation moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3. OWNER and CONTRACTOR each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect of all covenants, agreements and obligations contained in the Contract Documents. ' 3 WF900188 Article 10. INDEMNIFICATION. 10.1. The parties agree that 1% of the total compensation paid to the Contractor for performance of this Agreement shall represent the specific consideration for the Contractor's indemnification of the Owner and the Engineer as is set forth in Paragraphs 6.20 of the General Conditions. 10.2. It is the specific intent of the parties hereto that the foregoing indemnification complies , with Florida Statute 725.06 (Chapter 725). It is further the specific intent and agreement of the parties that all of the Contract documents on this Project are hereby amended to include the foregoing indemnification and the "Specific Consideration" therefore. ' 10.3 Contractor shall indemnify and hold harmless the Village, its officers and employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the , Contractor and persons employed or utilized by the Contractor in the performance of this construction contract. Article 11. SALES TAX INFORMATION. ' 11.1. The Owner Direct Special Conditions (Sales Tax Information) are incorporated herein by reference. , 4 WF900188 ' IN WITNESS WHEREOF, OWNER and CONTRACTOR have signed four (4) copies of this Agreement. One counterpart each has been delivered to OWNER and CONTRACTOR, and two (2) to the ENGINEER. All portions of the Contract Documents have been signed or identified by OWNER and CONTRACTOR or by ENGINEER on their behalf. This Agreement will be effective on 1 2013 OWNER: CONTRACTOR: VILLAGE OF TEQUESTA TLC Diversified, Inc By " Thurston Lamberson, President [CORP Attest �" o ° 'l` .! ... •..° ,9''�•,, Att iMM Address for givin�'�ptcs Ad ress for giving n aces O.'d 345 Tequesta Dri �Q� �= 2719 17th Street East Tequesta, FL � 334i•. O� 01-- Palmetto, FL 34221 j 561 575 -6200 i 0`'� License No. CGC041816 If CONTRACTOR is a corporation, attach evidence of authority to sign. i i i f } 3 f i 5 WF900138 I i 1� Performance Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. i� CONTRACTOR (Name and Address): SURETY (Name and Address of Principal Place TLC Diversified, Inc ofBusiness): Westfield Insurance Co. 2719 17th Street East, Palmetto FL 34221 1 Park Circle OWNER (Name and Address): Westfield Center, Ohio 44251 Village of Tequesta 345 Tequesta Drive Tequesta, FL 33469 CONTRACT ■el Date: Amount: One Hundred and Seventy -Seven Thousand Six Hundred Dollars /.00 Cents Description (Name and Location): WTP NaOCI Storage Tank Replacement VILLAGE OF TEQUESTA WATER TREATMENT PLANT NaOCI STORAGE TANK REPLACEMENT, TEQUESTA, FL BOND Date (Not earlier than Contract Date): Amount: One Hundred and Seventy -Seven Thousand Six Hundred Dollars /.00 Cents Modifications to this Bond Form: Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this j Payment Bond to be duly executed on its behalf by its authorized officer, agent or representative. i CONTRACTOR AS PRINCIPAL SURETY We s t 'el su nc e Co Company: TLC Diversified In o . Seal) Company: rp. Seal) Signature: Signature: i Name and Title: Thurston Lamberson, President Name and Title: e o e Je is , i (Attach Power of Attomey) Attorney- In -Fact (Space is provided below for signatures of additional parties, if required.) 1 CONTRACTOR AS PI2INC?1DAL SURETY 1 Company: (Corp. Seal) Company: (Corp. Seal) Signature: Signature: Name and Title: Name and Title: FJCDC No. 1910 -28 -A (1996 Edition) ginally prepared through the joint efforts of the Surety Association of America, Engineers Joint Documents Committee, the Associated General Contractors of America, the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. 4 I 1. The CONTRACTOR and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for 111 00610 -1 I _� 'rho performance of the Contract, which is innconporated herein by reference, denied pliability in ..,[tote or in o,t vithcnt ft titer notice the OAT DER Shalt be entitled to enforce any remedy available to the OWNER. 2. If the CONTRACTOR performs the Contract, the Surety and the CONTRACTOR have no obligation under this Bond, except to participate in 6. After the OWNER has terminated the CONTRACTOR's right to complete conferences as provided in paragraph 3.1. the Contract, and if the Surety elects to act under paragraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the OWNER shall not be greater 3. If there is no OWNER Default, the Surety's obligation under this Bond shall than those of the CONTRACTOR under the Contract, and the responsibilities o` arise after: the OWNER to the Surety shall not be greater than those of the OWNER undi the Contract. To a limit of the amount of this Bond, but subject to cormnitment 3.1 The OWNER has notified the CONTRACTOR and the Surety at the by the OWNER of the Balance of the Contract Price to mitigation of costs and addresses described in paragraph 10 below, that the OWNER is damages on the Contract, the Surety is obligated without duplication for: considering declaring a CONTRACTOR Default and has requested and attempted to arrange a conference with the CONTRACTOR and 6.1 The responsibilities of the CONTRACTOR for correction of defective the Surety to be held not later than fifteen days after receipt of such Work and completion of the Contract., notice to discuss methods of performing the Contract. If the owner, the CONTRACTOR and the Surety agree, the CONTRACTOR shall 6.2 Additional legal, design professional and delay costs resulting from be allowed a reasonable time to perform the Contract, but such an the CONTRACTOR's Default, and resulting from the actions or agreement shall be allowed a reasonable time to perform the Contract, failure to act of the Surety under paragraph 4; and but such an agreement shall not waive the OWNER's right, if any, subsequently to declare a CONTRACTOR Default; and 6.3 Liquidated damages, or if no liquidated damages are specified in the Contract. actual damages caused by delayed performance or non- 3.2 The owner has declared a CONTRACTOR Default and formally performance of the CONTRACTOR. terminated the CONTRACTOR's right to complete the Contract. Such CONTRACTOR Default shall not be declared earlier than 7. The Surety shall not be liable to the OWNER or others for obligations of the twenty days after the CONTRACTOR and the Surety have received CONTRACTOR that are unrelated to the Contract, and the Balance of the notice as provided in paragraph 3.1; and Contract Price shall not be reduced or set off on account of anv such unrelated obligations. No right of action shall accrue on this Bond to any person or entity 3.3 The owner has agreed to pay the Balance of the Contract Price to; other than the OWNER or its heirs, executors, administrators, or successors. 3.3.1. The Surety in accordance with the terns of the Contract; 8. The Surety hereby waives notice of any change, including changes of tune, to the Contract or to related subcontracts, purchase orders and other obligations. 3.3.2. Another contractor selected pursuant to paragraph 4.3 to perform the Contract. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the 4. When the owner has satisfied the conditions of paragraph 3, the Surety shall Work is located and shall be instituted within two years after CONTRACTOR promptly and at the Surety's expense take one of the following actions: Default or within two years after the CONTRACTOR ceased working or within two years after the Surety refuses or fails to perform its obligations under this 4.1 Arrange for the CONTRACTOR, with consent of the OWNER, to Bond, whichever occurs first. If the provisions of this paragraph are void or perform and complete the Contract; or prohibited by law, the minimum period of Iiniitaiion available to surities as a defense in the jurisdiction of the suit shall be applicable. 4.2 Undertake to perform and complete the Contract itself, through its agents or through independent contractors; or 10. Notice to the Surety, the OWNER or the CONTRACTOR shall be mailed or delivered to the addresses crown on the signature page. 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the OWNER for a contract for performance and 11. When this Bond has been furnished to comply with a statutory or other legal completion of the Contract, arrange for a contract to be prepared for requirement in the location where the Contract was to be performed, any execution by the OWNER and the contractor selected with the provision in this Bond conflicting with said statutory or legal requirement shall OWNER's concurrence, to be secured with performance and payment be deemed deleted herefrom and provisions conforming to such statutory or bonds executed by a qualified surety equivalent to the Bonds issued on other legal requirement shall be deemed incorporated herein. The intent is, that the Contract, and pay to the OWNER the amount of damages as this Bond shall be construed as a statutory Bond and not as a cormnon law bond. described in paragraph 6 in excess of the Balance of the Contract Price incurred by the OWNER resulting from the CONTRACTOR Default; 12. DEFINITION'S or 12.1 Balance of the Contract Price: The total amount payable by the 4.4 Waive its right to perform and complete, arrange for completion, or OWNER to the 'CONTRACTOR under the Contract after all proper obtain a new contractor and with reasonable promptness under the adjustments have been made, including allowance to the circumstances; CONTRACTOR of any amounts received or to be received by the OWNER in settlement of insurance or other Claims for damages to 4.4.1. After investigations, detennule the amount for which it may be which the CONTRACTOR is entitled, reduced by all valid and proper liable to the OWNER and, as soon as practicable after the payments made to or on behalf of the CONTRACTOR under this amount is determined, tender payment therefor to the OWNER; Contract. or 12.2 Contract: The agreement between the OWNER and the 4.4.2. Deny liability in whole or in part and notify the OWNER citing CONTRACTOR identified on the signature page, including all reasons therefor. Contract Documents and changes thereto. 5. If the Suretv does not proceed as nrovided in paragraph 4 with reasonable 123 CONTRACTOR Default: Failure of the CONTRACTOR_, which hsq promptness, the Surety shall be deemed to be in default on this Bond fifteen neither been remedied nor waived, to perform or otherwise to comply days after receipt of an additional written notice fi the 04t!NER to the Surety with the term.-- c f th C,_p ? demanding 'that the Surety perform its obligations under this Bond, and the 12.4 OWNER Default: Failure of the OWNER, which has neither been OWNER shall be entitled to enforce any remedy available to the OWNER. If remedied nor waived, to pay the CONTRACTOR as required by the 1 the Surety proceeds as provided in paragraph 4.4, and the Oi%viVER refuses the Contract or to perform and complete or comply with the other terms F payment tendered or the Surety has thereof. 1 1 I 00610 -2 General POWER NO. 0992282 04 Power Westfield Insurance Co. of Attorney Westfield National Insurance Co. CERTIFIED co�Y Oh Farmers Insurance C Westfield Center, Ohio Knoiv All Man t) These Presents, T:•tat WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL. INSURANCE COMPANY and OHIO FARMERS INSURAN�F COMPANY, corporations, hereinafter referred to individually as a " and coliectivety as "COmparrss" duly organized and existing under the laws of the State of Ohio, and having its principal office in Westfield ny Center, Molina County, Ohio, do by these presents make, constitute and appoint THEODORE J. JEDLiCK of DAVIE _ ^ ' .. - anal State of FL its true and lawful Attorney(%)win-racl : with full power and etithw9ty hereby w carkrrod in its name, place and stead, to execute. acknowledge and deliver any and all bonds, recognizartces, undertakings, or other inslrumems or omtracts of suretyship- - 1.11"im TWS POWR OF ATTORNEY CANNOT BE USED TO EXECUTE NOTE GUARANTEE, MORTGAGE DEFICIENCY, MORTGAGE GUARAIffM OR BANK DEPOSITORY BONDS. and to bind any of the Companies thereby as fully and to the same extent as if such bonds were signed by the President, sealed with ttue corporate seat of the applicable Company and duty attested by its Secretary, hereby ratifying and confirming an that the said Attorneys) -in -Fact may do in the pprranises. Said appo intment: is ma tinder and by authority of the following resolution adopted by the Board of DiracWs of each of the WESTF1Et.D INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHi FARMERS INSURANCE COMPANY: tae It Resolved, that the President, any Senior Executive, any Secretary or any Fidelity & Surety Operations Executive or other Execs ive shall be and is hereby vested with Lull power and authority to appoint any one or more suitable persons as Attorney(S)4ri -Fact to represent and act for and on behalf of the Camparty sub to the following provisions: The Attorney-Fact, Wray tae g'�ven full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge and deliver, any and all bonds, recognizances, contracts agresmerds of indemtu'ty and other conditional or obligatory undertakings and arty and alt notices aril documents canceling or terminating the Company's liability thereunder, and any such instrumerts so executed by any such A:trarneyy in Fact shall to as binding tit the Company as if signed by the President mid settled and attested by the Corporate Secretary. 73a 7t Curtner Resolveed that the signat thereto of any re Su des ignated and and the seal of th C ompany heretofore or hereafter affixe to any s shall attorney or any be valid and binding upon R he Company with respect y bondd or undertaking w whic certi ficate 6ea amwl V (Eac f acsimile h a d a o meeting held on February 8, 2000). in Wtness latxareof, WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY have caused these presents to be signed by their National Surety Leader and Senior Executive and their corporate seats to be hereto affixed INS 15th day of APRIL A.D.. 2010 . Cerpnrnie u" c ,, WESTFIELD INSURANCE COMPANY seatsp�� ; r�;�c •• ..• a WESTFIELD NATIONAL INSURANCE COMPANY Atrix«i Asa. V A. � ya+ OHI FARMERS INSURANCE COMPANY * ' State of Ohio Dennis P. Baus, National Surety Leader and County of Medine ss.; Semen Exwut" On this 15th day of APRIL A.D., 2010, before me personally came Dennis P. Batas to me known, who, being by me duty sworn, did depose end say, that he resides in Wooster, Ohio, that he is National Surety Leader and Senior Executive of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, the companies described ir and which executed the above Instrument: that he knows the seats of said Companies; that the seals affixed to said instrument are Stich corporate seats, that they were so affixed by order of the Boards of Directors of said Companies; and that he signed his name thereto by Iike xouWal r Ssat A Affixed A ¢\ t, S William J. Kahetb>, A at Law, Nota Public Stara of Ohio ipA � o My Commission Does Not Expire (Sec. 147.43 Otto Revised Codo) County of Medina SS.: -9 r �og ° • •f•, 1, Frank A. Carrino, Secretary of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Companies, which is still !n AA force and effect; and furthermore, the resolutions of the Boards d Directors, set o in the Power of Attorney are in full force and affect, In t�itness Whereot I have hereunto set my hand and affixed the seals of said Companies at Westfield Center, Ohio, Ills day of liWid'bX: : r ..wEAL :m e s 1 gserramy v*,-, : z,•a � g . 1848 'e Frank A. Carrirta, Secretary ,,,'441 /Hw �MNMWM' BPOAC2 (combined) (06-W-) Payment Bond Any singular reference to Contractor Surety, Owner or other party shalt be considered plural where applicable. CONTRACTOR (Na _me a d Address): SURETY (Name and Address of Principal Place TLC Diversified, Inc of Business): Westfield Insurance Co 2719 17th Street East, Palmetto FL 34221 OWNER (Name and Address): 1 Park Circle Village of Tequesta Westfield Center, Ohio 44251 345 Tequesta Drive Tequesta, FL 33469 CONTRACT Date: Amount:One Hundred and Seventy -Seven Thousand Six Hundred Dollars /.00 Cents Description (Name and Location): WTP NaOCI Storage Tank Replacement VILLAGE OF TEQUESTA WATER TREATMENT PLANT NaOCI STORAGE TANK REPLACEMENT TEQUESTA, FL BOND Date (Not earlier than Contract Date): Amount: One Hundred and Seventy -Seven Thousand Six Hundred Dollars /.00 Cents Modifications to this Bond Form: ety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent or representative. CONTRACTOR AS PRINCIPAL SURETY CompanyPLC Diversified, Inc (Corp. Seal) Compa rp.Seal) Vest iel Ins anc Signature: Signature: Name and Title: Thurston Lamberson, President Name and Title: The d e Jedl ick, (Attach Power of Attorney) Attorney -In -Fact (Space is provided below for signatures of additional parties, if required.) I CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: Signature: Name and Title: Name and Title: EJCDC No. 1910 -28 -B (1996 Edition) F Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Documents Committee, the Associated General Contractors of America, the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. i i t 00620 -1 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Na e a d Address): SURETY (Name and Address of Principal Place TLC Diversif Inc of Business): Westfield Insurance Co 2719 17th Street East, Palmetto FL 34221 OWNER (Name and Address): 1 Park Circle Village of Tequesta Westfield Center, Ohio 44251 345 Tequesta Drive Tequesta, FL 33469 CONTRACT Date: Amount: One Hundred and Seventy -Seven Thousand Six Hundred Dollars/. 00 Cents Description (Name and Location): WTP NaOCI Storage Tank Replacement VILLAGE OF TEQUFSTA WATER TREATMENT PLANT NaOCI STORAGE TANK_ REPLACEMENT, TEQUESTA, FL BOND Date (Not earlier than Contract Date): Amount: One Hundred and Seventy - Seven Thousand Six Hundred Dollars /.00 Cents Modifications to this Bond Form: ety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent, or representative. r, CONTRACTOR AS PRINCIPAL SURETY' CompannLC Diversified, Inc (Corp. Seal) Compa rp. Seal) Vest iel Ins anc Signature: i Signature: `L�✓�` F - �- Name and Title: Thurston Lamberson, President Name and Title: The d e Jedlick, (Attach Power of Attorney) Attorney - In -.Fact (Space is provided below for signatures of additional parties, if required.) 3 I s I �i E t CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: Signature: Name and Title: Name and Title: I EICDC No. 1910 -28 -B (1996 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Documents Committee, the Associated General Contractors of America, the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. t r E L 00620 -1 1) 1. The CONTRACTOR and the Surety, jointly and severally, bind themselves, by the Surety. their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Contract, which is incorporated hercin by reference. S. Amounts owed by the OWNER to the CONTRACTOR under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, 1 With respect to the Owner, this obligation shall be null and void if the under any Performance Bond. By the CONTRACTOR fi and the CONTRACTOR: OWNER accepting this Bond, they agree that all lands earned by th, CONTRACTOR in the performance of the Contract are dedicated to satisfy 2.1. Promptly makes payment, directly or indirectly, for all sums due obligations of the CONTRACTOR and the Surety under this Bond, subject to Claimants, and the OWNER's priority to use the funds for the completion of the Work. 2.2. Defends, indenmifres and holds harmless the OWNER from all 9. The Surety shall not be liable to the OWNER, Claimants or others for claims, demands, liens or suits by any person or entity who furnished obligations of the CONTRACTOR that are unrelated to the Contract. The labor, materials or equipment for use in the performance of the OWNER shall not be liable for payment of any costs or expenses of any Contract, provided the OWNER has promptly notified the Claimant under this Bond, and shall have under this Bond no obligations to CONTRACTOR and the Surety (at the addresses described in make payments to, give notices on behalf of, or otherwise have obligations to paragraph 12) of any claims, demands, liens or suits and tendered Claimants under this Bond. defense of such claims, demands, liens or suits to the CONTRACTOR and the Surety, and provided there is no OWNER 10. The Surety hereby waives notice of any change, including changes of time, Default. to the Contract or to related Subcontracts, purchase orders and other obligations. 3. With respect to Claimants, this obligation shall be null and void if the 11. No suit or action shall be commenced by a Claimant under this Bond other CONTRACTOR promptly makes payments, directly or indirectly, for all sums that in a court of competent jurisdiction in the location in which the Work or due. part of the Work is located or after the expiration of one year from the date (I) on which the Claimant gave the notice required by paragraph 4.1 or paragraph 4. Tire Bo 4 2 3, or (2) on which the last labor or service was performed b • anyone or the Surely shay, have no obligation to C�an. under this „��.d ant,: - P y last materials or equipment were furnished by anyone under the Construction 4.1 Claimants who are employed by or have a direct contract with the Contmet, whichever of (1) or (2) first occurs. If the provisions of this paragraph CONTRACTOR have given notice to the Surety (at the addresses are void or prohibited by law, the minimum period of litritntion available to described in paragraph 12) and sent a copy, or notice thereof, to the surdities as a defense in the jurisdiction of the suit shall be applicable. OWNER, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 12. Notice to the Surety, the OWNER or the CONTRACTOR shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice 4.2 Claimants who do not have a direct contract with the by Surety, the OWNER or the CONTRACTOR, however accomplished, shall be CONTRACTOR: sufficient compliance as of the date received at the address shown on the signature page. 1. Have fumished written notice to the CONTRACTOR and sent a copy, or notice thereof, to the OWNER, within 90 days after 13. When this Bond has been furnished to comply with a statutory or other legal having last performed labor or last furnished materials or requirement in the location where the Contract was to be performed, an equipment included in the claim stating, with substantial accuracy, provision in this Bond conflicting with said statutory or legal requirement sha the amount of the claim and the name of the party to whom the be deemed deleted herefrom and provisions conforming to such statutory or materials were furnished or supplied or for whom the labor was other legal requirement shall be deemed incorporated herein. The intent is, that done or performed; and this Bond shall be construed as a statutory Bond and not as a common law bond. t 2. Have either received a rejection in whole or in part from the 14. Upon request of any person or entity appearing to be a potential beneficiary 1 CONTRACTOR, or not received within 30 days of furnishing the of this Bond, the CONTRACTOR shall promptly furnish a copy of this Bond or above notice any communication from the CONTRACTOR by shall permit a copy to be made. i which the CONTRACTOR had indicated the claim will be paid directly or indirectly; and 15. DEFINITIONS 3. Not having been paid within the above 30 days, have sent a 15.1 Claimant: An individual or entity having a direct contract with the i written notice to the Surety and sent a copy, or notice thereof, to CONTRACTOR or with a Subcontractor of the CONTRACTOR to the OWNER, stating that a claim is being made under this Bond furnish labor, materials or equipment for use in the performance of the and enclosing a copy of the previous written notice furnished to Contract. The intent of this Bond shall be to include without limitation the CONTRACTOR. in the terms `labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment 5. If a notice required by paragraph 4 is given by the OWNER to the used in the Contract, architectural and engineering services required for CONTRACTOR or to the Surety, that is sufficient compliance. performance of the Work of the CONTRACTOR and the CONTRACTOR's Subcontractors, and all other items for which a j 6. When the Claimant has satisfied the conditions of paragraph 4, the Surety mechanic's lien may be asserted in the jurisdiction where the labor, shall promptly and at the Surety's expense take the following materials or equipment were famished. actions: 15.2 Contract: The agreement between the OWNER and the 6.1 Send an answer to the Claimant, with a copy to the OWNER, within CONTRACTOR identified on the signature page, including all 45 days after receipt of the claim, stating the amounts that are Contract Documents and changes thereto. undisputed and the basis for challenging any amounts that are disputed. 15.3 OWNER Default: Failure of the OWNER, which has neither been remedied nor waived, to pay the CONTRACTOR as required by the 6.2 Pay or arrange for payment ofany undisputed amounts. Contract or to perform and complete or comply with the other terms thereof. 7. The Surety's total obligation shall not exceed the amount of this Bond, and the ammint of this Bond shall be credited for any payments made in good faith 1 t r 00620-2 1 General POWER NO. 0992202 04 Po wer Westfie I nsurance Co. of Attorney Westfield National Insurance Co. CE RTIFIED co�Y Ohi Farmers I nsurance Co. Westfield Center, Ohio Know All Alen by These Presents, rtat WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURAN F COMPANY, corporations, hereinafter referred to individuallyy as a " " arxf cotleciively as "Companies," duly organ2ed and existing under the laws #f the State of Ohio. and having Its principal offiee in Weld ny Center, Medina County, Ohl#, do by these presents make, constitute and appoint THEODORE J. JEDLICK of AAVttE _ - - M + -- and State of FL its true and lawful Attort y(s)•in -r act with full power and authorit Ittsy herebyY CO�erred in its namC, place and stead, to execute. ackrowledge and deliver any and all fronds, recognjzarces, undertaktrtgs, or other trumatns or contracts of suretyship - - LIMtTAT THIS BOWER OF ATTORNEY CANNOT BE USED TO EXECUTE NOTE GUARANTEE, MORTGAGE DEFICIENCY, MORTGAGE AR OR BANK DEPOSITORY BONDS. and to bind any of the Companies thereby as fully and to the same extent as if such bonds were signed by the President, sealed with the corporate seat of the applicable Company and duty attested by its Secretar y. hereby ratifying and confirming an that the said Attorney(s)-in-Fact may do in the promises. Said appotnunent i$ made tinder and by authority of the following resolution adopted by the Board of Directors of each of the WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY: Be ft Res#lvead, that the President, any Senior Executive, any Secretary or any Fidelity & Surety Operations Executive or other Executive shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s) -in -Fact to represent and act. for and on behalf of the Com�rty Sub'ect to the following provisions: The Attomy -in -Fact. Wray t: ; z full power and authority for and in the name of and of behalf of the ny. to execute, acknowledge and dolver, any and all bonds, recognizences, contracts, agraernerus of indemnity and other conditional or obligatory undertakings and any and all notices aced documents canceling or terminating the Coftirany's liability tfieraunder, and arty suet i� so executed by any such Attorney -in -Fact shall be as binding upon the Company as if sf9rted by the Press= and sealed and Wasted by the Corporate Secretary. 'so it Further Resolved, that the signature of any such desrgneW person and the seal of the Compsrty heretofore or hereafter affixed to any pourer of attcx+tay or any cetiftate relating thereto by facstmtle, and any power of attorney or certificate bearing facskMe sitgrrstures o• facsimile seal sha# be valid and binding upon the Company with respect to any bond or ur dertaking to w it Is anached.' (Each adopted at a meeting held an Februar 8, 2000), In Witness Whereof WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY have caused these presents in be signed by their National Surety Leader anal Senior Ocecutive and their corporate seats to be hereto affixed lids 15th day of APRIL A.D., 2010 . FIELD INSURANCE ,, sg re rM 5eats te � � �.'�r :� !? +"� '� � w WESTFIELD NATIONAL INSURANCE COMPANY Armed ,& �v •son. E .� ;- :� �► t OHI FARMERS INSURANCE COMPANY •q S ai � • t •{t i rsae 'sm : ::c7r a sry 1846 N Z State aus, Matl I Leader and ell Ohio +•f �'''•••• , •M ^• "'` �`°"'"•' Dennis Dertnls P. Baas, ona Surety County of Medina ss.: ,Senior Executive ' On this 15th day of APRIL A.D., 2010, before true personally carry Deans P. Baus to act known, who, being by me duty sworn, did depose and say, that he resides in Wooster, Ohio: that he is Natiortai Sure Leader and Senior Executflre of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, the companies described ir and which executed the attire Instrument; that rte knows the seats of sold Companies; that the seats affixed to said instrument are such Corporate seats: that ' they were so affixed by order of the Boards of Directors of said Companies: and that he signed his nacre thereto by Iflce r. kotarial Affixes R% 4 ,..� f - William J. Kahe3firr, A at Low, Nota Public State of Ohio ef+ a My Commission Does Not Expire (Sec. 147.03 Ohio Revised Code) County of Medina ss.: 4 t . M • MNmIM• 1, Frank A. Camino, Secretary of WESTFIELD INSURANCE COMPANY, WES FIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY. do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, oxecuMd by said Compan which is still :n full force and effect: and furthermore, ne r rsolttions of the Boards of Directors, set out in the Power of Attorney are in fell force and affect. In genies$ Whereof I have hereunto set My hand and affixed the seats of said Companies at Westfield Center, Ohio, this day of SEAL r' 10 rrc- Frank A. CatYlno, Secre3t8ry BPOAC2 (combined) (06.02) This document has important legal consequences; consultation with an attome is encouraged with respect to its use or P g 9 Y g P modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Law. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly By PROFESSIONAL ENGINEERS TN PRIVATE PRACTICE a practice division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS AMERICAN CONSULTING ENGINEERS COUNCIL AMERICAN SOCIETY OF CIVIL ENGINEERS This document has been approved and endorsed by The Associated General Contractors of America Construction Specifications Institute These General Conditions have been prepared for use with the Owner - Contractor Agreements (No. 1910 -8 -A -1 or 1910-8 - A-2) (1996 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the EJCDC User's Guide (No. 1910 -50). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (No. 1910 -17) (1996 Edition). - EJCDC No. 1910 -8 (1996 Edition) -1- r Copyright ®1996 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314 American Consulting Engineers Council ' 1015 15th Street N.W., Washington, DC 20005 American Society of Civil Engineers 345 East 47th Street, New York, NY 10017 -2 ' TABLE OF CONTENTS ARTICLE i - DEFINITIONS AND TERMINOLOGY .................................................................................. ..............................6 1.01 Defined Terms ..................................................................................................................... ..............................6 1.02 Terminology ........................................................................................................................... ..............................8 ARTICLE2 - PRELIMINARY MATTERS ..................................................................................:................. ..............................9 2.01 Delivery of Bonds . nts ........................................................................................................ ..... 9 2.02 Copies of Documents. . ......................... ,9 2.03 Commencement of Contract Times; Notice to Proceed ..................................................... ..............................9 2.04 Starting the Work ................................................................................................................ ..............................9 2 .05 Before Starting Construction .............................................................................................. ..............................9 2.06 Preconstruction Conference ................................................................................................ .............................10 2.07 Initial Acceptance of Schedules ............ ................................................................................ .............................10 ' ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE ............................................ .............................10 3.01 Intent ..................................................................................................................................... .............................10 3.02 Reference Standards ............................................................................................................. .............................10 3.03 Reporting and Resolving Discrepancies ............................................................................ ............................... l i 3.04 Amending and Supplementing Contract'Documents .......................................................... ..............................1 l 3.05 Reuse of Documents ............................................................................................................. .............................11 ' ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS............................................................ ............................... ......................................... .............................11 4.01 Availability of Lands ............................................................................................................ .............................11 4.02 Subsurface and Physical Conditions ................................................................................... .............................12 4.03 Differing Subsurface or Physical Conditions ...................................................................... .............................12 4.04 Underground Facilities ........................................................................................................ .............................13 4.05 Reference Points ................................................................................................................... .............................14 4.06 Hazardous Environmental Condition at Site ....................................................................... .............................14 ARTICLE 5 -BONDS AND INSURANCE ..................................................................................................... .............................IS 5.01 Performance, Payment, and Other Bonds. .15 5 .02 Licensed Sureties and Insurers .................................,.......,...,,.,...,..........,........................,.... .............................15 5 .03 Certificates of Insurance ...................................................................................................... .............................15 5.04 CONTRACTORSs Liability Insurance ................................................................................. .............................15 5.05 OWNER's Liability Insurance . .16 5.06 Property In surance ............................................................................................................... .............................16 5 .07 Waiver of Rights ................................................................................................................... .............................17 5.08 Receipt and Application of Insurance Proceeds ................................................................. .............................18 5.09 Acceptance of Bonds and Insurance; Option to Replace .................................................... .............................18 5.10 Partial Utilization, Acknowledgment of Property Insurer .................................................. .............................18 ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES ................................................................................. .............................18 6.01 Supervision and Superintendence ........................................................................................ .............................18 6.02 Labor; Working Hours ............... ..19 6.03 Services, Materials, and Equipment ent . ............................ .. ..................................................... ............................ : 19 6 .04 Progress Schedule ...................................................................................................... ............................... 19 6 .05 Substitutes and "Or- Equals' ....................................................»......................... ............................... ..19 6.07 Patent Fees and Royalties .................................................................................................. .............................21 ' -3 0 .08 Permits .................................................................................................................................................... .......... 2 6 .09 Laws and Regulations ................................. -------- ........................................................................ Z 6 .lO Taxes .................................................................................................................................................................. ZZ (il) Use of3ito and Other Areas .............................................................................................................................. 2 ti\3 Safety and Protection ........................................................................................................................................ 2] 6 .14 Safety Representative ....................................................................................................................... ............... 6J5 Hazard Communication Programs ................................................................................................................... 3 6lh Emergencies ....................................................................................................................................................... 24 0J7 Shop Drawings and Samples ............................................................................................................................ %4 6 .18 Continuing the Work ......................................................................................................................................... 5 -- 6]9 CONTRA C7%lB's Genera Warranty and Guarantee ...................................................................................... 5 6.20 Indemnification .................................................................................................................................................. 25 ARTICLE7' OTHER WORK ....................................................................................................................................................... 26 7 .01 Related Work /t Site .......................................................................................................................................... Zh 7 .0% Coordination ........... ........................................................................................................................................ ARTICLE 8'OWNER'S RESPONSEBILITIES -.---------------------.-----------------..27 � 8.01 Communications /o Contractor ........................................................................................................................ J 8 .O2 Replacement of ENGRVEER ............................................................................................................................. 2? 8 .03 Furnish Data ..................................................................................................................................................... 27 8 .04 Pay Promptly When Due ................................................................................................................................... 27 DfD Lands and Easements; Reports and 2esiv ............................... ............................... ......................................... Q .06 Insurance .................................................................................................................................................. ........ 27 8 .07 Change Orders ........................................................................................................... 8.08 Inspections, Tests, and Approvals ........... --'_-__'------'—_-_-_-'_-....... -- .... %7 #.00 Limitations on0WNIR's Rugnenoibilit�s ....................................................................................................... 27 8.1O Undisclosed Hazardous Environmental Condition ----_-.—'__-_-_'---._--_—.'27 ' 8.D Evidence offinunoial Arrangements ............................................................................................................... z7 ARTICLE V'ENGINEER'S STATUS DURING CONSTRUCTION ----------------._-----'_--'z/ . 9 .0l OWNER'S Representative ................................................................................................................................. 27 9 .02 Visits /o Site ....................................................................................................................................................... 27 �� �O3}tg�cB�va,�t��e---_------_'_--------___---_--_______ � V.04 Clarifications and Interpretations .................................................................................................................... zo V.05 Authorized Variations bn Work ......................................................................................................................... m 0.06 Rejecting Defective Work ._-__-._--'----------__--------------.-28 A.07 Shop Drawings, Change Orders and Payments ........................................................ ...................... zo � 0lN Decisions ox Requirements 9f Contrac Documents undAuoeptz6dityoy Work ............................................ 29 0.lO Limitations unEkYIDYEBR's.4xthor4y and Responsibilities .......................................................................... zv ARTICLE 1O- CHANGES DN THE WORK; CLAIMS ............................................................................................................... 29 � lO.0l Authorized Changes in the Work .................................................................................................................... zy l0�2{�an�or�edChuug�in�eWox�'-_---_—'_---_---_-_---.--___—..'zy '2A ' lO.O3fx*cw���'Cho�e[�o&�r-------------------------.-.------._-----.. l0{4 Notification uo Surety ..... -_-------_—.----._'-_—____—'-'_------3o lO.O5 Claims and Disputes —.�----------_-------._---_'--'-.—_-_----- . ARTICLE \l' COST OP THE WORK; CASH ALLOWANCES; UNIT PRICE WORK ......................................................... 30 11 .0 1 Cost of the Work .............................................................................................................................................. 3o 1LO2Cux6A&,°anoex ............................................................................................................................................. 3z ill8Dhit}fice Work .............................................................................................................................................. 32 � -4- ARTICLE l2' CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES ....................................................... 33 12.01 Change of l Contrac Price ................................................................................................. ............................ 33 u� 12 .02 Change o/ Contract Times .............................................................................................................................. 34 l2.03 Delays Beyond (%)8DCBAC?l)D's Control .................................................................... ................................ 4 l2.04 Delays Within CONTRA CYlJR's Control ...................................................................................................... 4 �12.06 Delay Damages .................. .............. .................................................. .................................................. ..... 34 /QlTlCLB 13 ' TESTS AND INSPECTIONS; CORRECTION, REMOVAL ORACCEPTANCE OF DEFECTIVE WORK ....................................................................................................................................................................... 13 .01 Notice of Defects ............................................................................................................................................. 4 l382 Access m Work ................................................................................................................................................ 34 l3lB Tests and Inspections ...................................................................................................................................... ]4 13.04 Uncovering Work ............................................................................................................................................ 13 .05 OWNER May`Stop the Work ..................................... . . ................................................................. ...35 l310 Correction n, Remova q/Iefecti`e Work ................................................................................................. .... 35 l].07 Correction Period ........................................................................................................................................... 6 13 .08 Acceptance of Defective Work ........................................................................................................................ 6 l31N OWNER May Correct l)efeotiwoWork ........................................................................................................... 36 ARTICLE 14'yAlM[ENTSTO CONTRACTOR AND ---'-. ---'----.'37 14 .01 Schedule of Values .......................................................................................................................................... 37 l4 .02 Progress Payments ....................................... ................................................................................................. 37 14.03C\J0TRAC?YJR's Na,nzvty of Title ............. 38 i4 .04 Substantial Completion ................................................................................................................................... 39 l4 .05 Partial Utilization ........................................................................................................................................... 39 l4 .06 Final Inspection ............................................................................................................................................... 39 l4 .07 Final Paymen ................................................................................................................................................ 40 l4 .0A Waiver of Claims ............................................................................................................................................. 40 ARTICLE \5' SUSPENSION C0WORK AND TERN4INATION --'----__—__--_----__--.--4l lIO] OWNER May Suspend Work ......................................................................................................................... 4l l5{D OWNER May ?erninalo}0r Cause ................................................................................................................ 41 l5l8 OWNER May Terminate For Convenience .................................................................................................... 4l ]j.04C{lN7RAC2lJBMay Stop Work ur Terminate .............................................................................................. 42 ARTICLE }6-DISPUTE RESOLUTION ..................................................................................................................................... 42 l6Ol Methods and Procedures ................................................................................................................................ 42 ARTICLE 17' -._----'_—_---'-_—''---'------------._—._--__42 1T0l Giving Not .----'_-----------'------._---_---_-----''_-_-'42 — l7.02 Computat o/ Times ..................................................................................................................................... 42 /7.03 Cumulative Remedies ...................................................................................................................................... Q l7 .04 Survival of Obligations ................................................................................................................................... Q l7 .05 Controlling Law ........................................................................................................ ._-''--_—....... /Q � -�- r GENERAL CONDITIONS ARTICLE 1 - DEFINITIONS AND TERMINOLOGY 10. Claim - -A demand or assertion by OWNER or CONTRACTOR seeking an adjustment of Contract Price or , Contract Times, or both, or other relief with respect to the 1.01 Defined Terms terms of the Contract. A demand for money or services by a third party is not a Claim. A. Wherever used in the Contract Documents and printed with initial or all capital letters, the terms listed below 11. Contract - -The entire and integrated written will have the meanings indicated which are applicable to both agreement between the OWNER and CONTRACTOR the singular and plural thereof. concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written 1. Addenda —Written or graphic instruments issued or oral. prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the Contract Documents. 12. Contract Documents - -The Contract Documents ' establish the rights and obligations of the parties and include 2. Agreement- -The written instrument which is the Agreement, Addenda (which pertain to the Contract evidence of the agreement between OWNER and Documents), CONTRACTOR's Bid (including documenta- r CONTRACTOR covering the Work. tion accompanying the Bid and any post Bid documentation submitted prior to the Notice of Award) when attached as an 3. Application for Payment --The form acceptable exhibit to the Agreement, the Notice to Proceed, the Bonds, to ENGINEER which is to be used by CONTRACTOR these General Conditions, the Supplementary Conditions, the during the course of the Work in requesting progress or final Specifications and the Drawings as the same are more payments and which is to be accompanied by such supporting specifically identified in the Agreement, together with all documentation as is required by the Contract Documents. Written Amendments, Change Orders, Work Change Directives, Field Orders, and ENGINEER's written r 4. Asbestos - -Any material that contains more than interpretations and clarifications issued on or after the one percent asbestos and is friable or is releasing asbestos Effective Date of the Agreement. Approved Shop Drawings fibers into the air above current action levels established by and the reports and drawings of subsurface and physical the United States Occupational Safety and Health conditions are not Contract Documents. Only printed or hard r Administration. copies of the items listed in this paragraph are Contract Documents. Files in electronic media format of text, data, 5. Bid —The offer or proposal of a bidder submitted graphics, and the like that may be famished by OWNER to on the prescribed form setting forth the prices for the Work to CONTRACTOR are not Contract Documents. be performed. 13. Contract Price --The moneys payable by OWN - 6. Bidding Documents --The Bidding ER to CONTRACTOR for completion of the Work in r Requirements and the proposed Contract Documents (includ- accordance with the Contract Documents as stated in the ing all Addenda issued prior to receipt of Bids). Agreement (subject to the provisions of paragraph 11.03 in the case of Unit Price Work). 7. Bidding Requirements —The Advertisement or Invitation to Bid, Instructions to Bidders, Bid security form, if 14. Contract Times —The number of days or the any, and the Bid form with any supplements. dates stated in the Agreement to: (i) achieve Substantial Completion; and (ii) complete the Work so that it is ready for 8. Bonds -- Performance and payment bonds and final payment as evidenced by ENGINEER's written other instruments of security. recommendation of final payment. 9. Change Order - -A document recommended by 15. CONTRACTOR --The individual or entity with ENGINEER which is signed by CONTRACTOR and OWN- whom OWNER has entered into the Agreement. ER and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract 16. Cost of the Work --See paragraph 11.01.A for Times, issued on or after the Effective Date of the definition. Agreement. 1 -6- r 17. Drawings —That part of the Contract Documents 28. Notice of Award - -The written notice by OWN - prepared or approved by ENGINEER which graphically ER to the apparent successful bidder stating that upon timely shows the scope, extent, and character of the Work to be compliance by the apparent successful bidder with the performed by CONTRACTOR. Shop Drawings and other conditions precedent listed therein, OWNER will sign and CONTRACTOR submittals are not Drawings as so defined. deliver the Agreement. 18. Effective Date of the Agreement - -The date 29. Notice to Proceed - -A written notice given by indicated in the Agreement on which it becomes effective, but OWNER to CONTRACTOR fixing the date on which the ' if no such date is indicated, it means the date on which the Contract Times will commence to run and on which Agreement is signed and delivered by the last of the two CONTRACTOR shall start to perform the Work under the parties to sign and deliver. Contract Documents. 19. ENGINEER- -The individual or entity named as 30. OWNER- -The individual, entity, public body, or such in the Agreement. authority with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be performed, 20. ENGINEER's Consultant —An individual or ' entity having a contract with ENGINEER to furnish services 31. Partial Utilization --Use by OWNER of a as ENGINEER's independent professional associate or substantially completed part of the Work for the purpose for consultant with respect to the Project and who is identified as which it is intended (or a related purpose) prior to Substantial such in the Supplementary Conditions. Completion of all the Work. 21. Field Order - -A written order issued by ENGI- 32. PCBs -- Polychlorinated biphenyls. NEER which requires minor changes in the Work but which does not involve a change in the Contract Price or the 33. Petroleum -- Petroleum, including crude oil or Contract Times. any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 22. General Requirements -- Sections of Division 1 pounds per square inch absolute), such as oil, petroleum, fuel of the Specifications. The General Requirements pertain to oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed all sections of the Specifications. with other non - Hazardous Waste and crude oils. 23. Hazardous Environmental Condition —The 34. Project - -The total construction of which the presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Work to be performed under the Contract Documents may be Waste, or Radioactive Material in such quantities or the whole, or a part as may be indicated elsewhere in the circumstances that may present a substantial danger to Contract Documents. persons or property exposed thereto in connection with the Work. 35. Project Manual - -The bound documentary information prepared for bidding and constructing the Work. 24. Hazardous Waste - -The term Hazardous Waste A listing of the contents of the Project Manual, which may be shall have the meaning provided in Section 1004 of the Solid bound in one or more volumes, is contained in the table(s) of Waste Disposal Act (42 USC Section 6903) as amended from contents. time to time. 36. Radioactive Material— Source, special nuclear, 25. Laws and Regulations, Laws or Regulations -- or byproduct material as defined by the Atomic Energy Act of Any and all applicable laws, rules, regulations, ordinances, 1954 (42 USC Section 2011 et seq.) as amended from time to codes, and orders of any and all governmental bodies, time. agencies, authorities, and courts having jurisdiction. 37. Resident Project Representative —The autho- 26. Liens — Charges, security interests, or rized representative of ENGINEER who may be assigned to encumbrances upon Project funds, real property, or personal the Site or any part thereof. property. 38. Samples — Physical examples of materials, 27. Milestone - -A principal event specified in the equipment, or workmanship that are representative of some Contract Documents relating to an intermediate completion portion of the Work and which establish the standards by date or time prior to Substantial Completion of all the Work. which such portion of the Work will be judged. -7- 39. Shop Drawings- -All drawings, diagrams, 48. Work —The entire completed construction or the illustrations, schedules, and other data or information which various separately identifiable parts thereof required to be are specifically prepared or assembled by or for CON- provided under the Contract Documents. Work includes and TRACTOR and submitted by CONTRACTOR to illustrate is the result of performing or providing all labor, services, and some portion of the Work. documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and ' 40. Site - -Lands or areas indicated in the Contract equipment into such construction, all as required by the Documents as being famished by OWNER upon which the Contract Documents. Work is to be performed, including rights -of -way and , easements for access thereto, and such other lands furnished 49. Work Change Directive --A written statement to by OWNER which are designated for the use of CONTRACTOR issued on or after the Effective Date of the CONTRACTOR. Agreement and signed by OWNER and recommended by ENGINEER ordering an addition, deletion, or revision in the 41. Specifications--That part of the Contract Work, or responding to differing or unforeseen subsurface or Documents consisting of written technical descriptions of physical conditions under which the Work is to be performed materials, equipment, systems, standards, and workmanship or to emergencies. A Work Change Directive will not change as applied to the Work and certain administrative details the Contract Price or the Contract Times. but is evidence that ' applicable thereto. the parties expect that the change ordered or documented by a Work Change Directive will be incorporated. in a subse- 42. Subcontractor —An individual or entity having a quently issued Change Order following negotiations by the direct contract with CONTRACTOR or with any other parties as to its effect, if any, on the Contract Price or Subcontractor for the performance of a part of the Work at the Contract Times. Site. 50. Written Amendment —A written statement 43. Substantial Completion - -The time at which the modifying the Contract Documents, signed by OWNER and Work (or a specified part thereof) has progressed to the point CONTRACTOR on or after the Effective Date of the where, in the opinion of ENGINEER, the Work (or a Agreement and normally dealing with the nonengineering or specified part thereof) is sufficiently complete, in accordance nontechnical rather than strictly construction - related aspects with the Contract Documents, so that the Work (or a specified of the Contract Documents. part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and 1.02 Terminology "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. A. Intent of Certain Terms or Adjectives 44. Supplementary Conditions —That part of the 1. Whenever in the Contract Documents the terms Contract Documents which amends or supplements these "as allowed," "as approved," or terms of like effect or General Conditions. import are used, or the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of 45. Supplier - -A manufacturer, fabricator, supplier, like effect or import are used to describe an action or distributor, materialman, or vendor having a direct contract determination of ENGINEER as to the Work, it is with CONTRACTOR or with any Subcontractor to furnish intended that such action or determination will be solely materials or equipment to be incorporated in the Work by to evaluate, in general, the completed Work for CONTRACTOR or any Subcontractor. compliance with the requirements of and information in th Contract Documents and conformance with the design 46. Underground Facilities —All underground concept of the completed Project as a functioning whole pipelines, conduits, ducts, cables, wires, manholes, vaults, as shown or indicated in the Contract Documents (unless tanks, tunnels, -or other such facilities or attachments, and any there is a specific statement indicating otherwise). The encasements containing such facilities, including those that use of any such term or adjective shall not be effective to convey electricity, gases, steam, liquid petroleum products, assign to ENGINEER any duty or authority to supervise telephone or other communications, cable television, water, or direct the performance of the Work or any duty or wastewater, storm water, other liquids or chemicals, or traffic authority to undertake responsibility contrary to the or other control systems. provisions of paragraph 9.10 or any other provision of the Contract Documents. 47. Unit Price Work —Work to be paid for on the basis of unit prices. B. Day -8- M 1 1. The word "day" shall constitute a calendar ARTICLE 2 - PRELIMINARY MATTERS day of 24 hours measured from midnight to the next . midnight. 2.01 Delivery of Bonds C. Defective A. When CONTRACTOR delivers the executed 1. The word "defective," when modifying the Agreements to OWNER, CONTRACTOR shall also deliver word "Work," refers to Work that is unsatisfactory, to OWNER such Bonds as CONTRACTOR may be required ' faulty, or deficient in that it does not conform to the to furnish. Contract Documents or does not meet the require- ments of any inspection, reference standard, test, or 2.02 Copies of Documents approval referred to in the Contract Documents, or has been damaged prior to ENGINEER's recom- A. OWNER shall famish to CONTRACTOR up to ten mendation of final payment (unless responsibility for copies of the Contract Documents. Additional copies will be the protection thereof has been assumed by OWNER furnished upon request at the cost of reproduction. at Substantial Completion in accordance with paragraph 14.04 or 14.05). 2.03 Commencement of Contract Times; Notice to Proceed D. Furnish, Install, Perform, Provide A. The Contract Times will commence to run on the 1. The word "famish," when used in connec- thirtieth day after the Effective Date of the Agreement or, if a tion with services, materials, or equipment, shall mean Notice to Proceed is given, on the day indicated in the Notice to supply and deliver said services, materials, or to Proceed. A Notice to Proceed may be given at any time equipment to the Site (or some other specified within 30 days after the Effective Date of the Agreement. In location) ready for use or installation and in usable or no event will the Contract Times commence to run later than operable condition. the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date 2. The word "install," when used in connec- is earlier. tion with services, materials, or equipment, shall mean to put into use or place in final position said services, 2.04 Starting the Work materials, or equipment complete and ready for intended use. A. CONTRACTOR shall start to perform the Work on the date when the Contract Times commence to run. No 3. The words "perform" or "provide," when Work shall be done at the Site prior to the date on which the used in connection with services, materials, or Contract Times commence to run. equipment, shall mean to furnish and install said services, materials, or equipment complete and ready 2.05 Before Starting Construction for intended use. A. CONTRACTOR's Review of Contract Documents: 4. When "furnish," "install," "perform," or "pro- Before undertaking each part of the Work, CONTRACTOR vide" is not used in connection with services, materials, or shall carefully study and compare the Contract Documents equipment in a context clearly requiring an obligation of and check and verify pertinent figures therein and all CONTRACTOR, "provide" is implied. applicable field measurements. CONTRACTOR shall promptly report. in writing to ENGINEER any conflict, error, E. Unless stated otherwise in the Contract Documents, ambiguity, or discrepancy which CONTRACTOR may words or phrases which have a well -known technical or discover and shall obtain a written interpretation or construction industry or trade meaning are used in the clarification from ENGINEER before proceeding with any Contract Documents in accordance with such recognized Work affected thereby; however, CONTRACTOR shall not meaning, be liable to OWNER or ENGINEER for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless CONTRACTOR knew or reasonably should have known thereof. B. Preliminary Schedules: Within ten days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), CONTRACTOR shall submit 1. The progress schedule will be acceptable to to ENGINEER for its timely review: ENGINEER if it provides an orderly progression of the Work to completion within any specified Mile - 1. a preliminary progress schedule indicating stones and the Contract Times. Such acceptance will the times (numbers of days or dates) for starting and not impose on ENGINEER responsibility for the completing the various stages of the Work, including progress schedule, for sequencing, scheduling, or any Milestones specified in the Contract Documents; progress of the Work nor interfere with or relieve CONTRACTOR from CONTRACTOR's full respon- 2. a preliminary schedule of Shop Drawing sibility therefor. ' and Sample submittals which will list each required submittal and the times for submitting, reviewing, and 2. CONTRACTOR's schedule of Shop processing such submittal; and Drawing and Sample submittals will be acceptable to ENGINEER if it provides a workable arrangement for 3. a preliminary schedule of values for all of reviewing and processing the required submittals. the Work which includes quantities and prices of items which when added together equal the Contract 3. CONTRACT schedule of values will Price and subdivides the Work into component parts be acceptable to ENGINEEER ER as to form and substance in sufficient detail to serve as the basis for progress if it provides a reasonable allocation of the Contract payments during performance of the Work. Such Price to component parts of the Work. prices will include an appropriate amount of overhead ' and profit applicable to each item of Work. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, C. Evidence oflnsurance: Before any Work at the Site AMENDING, REUSE is started, CONTRACTOR and OWNER shall each deliver to. the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and 3.01 Intent other evidence of insurance which either of them or any additional insured may reasonably request) which A. The Contract Documents are complementary; what CONTRACTOR and OWNER respectively are required to is called for by one is as binding as if called for by all. purchase and maintain in accordance with Article 5. B. It is the intent of the Contract Documents to describe 2.06 Preconstruction Conference a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Documents. Any A. Within 20 days after the Contract Times start to run, labor, documentation, services, materials, or equipment that but before any Work at the Site is started, a conference may reasonably be inferred from the Contract Documents or attended by CONTRACTOR, ENGINEER, and others as from prevailing custom or trade usage as being required to appropriate will be held to establish a working understanding produce the intended result will be provided whether or not among the parties as to the Work and to discuss the schedules specifically called for at no additional cost to OWNER referred to in paragraph 2.053, procedures for handling Shop Drawings and other submittals, processing Applications for C. Clarifications and interpretations of the Contract Payment, and maintaining required records. Documents shall be issued by ENGINEER as provided in Article 9. 2.07 Initial Acceptance of Schedules 3.02 Reference Standards A. Unless otherwise provided in the Contract Docu- ments, at least ten days before submission of the first A. Standards, Specifications, Codes, Laws, and Application for Payment a conference attended by CON- Regulations TRACTOR, ENGINEER, and others as appropriate will be held to review for acceptability to ENGINEER as provided 1. Reference to standards, specifications, below the schedules submitted in accordance with paragraph manuals, or codes of any technical society, organiza- 2.05.B. CONTRACTOR shall have an additional ten days to tion, or association, or to Laws or Regulations, make corrections and adjustments and to complete and whether such reference be specific or by implication, resubmit the schedules. No progress payment shall be made shall mean the standard, specification, manual, code, to CONTRACTOR until acceptable schedules are submitted or Laws or Regulations in effect at the time of opening to ENGINEER of Bids (or on the Effective Date of the Agreement if -to- i there were no Bids), except as may be otherwise b. the provisions of any Laws or Regulations specifically stated in the Contract Documents. applicable to the performance of the Work (unless such an interpretation of the provisions of the 2. No provision of any such standard, Contract Documents would result in violation of specification, manual or code, or any instruction of a such Law or Regulation). r Supplier shall be effective to change the duties or responsibilities of OWNER, CONTRACTOR, or 3.04 Amending and Supplementing Contract Documents ENGINEER, or any of their subcontractors, consul - tants, agents, or employees from those set forth in the A. The Contract Documents may be amended to Contract Documents, nor shall any such provision or provide for additions, deletions, and revisions in the Work or instruction be effective to assign to OWNER, to modify the terms and conditions thereof in one or more of ENGINEER, or any of ENGINEER's Consultants, the following ways: (i) a Written Amendment; (ii) a Change agents, or employees any duty or authority to Order; or (iii) a Work Change Directive, supervise or direct the performance of the Work or any duty or authority to undertake responsibility B. The requirements of the Contract Documents may inconsistent with the provisions of the Contract be supplemented, and minor variations and deviations in the Documents. Work may be authorized, by one or more of the following ways: (i) a Field Order, (ii) ENGINEER's approval of a Shop 3.03 Reporting and Resolving Discrepancies Drawing or Sample; or (iii) ENGINEER's written interpreta- tion or clarification. A. Reporting Discrepancies 3.05 Reuse of Documents 1. If, during the performance of the Work, CONTRACTOR discovers any conflict, error, ambi -. A. CONTRACTOR and any Subcontractor or Supplier guity, or discrepancy within the Contract Documents or other individual or entity performing or furnishing any of or between the Contract Documents and any provision the Work under a direct or indirect contract with OWNER: (i) of any Law or Regulation applicable to the per shall not have or acquire any title to or ownership rights in mance of the Work or of any standard, specification, any of the Drawings, Specifications, or other documents (or manual or code, or of any instruction of any Supplier, copies of any thereof) prepared by or bearing the seal of CONTRACTOR shall report it to ENGINEER in ENGINEER or ENGINEER's Consultant, including writing at once. CONTRACTOR shall not proceed electronic media editions; and (ii) shall not reuse any of such with the Work affected thereby (except in an Drawings, Specifications, other documents, or copies thereof emergency as required by paragraph 6.16.A) until an on extensions of the Project or any other project without amendment or supplement to the Contract Documents written consent of OWNER and ENGINEER and specific has been issued by one of the methods indicated in written verification or adoption by ENGINEER This paragraph 3.04; provided, however, that prohibition will survive final payment, completion, and CONTRACTOR shall not be liable to OWNER or acceptance of the Work, or termination or completion of the ENGINEER for failure to report any such conflict, Contract. Nothing herein shall preclude CONTRACTOR error, ambiguity, or discrepancy unless CON - from retaining copies of the Contract Documents for record TRACTOR knew or reasonably should have known purposes. thereof. B. Resolving Discrepancies ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; 1. Except as may be otherwise specifically REFERENCE POINTS stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepan- 4.01 Availability of Lands cy between the provisions of the Contract Documents and: A. OWNER shall furnish the Site. OWNER shall notify CONTRACTOR of any encumbrances or restrictions a. the provisions of any standard, not of general application but specifically related to use of the specification, manual, code, or instruction Site with which CONTRACTOR must comply in performing (whether or not specifically incorporated by the Work. OWNER will obtain in a timely manner and pay reference in the Contract Documents); or for easements for permanent structures or permanent changes in existing facilities. If CONTRACTOR and OWNER are -Il- unable to agree on entitlement to or on the amount or extent, 3. any CONTRACTOR interpretation of or if any, of any adjustment in the Contract Price or Contract conclusion drawn from any "technical data" or any Times, or both, as a result of any delay in OWNER's such other data, interpretations, opinions, or infor- furnishing the Site, CONTRACTOR may make a Claim mation. therefor as provided in paragraph 10.05. 4.03 Deering Subsurface or Physical Conditions B. Upon reasonable written request, OWNER shall furnish CONTRACTOR with a current- statement of record A. Notice: If CONTRACTOR believes that any legal title and legal description of the lands upon which the subsurface or physical condition at or contiguous to the Site Work is to be performed and OWNER's interest therein as that is uncovered or revealed either: necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with 1. is of such a nature as to establish that any applicable Laws and Regulations. "technical data" on which CONTRACTOR is entitled to rely as provided in paragraph 4.02 is materially C. CONTRACTOR shall provide for all additional inaccurate; or lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 2. is of such a nature as to require a change in the Contract Documents; or 4,02 Subsurface and Physical Conditions 3. differs materially from that shown or A. Reports and Drawings: The Supplementary indicated in the Contract Documents; or Conditions identify: 4. is of an unusual nature, and differs materially from 1. those reports of explorations and tests of - conditions ordinarily encountered and generally recognized as subsurface conditions at or contiguous to the Site that inherent in work of the character provided for in the Contract ENGINEER has used in preparing the Contract Docu- Documents; ments; and , then CONTRACTOR shall, promptly after becoming aware 2. those drawings of physical conditions in thereof and before further disturbing the subsurface or or relating to existing surface or subsurface structures physical conditions or performing any Work in connection at or contiguous to the Site (except Underground therewith (except in an emergency as required by paragraph Facilities) that ENGINEER has used in preparing the 6.16.A), notify OWNER and ENGINEER in writing about Contract Documents. such condition. CONTRACTOR shall not further disturb such condition or perform any Work in connection therewith B. Limited Reliance by CONTRACTOR on Technical (except as aforesaid) until receipt of written order to do so. Data Authorized: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such B. ENGINEER's Review: After receipt of written reports and drawings, but such reports and drawings are not notice as required by paragraph 4.03.A, ENGINEER will Contract Documents. Such "technical data" is identified in promptly review the pertinent condition, determine the the Supplementary Conditions. Except for such reliance on necessity of OWNER's obtaining additional exploration or such "technical data," CONTRACTOR may not rely upon or tests with respect thereto, and advise OWNER in writing make any Claim against OWNER, ENGINEER, or any of (with a copy to CONTRACTOR) of ENGINEER's findings ENGINEER's Consultants with respect to: and conclusions. 1. the completeness of such reports and C. Possible Price and Times Adjustments drawings for CONTRACTOR's purposes, including, but not limited to, any aspects of the means, methods, 1. The Contract Price or the Contract Times, techniques, sequences, and procedures of construction or both, will be equitably adjusted to the extent that to be employed by CONTRACTOR, and safety the existence of such differing subsurface or physical precautions and programs incident thereto; or condition causes an increase or decrease in CONTRACTOR's cost of, or time required for, 2. other data, interpretations, opinions, and performance of the Work; subject, however, to the information contained in such reports or shown or following: indicated in such drawings; or -12- a. such condition must meet any one or more of the categories described in paragraph 4.03.A; 1. OWNER and ENGINEER shall not be and responsible for the accuracy or completeness of any such information or data; and b. with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Price 2. the cost of all of the following will be will be subject to the provisions of paragraphs 9.08 included in the Contract Price, and CONTRACTOR and 11.03. shall have full responsibility for: 2. CONTRACTOR shall not be entitled to a. reviewing and checking all such informa- any adjustment in the Contract Price or Contract tion and data, Times if: b. locating all Underground Facilities shown a. CONTRACTOR knew of the existence of or indicated in the Contract Documents, such conditions at the time CONTRACTOR made a final commitment to OWNER in respect of c. coordination of the Work with the owners Contract Price and, Contract Times by the submis- of such Underground Facilities, including sion of a Bid or becoming bound under a negotiat- OWNER, during construction, and ed contract; or d. the safety and protection of all such Under - b. the existence of such condition could ground Facilities and repairing any damage reasonably have been discovered or revealed as a thereto resulting from the Work. result of any examination, investigation, explo- ration, test, or study of the Site and contiguous. B. Not Shown or Indicated areas required by the Bidding Requirements or Contract Documents to be conducted by or for 1. If an Underground Facility is uncovered or CONTRACTOR prior to CONTRACTOR's revealed at or contiguous to the Site which was not making such final commitment; or shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, c. CONTRACTOR failed to give the written CONTRACTOR shall, promptly after becoming notice within the time and as required by para- aware thereof and before further disturbing conditions graph 4.03.A. affected thereby or performing any Work in connection therewith (except in an emergency as 3. If OWNER and CONTRACTOR are required by paragraph 6.16.A), identify the owner of unable to agree on entitlement to or on the amount or such Underground Facility and give written notice to extent, if any, of any adjustment in the Contract Price that owner and to OWNER and ENGINEER. ENGI- or Contract Times, or both, a Claim may be made NEER will promptly review the Underground Facility therefor as provided in paragraph 10.05. However, and determine the extent, if any, to which a change is OWNER, ENGINEER, and ENGINEER's required in the Contract Documents to reflect and Consultants shall not be liable to CONTRACTOR for document the consequences of the existence or any claims, costs, losses, or damages (including but location of the Underground Facility. During such not limited to all fees and charges of engineers, time, CONTRACTOR shall be responsible for the architects, attorneys, and other professionals and all safety and protection of such Underground Facility. court or arbitration or other dispute resolution costs) sustained by CONTRACTOR on or in connection 2. If ENGINEER concludes that a change in with any other project or anticipated project. the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect 4.04 Underground Facilities and document such consequences. An equitable adjustment shall be made in the Contract Price of A. Shown or Indicated: The information and data Contract Times, or both, to the extent that they are shown or indicated in the Contract Documents with respect to attributable to the existence or location of any existing Underground Facilities at or contiguous to the Site is Underground Facility that was not shown or indicated based on information and data famished to OWNER or or not shown or indicated with reasonable accuracy in ENGINEER by the owners of such Underground Facilities, the Contract Documents and that CONTRACTOR did including OWNER, or by others. Unless it is otherwise not know of and could not reasonably have been expressly provided in the Supplementary Conditions: expected to be aware of or to have anticipated. If -13- OWNER and CONTRACTOR are unable to agree on such other data, interpretations, opinions or entitlement to or on the amount or extent, if any, of information. any such adjustment in Contract Price or Contract Times, OWNER or CONTRACTOR may make a C. CONTRACTOR shall not be responsible for any Claim therefor as provided in paragraph 10.05. Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or 4.05 Reference Points Specifications or identified in the Contract Documents to be within the scope of the Work. CONTRACTOR shall be A. OWNER shall provide engineering surveys to responsible for a Hazardous Environmental Condition created establish reference points for construction which in with any materials brought to the Site by CONTRACTOR, ENGINEER's judgment are necessary to enable CON- Subcontractors, Suppliers, or anyone else for whom CON- TRACTOR to proceed with the Work. CONTRACTOR shall TRACTOR is responsible. be responsible for laying out the Work, shall protect and preserve the established reference points and property D. If CONTRACTOR encounters a Hazardous monuments, and shall make no changes or relocations Environmental Condition or if CONTRACTOR or anyone for without the prior written approval of OWNER. whom CONTRACTOR is responsible creates a Hazardous CONTRACTOR shall report to ENGINEER whenever any Environmental Condition, CONTRACTOR shall immedi- reference point or property monument is lost or destroyed or ately: (i) secure or otherwise isolate such condition; (ii) stop requires relocation because of necessary changes in grades or all Work in connection with such condition and in any area locations, and shall be responsible for the accurate affected thereby (except in an emergency as .required by replacement or relocation of such reference points or property paragraph 6.16); and (iii) notify OWNER and ENGINEER monuments by professionally qualified personnel. (and promptly thereafter confirm such notice in writing). OWNER shall promptly consult with ENGINEER concerning 4.06 Hazardous Environmental Condition at Site the necessity for OWNER to retain a qualified expert to evaluate such condition or take corrective action, if any. A. Reports and Drawings: Reference is made to the Supplementary Conditions for the identification of those E. CONTRACTOR shall not be required to resume reports and drawings relating to a Hazardous Environmental Work in connection with such condition or in any affected Condition identified at the Site, if any, that have been utilized area until after OWNER has obtained any required permits by the ENGINEER in the preparation of the Contract related thereto and delivered to CONTRACTOR written Documents. notice: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; B. Limited Reliance by CONTRACTOR on Technical or (ii) specifying any special conditions under which such Data Authorized: CONTRACTOR may rely upon the Work may be resumed safely. If OWNER and general accuracy of the "technical data" contained in such CONTRACTOR cannot agree as to entitlement to or on the reports and drawings, but such reports and drawings are not amount or extent, if any, of any adjustment in Contract Price Contact Documents. Such "technical data" is identified in or Contract Times, or both, as a result of such Work stoppage the Supplementary Conditions. Except for such reliance on or such special conditions under which Work is agreed to be such "technical data," CONTRACTOR may not rely upon or resumed by CONTRACTOR, either party may make a Claim make any Claim against OWNER; ENGINEER - or any of therefor as provided in paragraph 10.05. ENGINEER's Consultants with respect to: F. If after receipt of such written notice 1. the completeness of such reports and CONTRACTOR does not agree to resume such Work based drawings for CONTRACTOR's purposes, including, on a reasonable belief it is unsafe, or does not agree to resume but not limited to, any aspects of the means, methods, such Work under such special conditions, then OWNER may techniques, sequences and procedures of construction order the portion of the Work that is in the area affected by to be employed by CONTRACTOR and safety such condition to be deleted from the Work. If OWNER and precautions and programs incident thereto; or CONTRACTOR cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or 2. other data, interpretations, opinions and Contract Times as a result of deleting such portion of the information contained in such reports or shown or Work, then either party may make a Claim therefor as indicated in such drawings; or provided in paragraph 10.05. OWNER may have such deleted portion of the Work performed by OWNER's own 3. any CONTRACTOR interpretation of or forces or others in accordance with Article 7. conclusion drawn from any "technical data" or any -14- G. To the fullest extent permitted by Laws and Regulations, OWNER shall indemnify and hold harmless B. All Bonds shall be in the form prescribed by the CONTRACTOR, Subcontractors, ENGINEER, Contract Documents except as provided otherwise by Laws ENGINEER's Consultants and the officers, directors, or Regulations, and shall be executed by such sureties as are partners, employees, agents, other consultants, and named in the current list of "Companies Holding Certificates subcontractors of each and any of them from and against all of Authority as Acceptable Sureties on Federal Bonds and as claims, costs, losses, and damages (including but not limited Acceptable Reinsuring Companies" as published in Circular to all fees and charges of engineers, architects, attorneys, and 570 (amended) by the Financial Management Service, Surety other professionals and all court or arbitration or other dispute Bond Branch, U.S. Department of the Treasury. All Bonds resolution costs) arising out of or relating to a Hazardous signed by an agent must be accompanied by a certified copy Environmental Condition, provided that such Hazardous of such agent's authority to act. Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract C. If the surety on any Bond furnished by CON - Documents to be included within the scope of the Work, and TRACTOR is declared bankrupt or becomes insolvent or its (ii) was not created by CONTRACTOR or by anyone for right to do business is terminated in any state where any part whom CONTRACTOR is responsible. Nothing in this para- of the Project is located or it ceases to meet the requirements graph 4.06.E shall obligate OWNER to indemnify any of paragraph 5.013, CONTRACTOR shall within 20 days individual or entity from and against the consequences of that thereafter substitute another Bond and surety, both of which individual's or entity's own negligence. shall comply with the requirements of paragraphs 5.01.B and 5.02. H. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold 5.02 Licensed Sureties and Insurers harmless OWNER, ENGINEER, ENGINEER's Consultants, and the officers, directors, partners, employees, agents, other- A. All Bonds and insurance required by the Contract consultants, and subcontractors of each and any of them from Documents to be purchased and maintained by OWNER or and against all claims, costs, losses, and damages (including CONTRACTOR shall be obtained from surety or insurance but not Iimited to all fees and charges of engineers, architects, companies that are duly licensed or authorized in the attorneys, and other professionals and all court or arbitration jurisdiction in which the Project is located to issue Bonds or or other dispute resolution costs) arising out of or relating to a insurance policies for the limits and coverages so required. Hazardous Environmental Condition created by Such surety and insurance companies shall also meet such CONTRACTOR or by anyone for whom CONTRACTOR is additional requirements and qualifications as may be provided responsible. Nothing in this paragraph 4.06.F shall obligate in the Supplementary Conditions. CONTRACTOR to indemnify any individual or entity from and against the consequences of that individual's or entity's 5,03 Certificates of Insurance own negligence. A. CONTRACTOR shall deliver to OWNER, with I. The provisions of paragraphs 4.02, 4.03, and 4.04 copies to each additional insured identified in the Supple - are not intended to apply to a Hazardous Environmental mentary Conditions, certificates of insurance (and other Condition uncovered or revealed at the Site. evidence of insurance requested by OWNER or any other additional insured) which CONTRACTOR is required to purchase and maintain. OWNER shall deliver to ARTICLE 5 - BONDS AND INSURANCE CONTRACTOR, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by 5.01 Performance; Payment, and Other Bonds CONTRACTOR or any other additional insured) which OWNER is required to purchase and maintain. A. CONTRACTOR shall fuish performance and payment Bonds, each in an amount at least equal to the 5.04 CONTRACTOR's Liability Insurance Contract Price as security for the faithful performance and payment of all CONTRACTOR's obligations under the A. CONTRACTOR shall purchase and maintain such Contract Documents. These Bonds shall iemain in effect at liability and other insurance as is appropriate for the Work least until one year after the date when final payment being performed and as will provide protection from claims becomes due, except as provided otherwise by Laws or set forth below which may arise out of or result from Regulations or by the Contract Documents. CONTRACTOR CONTRACTOR's performance of the Work and shall also furnish such other Bonds as are required by the CONTRACTOR's other obligations under the Contract Contract Documents. Documents, whether it is to be performed by -15- i CONTRACTOR, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to 3. include completed operations insurance; perform any of the Work, or by anyone for whose acts any of them may be liable: 4. include contractual liability insurance covering CONTRACTOR's indemnity obligations , 1. claims under workers' compensation, under paragraphs 6.07, 6.11, and 6.20; disability benefits, and other similar employee benefit acts; 5. contain a provision or endorsement that the coverage afforded will not be canceled, materially 2. claims for damages because of bodily changed or renewal refused until at least thirty days injury, occupational sickness or disease, or death of prior written notice has been given to OWNER and CONTRACTOR's employees; CONTRACTOR and to each other additional insured identified in the Supplementary Conditions to whom a 3. claims for damages because of bodily certificate of insurance has been issued (and the injury, sickness or disease, or death of any person certificates of insurance famished by the CONTRAC- other than CONTRACTOR's employees; TOR pursuant to paragraph 5.03 will so provide); 4. claims for damages insured by reasonably 6. remain in effect at least until final payment available personal injury liability coverage which are and at all times thereafter when CONTRACTOR may sustained: (i) by any person as a result of an offense be correcting, removing, or replacing defective Work directly or indirectly related to the employment of in accordance with paragraph 13.07; and such person by CONTRACTOR, or (ii) by any other person for any other reason; 7. with respect to completed operations insur- ance, and any insurance coverage written on a claims - 5. claims for damages, other than to the Work made basis, remain in effect for at least two years after itself, because of injury to or destruction of tangible final payment (and CONTRACTOR shall fiunish property wherever located, including loss of use OWNER and each other additional insured identified resulting therefrom; and in the Supplementary Conditions, to whom a certificate of insurance has been issued, evidence 6. claims for damages because of bodily satisfactory to OWNER and any such additional injury or death of any person or property damage insured of continuation of such insurance at final arising out of the ownership, maintenance or use of payment and one year thereafter). any motor vehicle. 5.05 OWNER's Liability Insurance B. The policies of insurance so required by this , paragraph 5.04 to be purchased and maintained shall; A. In addition to the insurance required to be provided by CONTRACTOR under paragraph 5.04, OWNER, at 1. with respect to insurance required by para- OWNER's option, may purchase and maintain at OWNER's graphs 5.04.A.3 through 5.04.A.6 inclusive, include as expense OWNER's own liability insuran as will protect additional insureds (subject to any customary exclu- OWNER against claims which may arise from operations sion in respect of professional liability) OWNER, under the Contract Documents. ENGINEER, ENGINEER's Consultants, and any other individuals or entities identified in the Supple- 5.06 Property Insurance mentary Conditions, all of whom shall be listed as additional insureds, and include coverage for the A. Unless otherwise provided in the Supplementary respective officers, directors, partners, employees, Conditions, OWNER shall purchase and maintain property agents, and other consultants and subcontractors of insurance upon the Work at the Site in the amount of the full each and any of all such additional insureds, and the replacement cost thereof (subject to such deductible amounts insurance afforded to these additional insureds shall as may be provided in the Supplementary Conditions or provide primary coverage for all claims covered requ by Laws and Regulations). This insurance shall: thereby' I. include the interests of OWNER, CON- 2. include at least the specific coverages and TRACTOR, Subcontractors, ENGINEER, be written for not less than the limits of liability ENGINEER's Consultants, and any other individuals provided in the Supplementary Conditions or required or entities identified in the Supplementary Conditions, by Laws or Regulations, whichever is greater; and the officers, directors, partners, employees, -16- agents, and other consultants and subcontractors of be canceled or materially changed or renewal refused until at each and any of them, each of whom is deemed to least 30 days prior written notice has been given to OWNER have an insurable interest and shall be listed as an and CONTRACTOR and to each other additional insured to additional insured; whom a certificate of insurance has been issued and will contain waiver provisions in accordance with paragraph 5.07. 2. be written on a Builder's Risk "all -risk" or open peril or special causes of loss policy form that D. OWNER shall not be responsible for purchasing and shall at least include insurance. for physical loss or maintaining any property insurance specified in this damage to the Work, temporary buildings, false work, paragraph 5.06 to protect the interests of CONTRACTOR, and materials and equipment in transit, and shall Subcontractors, or others in the Work to the extent of any insure against at least the following perils or causes of deductible amounts that are identified in the Supplementary loss: fire, lightning, extended coverage, theft, vandal- Conditions. The risk of loss within such identified deductible ism and malicious mischief, earthquake, collapse, amount will be borne by CONTRACTOR, Subcontractors, or debris removal, demolition occasioned by en- others suffering any such loss, and if any of them wishes forcement of Laws and Regulations, water damage, property insurance coverage within the limits of such and such other perils or causes of loss as may be amounts, each may purchase and maintain it at the specifically required by the Supplementary purchaser's own expense. Conditions; E. If CONTRACTOR requests in writing that other 3. include expenses incurred in the repair or special insurance be included in the property insurance replacement of any insured property (including but not policies provided under paragraph 5.06, OWNER shall, if limited to fees and charges of engineers and archi- possible, include such insurance, and the cost thereof will be tects); charged to CONTRACTOR by appropriate Change Order or Written Amendment. Prior to commencement of the Work at 4. cover materials and equipment stored at the the Site, OWNER shall in writing advise CONTRACTOR Site or at another location that was agreed to in whether or not such other insurance has been procured by writing by OWNER prior to being incorporated in the OWNER Work, provided that such materials and equipment have been included in an •Application for Payment 5.07 Waiver of Rights recommended by ENGINEER; A. OWNER and CONTRACTOR intend that all 5. allow for partial utilization of the Work by policies purchased in accordance with paragraph 5.06 will OWNER; protect OWNER, CONTRACTOR, Subcontractors, ENGINEER, ENGINEER's Consultants, and all other 6. include testing and startup; and individuals or entities identified in the Supplementary Condi- tions to be listed as insureds or additional insureds (and the 7. be maintained in effect until final payment officers, directors, partners, employees, agents, and other is made unless otherwise agreed to in writing by consultants and subcontractors of each and any of them) in OWNER, CONTRACTOR, and ENGINEER with 30 such policies and will provide primary coverage for all losses days written notice to each other additional insured to and damages caused by the perils or causes of loss covered whom a certificate of insurance has been issued. thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the B. OWNER shall purchase and maintain such boiler insurers will have no rights of recovery against any of the and machinery insurance or additional property insurance as insureds or additional insureds thereunder. OWNER and may be required by the Supplementary Conditions or Laws CONTRACTOR waive all rights against each other and their and Regulations which will include the interests of OWNER, respective officers, directors, partners, employees, agents, and CONTRACTOR, Subcontractors, ENGINEER, other consultants and subcontractors of each and any of them ENGINEER's Consultants, and any other individuals or for all losses and damages caused by, arising out of or entities identified in the Supplementary Conditions, each of resulting from any of the perils or causes of loss covered by whom is deemed to have an insurable interest and shall be such policies and any other property insurance applicable to listed as an insured or additional insured. the Work; and, in addition, waive all such rights against Subcontractors, ENGINEER, ENGINEER's Consultants, and C. All the policies of insurance (and the certificates or all other individuals or entities identified in the Supplemen- other evidence thereof) required to be purchased and tary Conditions to be listed as insureds or additional insureds maintained in accordance with paragraph 5.06 will contain a (and the officers, directors, partners, employees, agents, and provision or endorsement that the coverage afforded will not other consultants and subcontractors of each and any of them) -17- under such policies for losses and damages so caused. None such objection be made, OWNER as fiduciary shall make of the above waivers shall extend to the rights that any party settlement with the insurers in accordance with such making such waiver may have to the proceeds of insurance agreement as the parties in interest may reach. If no such held by OWNER as trustee or otherwise payable under any agreement among the parties in interest is reached, OWNER policy so issued. as fiduciary shall adjust and settle the loss with the insurers ' and, if required in writing by any party in interest, OWNER B. OWNER waives all rights against CONTRACTOR, as fiduciary shall give bond for the proper performance of Subcontractors, ENGINEER, ENGINEER's Consultants, and such duties. the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them for: 5.09 Acceptance of Bonds and Insurance; Option to Replace 1. loss due to business interruption, loss of use, or other consequential loss extending beyond A. If either OWNER or CONTRACTOR has any direct physical loss or damage to OWNER's property objection to the coverage afforded by or other provisions of or the Work caused by, arising out of, or resulting the Bonds or insurance required to be purchased and from fire or other peril whether or not insured by maintained by the other party in accordance with Article 5 on ' OWNER; and the basis of non - conformance with the Contract Documents, the objecting party shall so notify the other party in writing 2. loss or damage to the completed Project or within 10 days after receipt of the certificates (or other part thereof caused by, arising out of, or resulting from evidence requested) required by paragraph 2.05.C. OWNER , fire or other insured peril or cause of loss covered by and CONTRACTOR shall each provide to the other such any property insurance maintained on the completed additional information in respect of insurance provided as the Project or part thereof by OWNER during partial other may reasonably request. If either party does not utilization pursuant to paragraph 14.05, after Substan- purchase or maintain all of the Bonds and insurance required tial Completion pursuant to paragraph 14.04, or after of such party by the Contract Documents, such party shall final payment pursuant to paragraph 14.07. notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain C. Any insurance policy maintained by OWNER prior to any change in the required coverage. Without covering any loss, damage or consequential loss referred to in prejudice to any other right or remedy, the other party may paragraph 5.07.B shall contain provisions to the effect that in elect to obtain equivalent Bonds or insurance to protect such the event of payment of any such loss, damage, or other party's interests at the expense of the party who was consequential loss, the insurers will have no rights of required to provide such coverage, and a Change Order shall recovery against CONTRACTOR, Subcontractors, be issued to adjust the Contract Price accordingly. ENGINEER, or ENGINEER's Consultants and the officers, directors, partners, employees, agents, and other consultants 5.10 Partial Utilization, Acknowledgment of Property and subcontractors of each and any of them. Insurer 5.08 Receipt and Application oflnsurance Proceeds A. If OWNER finds it necessary to occupy or use a portion or portions of the Work prior to Substantial A. Any insured loss under the policies of insurance Completion of all the Work as provided in paragraph 14.05, required by paragraph 5.06 will be adjusted with OWNER no such use or occupancy shall commence before the insurers and made payable to OWNER as fiduciary for the insureds, providing the property insurance pursuant to paragraph 5.06 as their interests may appear, subject to the requirements of have acknowledged notice thereof and in writing effected any any applicable mortgage clause and of paragraph 5.08.B. changes in coverage necessitated thereby. The insurers OWNER shall deposit in a separate account any money so providing the property insurance shall consent by endorse - received and shall distribute it in accordance with such agree - ment on the policy or policies, but the property insurance ment as the parties in interest may reach. If no other special shall not be canceled or permitted to lapse on account of any agreement is reached, the damaged Work shall be repaired or such partial use or occupancy. replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES Change Order or Written Amendment. B. OWNER as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in 6.01 Supervision and Superintendence interest shall object in writing within 15 days after the occurrence of loss to OWNER's exercise of this power. If -18- A. CONTRACTOR shall supervise, inspect, and direct B. All materials and equipment incorporated into the the Work competently and efficiently, devoting such attention Work shall be as specified or, if specified, shall be of thereto and applying such skills and expertise as may be good quality and new, except as otherwise provided in the necessary to perform the Work in accordance with the Contract Documents. All warranties and guarantees Contract Documents. CONTRACTOR shall be solely specifically called for by the Specifications shall expressly responsible for the means, methods, techniques, sequences, run to the benefit of OWNER. If required by ENGINEER, and procedures of construction, but CONTRACTOR shall not CONTRACTOR shall furnish satisfactory evidence be responsible for the negligence of OWNER or ENGINEER (including reports of required tests) as to the source, kind, and in the design or specification of a specific means, method, quality of materials and equipment. All materials and technique, sequence, or procedure of construction which is equipment shall be stored, applied, installed, connected, shown or indicated in and expressly required by the Contract erected, protected, used, cleaned, and conditioned in Documents. CONTRACTOR shall be responsible to see that accordance with instructions of the applicable Supplier, the completed Work complies accurately with the Contract except as otherwise may be provided in the Contract Docu- Documents. mens. B. At all times during the progress of the Work, 6.04 Progress Schedule CONTRACTOR shall assign a competent resident superin- tendent thereto who shall not be replaced without written A. CONTRACTOR shall adhere to the progress notice to OWNER and ENGINEER except under schedule established in accordance with paragraph 2.07 as it extraordinary circumstances. The superintendent will be may be adjusted from time to time as provided below. CONTRACTOR's representative at the Site and shall have authority to act on behalf of CONTRACTOR. All 1. CONTRACTOR shall submit to ENGI- communications given to or received from the superintendent NEER for acceptance (to the extent indicated in shall be binding on CONTRACTOR. paragraph 2.07) proposed adjustments in the progress schedule that will not result in changing the Contract 6.02 Labor; Working Hours Times (or Milestones). Such adjustments will conform generally to the progress schedule then in A. CONTRACTOR shall provide competent, suitably effect and additionally will comply with any provi- qualified personnel to survey, lay out, and construct the Work sions of the General Requirements applicable thereto. as required by the Contract Documents. CONTRACTOR shall at all times maintain good discipline and order at the 2. Proposed adjustments in the progress Site. schedule that will change the Contract Times (or Milestones) shall be submitted in accordance with the B. Except as otherwise required for the safety or requirements of Article 12. Such adjustments may protection of persons or the Work or property at the Site or only be made by a Change Order or Written Amend - adjacent thereto, and except as otherwise stated in the ment in accordance with Article 12. Contract Documents, all Work at the Site shall be performed during regular working hours, and CONTRACTOR will not 6.05 Substitutes and "Or- Equals" permit overtime work or the performance of Work on Saturday, Sunday, or any legal holiday without OWNER's A. Whenever an item of material or equipment is written consent (which will not be unreasonably withheld) specified or described in the Contract Documents by using the given after prior written notice to ENGINEER. name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. 6.03 Services, Materials, and Equipment Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or- equal" item A. Unless otherwise specified in the General Re- or no substitution is permitted, other items of material or quirements, CONTRACTOR shall provide and assume full equipment or - material or equipment of other Suppliers may responsibility for all services, materials, equipment, labor, be submitted to ENGINEER for review under the circum- transportation, construction equipment and machinery, tools, stances described below. appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and 1. "Or-Equal " Items: If in ENGINEER's sole incidentals necessary for the performance, testing, start-up, discretion an item of material or equipment proposed ' and completion of the Work. by CONTRACTOR is fiurctionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by _19- 1 ENGINEER as an "or- equal" item, in which case The application will state the extent, if any, to review and approval of the proposed item may, in which the use of the proposed substitute item will ENGINEER's sole discretion, be accomplished prejudice CONTRACTOR's achievement of without compliance with some or all of the require- Substantial Completion on time, whether or not ments for approval of proposed substitute items. For use of the proposed substitute item in the Work the purposes of this paragraph 6.05.A.1, a proposed will require a change in any of the Contract Docu- item of material or equipment will be considered ments (or in the provisions of any other direct functionally equal to an item so named if contract with OWNER for work on the Project) to adapt the design to the proposed substitute item a. in the exercise of reasonable judgment and whether or not incorporation or use of the ENGINEER determines that: (i) it is at least equal proposed substitute item in connection with the in quality, durability, appearance, strength, and Work is subject to payment of any license fee or design characteristics; (ii) it will reliably perform royalty. All variations of the proposed substitute at least equally well the function imposed by the item from that specified will be identified in the design concept of the completed Project as a application, and available engineering, sales, functioning whole, and; maintenance, repair, and replacement services will be indicated. The application will also contain an b. CONTRACTOR certifies that: (i) there is itemized estimate of all costs or credits that will no increase in cost to the OWNER; and (ii) it will result directly or indirectly from use of such conform substantially, even with deviations, to the substitute item, including costs of redesign and detailed requirements of the item named in the claims of other contractors affected by any Contract Documents. resulting change, all of which will be considered by ENGINEER in evaluating the proposed 2. Substitute Items substitute item. ENGINEER may require CON- TRACTOR to furnish additional data about the a. if in ENGINEER's sole discretion an item proposed substitute item. of material or equipment proposed by CON- TRACTOR does not qualify as an "or-equal" item B. Substitute Construction Methods or procedures: If under paragraph 6.05.A.1, it will be considered a a specific means, method, technique, sequence, or procedure proposed substitute item. of construction is shown or indicated in and expressly required by the Contract Documents, CONTRACTOR may b. CONTRACTOR shall submit sufficient furnish or utilize a substitute means, method, technique, information as provided below to allow ENGI- sequence, or procedure of construction approved by ENGI- NEER to determine that the item of material or NEER. CONTRACTOR shall submit sufficient information equipment proposed is essentially equivalent to to allow ENGINEER, in ENGINEER's sole discretion, to that named and an acceptable substitute therefor. determine that the substitute proposed is equivalent to that Requests for review of proposed substitute items expressly called for by the Contract Documents. The proce- of material or equipment will not be accepted by dure for review by ENGINEER will be similar to that ENGINEER from anyone other than CON- provided in subparagraph 6.05 -A -2. TRACTOR. C. Engineer's Evaluation: ENGINEER will be c. The procedure for review by ENGINEER allowed a reasonable time within which to evaluate each will be as set forth in paragraph 6.05.A.2.d, as proposal or submittal made pursuant to paragraphs 6.05.A supplemented in the General Requirements and as and 6.05.13. ENGINEER will be the sole judge of accept - ENGINEER may decide is appropriate under the ability. No "or-equal' or substitute will be ordered, installed circumstances. or utilized until ENGINEER's review is complete, which will be evidenced by either a Change Order for a substitute or an d. CONTRACTOR shall first make written approved Shop Drawing for an "or equal." ENGINEER will application to ENGINEER for review of a advise CONTRACTOR in writing of any negative proposed substitute item of material or equipment determination. that CONTRACTOR seeks to famish or use. The application shall certify that the proposed substi- D. Special Guarantee: OWNER may require CON - tute item will perform adequately the functions TRACTOR to famish at CONTRACTOR's expense a special and achieve the results called for by the general performance guarantee or other surety with respect to any design, be similar in substance to that specified, substitute. and be suited to the same use as that specified. r -20- r r E. ENGINEER's Cost Reimbursement: ENGINEER create for the benefit of any such Subcontractor, Supplier, or will record time required by ENGINEER and ENGINEER's other individual or entity any contractual relationship between Consultants in evaluating substitute proposed or submitted by OWNER or ENGINEER and any such Subcontractor, CONTRACTOR pursuant to paragraphs 6.05.A.2 and 6.05.E Supplier or other individual or entity, nor shall it create any and in making changes in the Contract Documents (or in the obligation on the part of OWNER or ENGINEER to pay or to provisions of any other direct contract with OWNER for see to the payment of any moneys due any such Subcon- work on the Project) occasioned thereby. Whether or not tractor, Supplier, or other individual or entity except as may ENGINEER approves a substitute item so proposed or otherwise be required by Laws and Regulations. submitted by CONTRACTOR, CONTRACTOR shall reimburse OWNER for the charges of ENGINEER and D. CONTRACTOR shall be solely responsible for ENGINEER's Consultants for evaluating each such proposed scheduling and coordinating the Work of Subcontractors, substitute. Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract F. CONTRACTOR's Expense: CONTRACTOR shall with CONTRACTOR. provide all data in support of any proposed substitute or "or- equal" at CONTRACTOR's expense. E. CONTRACTOR shall require all Subcontractors, Suppliers, and such other individuals or entities performing or 6.06 Concerning Subcontractors, Suppliers, and Others furnishing any of the Work to communicate with ENGI- NEER through CONTRACTOR. A. CONTRACTOR shall not employ any Subcon- tractor, Supplier, or other individual or entity (including those F. The divisions and sections of the Specifications and acceptable to OWNER as indicated in paragraph 6.06.B), the identifications of any Drawings shall not control whether initially or as a replacement, against whom OWNER CONTRACTOR in dividing the Work among Subcontractors may have reasonable objection. CONTRACTOR shall not be or Suppliers or delineating the Work to be performed by any required to employ any Subcontractor, Supplier, or other specific trade. individual or entity to fumish or perform any of the Work against whom CONTRACTOR has reasonable objection. G. All Work performed for CONTRACTOR by a Subcontractor or Supplier will be pursuant to an appropriate B. If the Supplementary Conditions require the identity agreement between CONTRACTOR and the Subcontractor of certain Subcontractors, Suppliers, or other individuals or or Supplier which specifically binds the Subcontractor or entities to be submitted to OWNER in advance for acceptance Supplier to the applicable terms and conditions of the by OWNER by a specified date prior to the Effective Date of Contract Documents for the benefit of OWNER and the Agreement, and if CONTRACTOR has submitted a list ENGINEER. Whenever any such agreement is with a thereof in accordance with the Supplementary Conditions, Subcontractor or Supplier who is listed as an additional OWNER's acceptance (either in writing or by failing to make insured on the property insurance provided in paragraph 5.06, written objection thereto by the date indicated for acceptance the agreement between the CONTRACTOR and the or objection in the Bidding Documents or the Contract Subcontractor or Supplier will contain provisions whereby Documents) of any such Subcontractor, Supplier, or other the Subcontractor or Supplier waives all rights against individual or entity so identified may be revoked on the basis OWNER, CONTRACTOR, ENGINEER, ENGINEER's of reasonable objection after due investigation. CON- Consultants, and all other individuals or entities identified in TRACTOR shall submit an acceptable replacement for the the Supplementary Conditions to be listed as insureds or rejected Subcontractor, Supplier, or other individual or entity, additional insureds (and the officers, directors, partners, and the Contract Price will be adjusted by the difference in employees, agents, and other consultants and subcontractors the cost occasioned by such replacement, and an appropriate of each and any of them) for all losses and damages caused Change Order will be issued or Written Amendment signed. by, arising out of, relating to, or resulting from any of the No acceptance by OWNER of any such Subcontractor, perils or causes of loss covered by such policies and any other Supplier, or other individual or entity, whether initially or as a property insurance applicable to the Work. If the insurers on replacement, shall constitute a waiver of any right of any such policies require separate waiver forms to be signed OWNER or ENGINEER to reject defective Work. by any Subcontractor or Supplier, CONTRACTOR will obtain the same. C. CONTRACTOR shall be fully responsible to OWNER and ENGINEER for all acts and omissions of the 6.07 Patent Fees and Royalties Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as A. CONTRACTOR shall pay all license fees and CONTRACTOR is responsible for CONTRACTOR's own royalties and assume all costs incident to the use in the acts and omissions. Nothing in the Contract Documents shall performance of the Work or the incorporation in the Work of r -21- r r any invention, design, process, product, or device which is the responsibility to make certain that the Specifications and subject of patent rights or copyrights held by others. If a Drawings are in accordance with Laws and Regulations, but , particular invention, design, process, product, or device is this shall not relieve CONTRACTOR of CONTRACTOR's specified in the Contract Documents for use in the obligations under paragraph 3.03. performance of the Work and if to the actual knowledge of OWNER or ENGINEER its use is subject to patent rights or C. Changes in Laws or Regulations not known at the copyrights calling for the payment of any license fee or time of opening of Bids (or, on the Effective Date of the royalty to others, the existence of such rights shall be Agreement if there were no Bids) having an effect on the cost disclosed by OWNER in the Contract Documents. To the or time of performance of the Work may be the subject of an fullest extent permitted by Laws and Regulations, adjustment in Contract Price or Contract Times. If OWNER CONTRACTOR shall indemnify and hold harmless and CONTRACTOR are unable to agree on entitlement to or OWNER, ENGINEER, ENGINEER's Consultants, and the on the amount or extent, if any, of any such adjustment, a officers, directors, partners, employees or agents, and other Claim may be made therefor as provided in paragraph 10.05. consultants of each and any of them from and against all claims, costs, losses, and damages (including but not limited 6.10 Taxes to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute A. CONTRACTOR shall pay all sales, consumer, use, resolution costs) arising out of or relating to any infringement and other similar taxes required to be paid by CONTRAC- of patent rights or copyrights incident to the use in the TOR in accordance with the Laws and Regulations of the performance of the Work or resulting from the incorporation place of the Project which are applicable during the ' in the Work of any invention, design, process, product, or performance of the Work. device not specified in the Contract Documents. 6.11 Use of Site and Other Areas 6.08 Permits A. Limitation on Use of Site and Other Areas A. Unless otherwise provided in the Supplementary Conditions, CONTRACTOR shall obtain and pay for all 1. CONTRACTOR shall confine construction construction permits and licenses. OWNER shall assist equipment, the storage of materials and equipment, CONTRACTOR, when necessary, in obtaining such permits and the operations of workers to the Site and other and licenses. CONTRACTOR shall pay all governmental areas permitted by Laws and Regulations, and shall charges and inspection fees necessary for the prosecution of not unreasonably encumber the Site and other areas the Work which are applicable at the time of opening of Bids, with construction equipment or other materials or or, if there are no Bids, on the Effective Date of the equipment. CONTRACTOR shall assume full Agreement. CONTRACTOR shall pay all charges of utility responsibility for any damage to any such land or area, owners for connections to the Work, and OWNER shall pay or to the owner or occupant thereof, or of any adjacent all charges of such utility owners for capital costs related land or areas resulting from the performance of the thereto, such as plant investment fees. Work. 6.09 Laws and Regulations 2. Should any claim be made by any such owner or occupant because of the performance of the A. CONTRACTOR shall give all notices and comply Work, CONTRACTOR shall promptly settle with with all Laws and Regulations applicable to the performance such other party by negotiation or otherwise resolve of the Work. Except where otherwise expressly required by the claim by arbitration or other dispute resolution applicable Laws and Regulations, neither OWNER nor proceeding or at law. ENGINEER shall be responsible for monitoring CONTRACTOR's compliance with any Laws or 3. To the fullest extent permitted by Laws and Regulations. Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's B. If CONTRACTOR performs any Work knowing or Consultant, and the officers, directors, partners, having reason to know that it is contrary to Laws or employees, agents, and other consultants of each and ' Regulations, CONTRACTOR shall bear "all claims, costs, any of them from and against all claims, costs, losses, losses, and damages (including but not limited to all fees and and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute professionals and all court or arbitration or other resolution costs) arising out of or relating to such Work; dispute resolution costs) arising out of or relating to however, it shall not be CONTRACTOR's primary any claim or action, legal or equitable, brought by any r -22- r such owner or occupant against OWNER, ENGINEER, or any other party indemnified 3. other property at the Site or adjacent hereunder to the extent caused by or based upon thereto, including trees, shrubs, lawns, walks, pave - CONTRACTOR's performance of the Work. ments, roadways, structures, utilities, and Under- ' ground Facilities not designated for removal, reloca- B. Removal of Debris During Performance of the lion, or replacement in the course of construction. Work: During the progress of the Work CONTRACTOR shall keep the Site and other areas free from accumulations of B. CONTRACTOR shall comply with all applicable waste materials, rubbish, and other debris. Removal and Laws and Regulations relating to the safety of persons or disposal of such waste materials, rubbish, and other debris property, or to the protection of persons or property from shall conform to applicable Laws and Regulations, damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. C. Cleaning.- Prior to Substantial Completion of the CONTRACTOR shall notify owners of adjacent property and Work CONTRACTOR shall clean the Site and make it ready of Underground Facilities and other utility owners when for utilization by OWNER. At the completion of the Work prosecution of the Work may affect them, and shall cooperate CONTRACTOR shall remove from the Site all tools, with them in the protection, removal, relocation, and appliances, construction equipment and machinery, and replacement of their property. All damage, injury, or loss to surplus materials and shall restore to original condition all any property referred to in paragraph 6.13.A.2 or 6.13.A.3 property not designated for alteration by the Contract caused, directly or indirectly, in whole or in part, by CON- , Documents. TRACTOR, any Subcontractor, Supplier, or any other individual or entity d or indirectly employed by any of D. Loading Structures: - CONTRACTOR shall not load them to perform any of the Work, or anyone for whose acts nor permit any part of any structure to be loaded in any any of them may be liable, shall be remedied by manner that will endanger the structure, nor shall- CONTRACTOR (except damage or loss attributable to the CONTRACTOR subject any part of the Work or adjacent fault of Drawings or Specifications or to the acts or omissions property to stresses or pressures that will endanger it. of OWNER or ENGINEER or ENGINEER's Consultant, or 1 anyone employed by any of them, or anyone for whose acts 6.12 Record Documents any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of A. CONTRACTOR shall maintain in a safe place at the CONTRACTOR or any Subcontractor, Supplier, or other Site one record copy of all Drawings, Specifications, individual or entity directly or indirectly employed by any of Addenda, Written Amendments, Change Orders, Work them). CONTRACTOR's duties and responsibilities for Change Directives, Field Orders, and written interpretations safety and for protection of the Work shall. continue until such and clarifications in good order and annotated to show time as all the Work is completed and ENGINEER has issued changes made during construction. These record documents a notice to OWNER and CONTRACTOR in accordance with together with all approved Samples and a counterpart of all paragraph 14.07.B that the Work is acceptable (except as approved Shop Drawings will be available to ENGINEER for otherwise expressly provided in connection with Substantial ' reference. Upon completion of the Work, these record Completion). documents, Samples, and Shop Drawings will be delivered to ENGINEER for OWNER 6.14 Safety Representative 6.13 Safety and Protection A. CONTRACTOR shall designate a qualified and experienced safety representative at the Site whose duties and A. CONTRACTOR shall be solely responsible for responsibilities shall be the prevention of accidents and the initiating, maintaining and supervising all safety precautions maintaining and supervising of safety precautions and and programs in connection with the Work. CONTRACTOR programs. shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or 6.15 Hazard Communication Programs 1 loss to: _ A. CONTRACTOR shall be responsible for coordi- I. all persons on the Site or who may be nating any exchange of material safety data sheets or other affected by the Work; hazard communication information required to be made available to or exchanged between or among employers at the 2. all the Work and materials and equipment Site in accordance with Laws or Regulations. to be incorporated therein, whether in storage on or off the Site; and 1 -23- I� 6.16 Emergencies a. all field measurements, quantities, dimen- sions, specified performance criteria, installation , A. in emergencies affecting the safety or protection of requirements, materials, catalog numbers, and persons or the Work or property at the Site or adjacent similar information with respect thereto; thereto, CONTRACTOR is obligated to act to prevent , threatened damage, injury, or loss. CONTRACTOR shall b. all materials with respect to intended use, give ENGINEER prompt written notice if CONTRACTOR fabrication, shipping, handling, storage, assembly, believes that any significant changes in the Work or and installation pertaining to the performance of variations from the Contract Documents have been caused the Work; thereby or are required as a result thereof. If ENGINEER determines that a change in the Contract Documents is c. all information relative to means, methods, required because of the action taken by CONTRACTOR in techniques, sequences, and procedures of construc- response to such an emergency, a Work Change Directive or tion and safety precautions and programs incident Change Order will be issued. thereto; and 6.17 Shop Drawings and Samples d. CONTRACTOR shall also have reviewed ' and coordinated each Shop Drawing or Sample A. CONTRACTOR shall submit Shop Drawings to with other Shop Drawings and Samples and with ENGINEER for review and approval in accordance with the the requirements of the Work and the Contract acceptable schedule of Shop Drawings and Sample Documents. ' submittals. All submittals will be identified as ENGINEER may require and in the number of copies specified in the 2. Each submittal shall bear a stamp or specif- General Requirements. The data shown on the Shop is written indication that CONTRACTOR has satis- Drawings will be complete with respect to quantities, dimen- fied CONTRACTOR's obligations under the Contract ' sions, specified performance and design criteria, materials, Documents with respect to CONTRACTOR's review and similar data to show ENGINEER the services, materials, and approval of that submittal. and equipment CONTRACTOR proposes to provide and to enable ENGINEER to review the information for the limited 3. At the time of each submittal, CONTRAC- TOR shall give ENGINEER specific written notice of purposes required by paragraph 6.17.E. such variations, if any, that the Shop Drawing or B. CONTRACTOR shall also submit Samples to Sample submitted may have from the requirements of ENGINEER for review and approval in accordance with the the Contract Documents, such notice to be in a written acceptable schedule of Shop Drawings and Sample communication separate from the submittal; and, in submittals. Each Sample will be identified clearly as to addition, shall cause a specific notation to be made on material, Supplier, pertinent data such as catalog numbers, each Shop Drawing and Sample submitted to ENGI- and the use for which intended and otherwise as ENGINEER NEER for review and approval of each such variation. may require to enable ENGINEER to review the submittal for the limited purposes required by paragraph 6.17.E. The E. ENGINEER's Review numbers of each Sample to be submitted will be as specified in the Specifications. 1. ENGINEER will timely review and approve Shop Drawings and Samples in accordance C. Where a Shop Drawing or Sample is required by the with the schedule of Shop Drawings and Sample Contract Documents or the schedule of Shop Drawings and submittals acceptable to ENGINEER. ENGINEER's Sample submittals acceptable to ENGINEER as required by review and approval will be only to determine if the paragraph 2.07, any related Work perfotmed prior to items covered by the submittals will, after installation ENGINEER's review and approval of the pertinent submittal or incorporation in the Work, conform to the ' will be at ' the sole expense and responsibility of information given in the Contract Documents and be CONTRACTOR. compatible with the design concept of the completed Project as a functioning whole as indicated by the D. Submittal Procedures Contract Documents. ' 1. Before submitting each Shop Drawing or 2. ENGINEER's review and approval will not Sample, CONTRACTOR shall have determined and extend to means, methods, techniques, sequences, or , verified: procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by i -24- ' the Contract Documents) or to safety precautions or programs incident thereto. The review and approval B. CONTRACTOR's obligation to perform and of a separate item as such will not indicate approval of complete the Work in accordance with the Contract the assembly in which the item functions. Documents shall be absolute. None of the following will ' constitute an acceptance of Work that is not in accordance 3. ENGINEER's review and approval of with the Contract Documents or a release of Shop Drawings or Samples shall not relieve CON- CONTRACTOR's obligation to perform the Work in TRACTOR from responsibility for any variation from accordance with the Contract Documents: the requirements of the Contract Documents unless CONTRACTOR has in writing called ENGINEER's 1. observations by ENGINEER; attention to each such variation at the time of each submittal as required by paragraph 6.17.D.3 and 2. recommendation by ENGINEER or pay - ENGINEER has given written approval of each such ment by OWNER of any progress or final payment; variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or 3. the issuance of a certificate of Substantial Sample approval; nor will any approval by Completion by ENGINEER or any payment related ENGINEER relieve CONTRACTOR from thereto by OWNER; responsibility for complying with the requirements of paragraph 6.17.D.1. 4. use or occupancy of the Work or any part thereof by OWNER; F. Resubmittal Procedures 5. any acceptance by OWNER or any failure ' 1. CONTRACTOR shall make corrections to do so; required by ENGINEER and shall return the required number of corrected copies of Shop Drawings and 6. any review and approval of a Shop Draw - submit as required new Samples for review and ing or Sample submittal or the issuance of a notice of approval. CONTRACTOR shall direct specific acceptability by ENGINEER; attention in writing to revisions other than the corrections called for by ENGINEER on previous 7. any inspection, test, or approval by others; submittals. or 6.18 Continuing the Work 8. any correction of defective Work by OWN- ER. A. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements 6.20 Indemnification with OWNER No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except A. To the fullest extent permitted by Laws and Regula- as permitted by paragraph 15.04 or as OWNER and lions, CONTRACTOR shall indemnify and hold harmless CONTRACTOR may otherwise agree in writing. OWNER, ENGINEER, ENGINEER's Consultants, and the officers, directors, partners, employees, agents, and other 6.19 CONTRACTOR's General Warranty and Guaran- consultants and subcontractors of each and any of them from tee and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, A. CONTRACTOR warrants and guarantees to attorneys, and other professionals and all court or arbitration OWNER, ENGINEER, and ENGINEER's Consultants that or other dispute resolution costs) arising out of or relating.to ' all Work will be in accordance with the Contract Documents the performance of the Work, provided that any such claim, and will not be defective. CONTRACTOR's warranty and cost, loss, or damage: guarantee hereunder excludes defects or damage caused by: ' I. is attributable to bodily injury, sickness, 1. abuse, modification, or improper main- disease, or death, or to injury to or destruction of tenance or operation by persons other than CON - tangible property (other than the Work itself), includ- TRACTOR, Subcontractors, Suppliers, or any other ing the loss of use resulting therefrom; and individual or entity for whom CONTRACTOR is responsible; or 2. is caused in whole or in part by any negli- gent act or omission of CONTRACTOR, any Sub - 2. normal wear and tear under normal usage. contractor, any Supplier, or any individual or entity 25 directly or indirectly employed by any of them to 2. if OWNER and CONTRACTOR are perform any of the Work or anyone for whose acts any unable to agree on entitlement to or on the amount or of them may be liable, regardless of whether or not extent, if any, of any adjustment in the Contract Price caused in part by any negligence or omission of an or Contract Times that should be allowed as a result of individual or entity indemnified hereunder or whether such other work, a Claim may be made therefor as ' liability is imposed upon such indemnified party by provided in paragraph 10.05. Laws and Regulations regardless of the negligence of any such individual or entity. B. CONTRACTOR shall afford each other contractor who is a party to such a'direct contract and each utility owner B. In any arid all claims against OWNER or ENGI- (and OWNER, if OWNER is perforating the other work with NEER or any of their respective consultants, agents, officers, OWNER's employees) proper and safe access to the Site and directors, partners, or employees by any employee (or the a reasonable opportunity for the introduction and storage of survivor or personal representative of such employee) of materials and equipment and the execution of such other ' CONTRACTOR, any Subcontractor, any Supplier, or any work and shall properly coordinate the Work with theirs. individual or entity directly or indirectly employed by any of Unless otherwise provided in the Contract Documents, CON - them to perform any of the Work, or anyone for whose acts TRACTOR shall do all cutting, fitting, and patching of the any of them may be liable, the indemnification obligation Work that may be required to properly connect or otherwise under paragraph 6.20.A shall not be limited in any way by make its several parts come together and properly integrate any limitation on the amount or type of damages, with such other work. CONTRACTOR shall not endanger compensation, or benefits payable by or for CONTRACTOR any work of others by cutting, excavating, or otherwise or any such Subcontractor, Supplier, or other individual or altering their work and will only cut or alter their work with entity under workers' compensation acts, disability benefit the written consent of ENGINEER and the others whose acts, or other employee benefit acts. work will be affected. The duties and responsibilities of CONTRACTOR under this paragraph are for the benefit of ' C. The indemnification obligations of CONTRACTOR such utility owners and other contractors to the extent that under paragraph 6.20.A shall not extend to the liability of there are comparable provisions for the benefit of ENGINEER and ENGINEER's Consultants or to the officers, CONTRACTOR in said direct contracts between OWNER directors, partners, employees, agents, and other consultants and such utility owners and other contractors. and subcontractors of each and any of them arising out of: C. If the proper execution or results of any part of 1. the preparation or approval of, or the CONTRACTOR's Work depends upon work performed by failure to prepare or approve, maps, Drawings, others under this Article 7, CONTRACTOR shall inspect opinions, reports, surveys, Change Orders, designs, or such other work and promptly report to ENGINEER in Specifications; or writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper 2. giving directions or instructions, or failing execution and results of CONTRACTOR's Work. to give them, if that is the primary cause of the injury CONTRACTOR's failure to so report will constitute an or damage. acceptance of such other work as fit and proper for integration with CONTRACTOR's Work except for latent , defects and deficiencies in such other work. ARTICLE 7 - OTHER WORK 7.02 Coordination 7.01 Related Work at Site A. If OWNER intends to contract with others for the performance of other work on the Project at the Site, the A. OWNER may perform other work related to the following will be set forth in Supplementary Conditions: ' Project at the Site by OWNER's employees, or let other direct contracts therefor, or have other work performed by utility 1. the individual or entity who will have authority and responsibility for coordination of the owners. If such other work is not noted_ in the Contract Documents, then: activities among the various contractors will be ' identified; 1. written notice thereof will be given to CONTRACTOR prior to starting any such other 2. the specific matters to be covered by such , authority and responsibility will be itemized; and work; and -26- ' 3. the extent of such authority and responsi- A. OWNER is obligated to execute Change Orders as bilities will be provided. indicated in paragraph 10.03. B. Unless otherwise provided in the Supplementary 8.08 Inspections, Tests, and Approvals ' Conditions, OWNER shall have sole authority and respon- sibility for such coordination. A. OWNER's responsibility in respect to certain inspections, tests, and approvals is set forth in paragraph 13.03.B. ARTICLE 8 - OWNER'S RESPONSIBILITIES 8.09 Limitations on OWNER's Responsibilities 8.01 Communications to Contractor A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for, A. Except as otherwise provided in these General CONTRACTOR's means, methods, techniques, sequences, Conditions, OWNER shall issue all communications to or procedures of construction, or the safety precautions and CONTRACTOR through ENGINEER. programs incident thereto, or for any failure of CON- TRACTOR to comply with Laws and Regulations applicable 8.02 Replacement of ENGINEER to the performance of the Work OWNER will not be responsible for CONTRACTOR's failure to perform the A. In case of termination of the employment of ENGI- Work in accordance with the Contract Documents. NEER, OWNER shall appoint an engineer to whom CONTRACTOR makes no reasonable objection, whose 8.10 Undisclosed Hazardous Environmental Condition status under the Contract Documents shall be that of the former ENGINEER. A. OWNER's responsibility in respect to an undis- closed Hazardous Environmental Condition is set forth in 8.03 Furnish Data paragraph 4.06. A. OWNER shall promptly furnish the data required of 8.11 Evidence of Financial Arrangements OWNER under the Contract Documents. A. If and to the extent OWNER has agreed to famish 8.04 Pay Promptly When Due CONTRACTOR reasonable evidence that financial arrangements have been made to satisfy OWNER's A. OWNER shall make payments to CONTRACTOR obligations under the Contract Documents, OWNER's promptly when they are due as provided in paragraphs responsibility in respect thereof will be as set forth in the 14.02.0 and 14.07.C. Supplementary Conditions. 8.05 Lands and Easements; Reports and Tests ' ARTICLE 9 - ENGINEER'S STATUS DURING A. OWNER's duties in respect of providing lands and CONSTRUCTION easements and providing engineering surveys to establish reference points are set forth in paragraphs 4.01 and 4.05. Paragraph 4.02 refers to OWNER's identifying and making 9.01 OWNER'S Representative available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions and drawings of physical A. ENGINEER will be OWNEWs representative conditions in or relating to existing surface or subsurface during the construction period. The duties and responsi- structures at or contiguous to the Site that have been utilized bilities and the limitations of authority of ENGINEER as by ENGINEER in preparing the Contract Documents. OWNER's representative during construction are set forth in the Contract Documents and will not be changed without 8.06 Insurance written consent of OWNER and ENGINEER A. OWNER's responsibilities, if any, in respect to put- 9.02 Visits to Site chasing and maintaining liability and property insurance are ' set forth in Article 5. A. ENGINEER will make visits to the Site at intervals appropriate to the various stages of construction as 8.07 Change Orders ENGINEER deems necessary in order to observe as an experienced and qualified design professional the progress ' -27- that has been made and the quality of the various aspects of result of a written clarification or interpretation, a Claim may CONTRACTOR's executed Work. Based on information be made therefor as provided in paragraph 10.05. ' obtained during such visits and observations, ENGINEER, for the benefit of OWNER, will determine, in general, if the 9.05 Authorized Variations in Work Work is proceeding in accordance with the Contract , Documents. ENGINEER will not be required to make A. ENGINEER may authorize minor variations in the exhaustive or continuous inspections on the Site to check the Work from the requirements of the Contract Documents quality or quantity of the Work. ENGINEER's efforts will be which do not involve an adjustment in the Contract Price or directed toward providing for OWNER a greater degree of the Contract Times and are compatible with the design , confidence that the completed Work will conform generally concept of the completed Project as a functioning whole as to the Contract Documents. On the basis of such visits and indicated by the 'Contract Documents. These may be observations, ENGINEER will keep OWNER informed of accomplished by a Field Order and will be binding on the progress of the Work and will endeavor to guard OWNER OWNER and also on CONTRACTOR, who shall perform the against defective Work. Work involved promptly. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or B. ENGINEER's visits and observations are subject to extent, if any, of any adjustment in the Contract Price or all the limitations on ENGINEER's authority and Contract Times, or both, as a result of a Field Order, a Claim responsibility set forth in paragraph 9. 10, and particularly, but may be made therefor as provided in paragraph 10.05. without limitation, during or as a result of ENGINEER's visits or observations of CONTRACTOR's Work 9.06 Rejecting Defective Work ENGINEER will not supervise, direct, control, or have authority over or be responsible for CONTRACTOR's A. ENGINEER will have authority to disapprove or means, methods, techniques, sequences, or procedures of reject Work which ENGINEER believes to be defective, or construction, or the safety precautions and programs incident. that ENGINEER believes will not produce a completed ' thereto, or for any failure of CONTRACTOR to comply with Project that conforms to the Contract Documents or that will Laws and Regulations applicable to the performance of the prejudice the integrity of the design concept of the completed Work. Project as a functioning whole as indicated by the Contract Documents. ENGINEER will also have authority to require , 9.03 Project Representative special inspection or testing of the Work as provided in paragraph 13.04, whether or not the Work is fabricated, A. If OWNER and ENGINEER agree, ENGINEER installed, or completed. ' will fumish a Resident Project Representative to assist ENGINEER in providing more extensive observation of the 9.07 Shop Drawings, Change Orders and Payments Work. The responsibilities and authority and limitations thereon of any such Resident Project Representative and A. In connection with ENGINEER's authority as to assistants will be as provided in paragraph 9.10 and in the Shop Drawings and Samples, see paragraph 6.17. Supplementary Conditions, If OWNER designates another representative or agent to represent OWNER at the Site who B. In connection with ENGINEER's authority as to is not ENGINEER's Consultant, agent or employee, the Change Orders, see Articles 10, 11, and 12. , responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supple- C. In connection with ENGINEER's authority as to mentary Conditions. Applications for Payment, see Article 14. 9.04 Clar f cations and Interpretations 9.08 Determinations for Unit Price Work A. ENGINEER will issue with reasonable promptness A. ENGINEER will determine the actual quantities and such written clarifications or interpretations of the require- classifications of Unit Price Work performed by ments of the Contract Documents as ENGINEER may deter- CONTRACTOR ENGINEER will review with CON - mine necessary, which shall be consistent with the intent of TRACTOR the ENGINEER's preliminary determinations on and reasonably inferable from the Contract Documents. Such such matters before rendering a written decision thereon (by written clarifications and interpretations will be binding on recommendation of an Application for Payment or OWNER and CONTRACTOR_ If OWNER and CON- otherwise). ENGINEER's written decision thereon will be TRACTOR are unable to agree on entitlement to or on the final and binding (except as modified by ENGINEER to ' amount or extent, if any, of any adjustment in the Contact reflect changed factual conditions or more accurate data) Price or Contract Times, or both, that should be allowed as a upon OWNER and CONTRACTOR, subject to the provisions of paragraph 10.05. -28- ' Supplier, or of any other individual or entity performing any 9.09 Decisions on Requirements of Contract Documents of the Work. and Acceptability of Work D. ENGINEER's review of the final Application for A. ENGINEER will be the initial interpreter of the Payment and accompanying documentation and all mainte- requirements of the Contract Documents and judge of the nance and operating instructions, schedules, guarantees, acceptability of the Work thereunder. Claims, disputes and Bonds, certificates of inspection, tests and approvals, and other matters relating to the acceptability of the Work, the other documentation required to be delivered by paragraph quantities and classifications of Unit Price Work, the 14.07.A will only be to determine generally that their content interpretation of the requirements of the Contract Documents complies with the requirements of, and in the case of pertaining to the performance of the Work, and Claims certificates of inspections, tests, and approvals that the results seeking changes in the Contract Price or Contract Times will certified indicate compliance with, the Contract Documents. be 'referred initially to ENGINEER in writing, in accordance with the provisions of paragraph 10.05, with a request for a E. The limitations upon authority and responsibility set formal decision. forth in this paragraph 9.10 shall also apply to ENGINEER's Consultants, Resident Project Representative, and assistants. B. When functioning as interpreter and judge under this paragraph 9.09, ENGINEER will not show partiality to ARTICLE 10 - CHANGES IN THE WORK; CLAIMS OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by 10.01 Authorized Changes in the Work ENGINEER pursuant to this paragraph 9.09 with respect to any such Claim, dispute, or other matter (except any which A. Without invalidating the Agreement and without have been waived by the making or acceptance of final• notice to any surety, OWNER may, at any time or from time payment as provided in paragraph 14.07) will be a condition to time, order additions, deletions, or revisions in the Work by precedent to any exercise by OWNER or CONTRACTOR of a Written Amendment, a Change Order, or a Work Change such rights or remedies as either may otherwise have under Directive. Upon receipt of any such document, the Contract Documents or by Laws or Regulations in respect CONTRACTOR shall promptly proceed with the Work of any such Claim, dispute, or other matter. involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise 9.10 Limitations on ENGINEER's Authority and specifically provided). Responsibilities B. If OWNER and CONTRACTOR are unable to A. Neither ENGINEER's authority or responsibility agree on entitlement to, or on the amount or extent, if any, of under this Article 9 or under any other provision of the an adjustment in the Contract Price or Contract Times, or Contract Documents nor any decision made by ENGINEER both, that should be allowed as a result of a Work Change in good faith either to exercise or not exercise such authority Directive, a Claim may be made therefor as provided in or responsibility or the undertaking, exercise, or performance paragraph 10.05. of any authority or responsibility by ENGINEER shall create, impose, or give rise to any duty in contract, tort, or otherwise 10.02 Unauthorized Changes in the Work owed by ENGINEER to CONTRACTOR, any Subcontractor, ' any Supplier, any other individual or entity, or to any surety A. CONTRACTOR shall not be entitled to an increase for or employee or agent of any of them. in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the B. ENGINEER will not supervise, direct, control, or Contract Documents as amended, modified, or supplemented have authority over or be responsible for CONTRACTOR's as provided in paragraph 3.04, except in the case of an emer- means, methods, techniques, sequences, or procedures of gency as provided in paragraph 6.16 or in the case of construction, or the safety precautions and programs incident uncovering Work as provided in paragraph 13.04.B. thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the 10.03 Execution of Change Orders Work. ENGINEER will not be ' responsible for CONTRACTOR's failure to perform the Work in accordance A. OWNER and CONTRACTOR shall execute I with the Contract Documents, appropriate Change Orders recommended by ENGINEER (or Written Amendments) covering: C. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor, any 1 -29- I . changes in the Work which are: (i) ordered claimant within 30 days after receipt of the claimant's last by OWNER pursuant to paragraph 10.01.A, (ii) re- submittal (unless ENGINEER allows additional time). quired because of acceptance of defective Work under paragraph 13.08.A or OWNER's correction of B. ENGINEER's Decision: ENGINEER will render a defective Work under paragraph 13.09, or (iii) agreed formal decision in writing within 30 days after receipt of the to by the parties; last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on 2. changes in the Contract Price or Contract such Claim, dispute, or other matter will be final and binding Times which are agreed to by the parties, including upon OWNER and CONTRACTOR unless: any undisputed sum or amount of time for Work actually performed in accordance with a Work Change 1. an appeal from ENGINEER's decision is Directive; and taken within the time limits and in accordance with the dispute resolution procedures set forth in Article 16; 3. changes in the Contract Price or Contract or Times which embody the substance of any written decision rendered by ENGINEER pursuant to para- 2. if no such dispute resolution procedures graph 10.05; provided that, in lieu of executing any have been set forth in Article 16, a written notice of such Change Order, an appeal may be taken from any intention to appeal from ENGINEER's written such decision in accordance with the provisions of the decision is delivered by OWNER or CONTRACTOR Contract Documents and applicable Laws and Regula- to the other and to ENGINEER within 30 days after , tions, but during any such appeal, CONTRACTOR the date of such decision, and a formal proceeding is shall carry on the Work and adhere to the progress instituted by the appealing party in a forum of schedule as provided in paragraph 6.18.A. competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial 10.04 Notification to Surety Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), A. If notice of any change affecting the general scope to exercise such rights or remedies as the appealing , of the Work or the provisions of the Contract Documents party may have with respect to such Claim, dispute, or (including, but not limited to, Contract Price or Contract other matter in accordance with applicable Laws and Times) is required by the provisions of any Bond to be given Regulations. to a surety, the giving of any such notice will be CONTRACTOR's responsibility. The amount of each C. If ENGINEER does not render a formal decision in applicable Bond will be adjusted to reflect the effect of any writing within the time stated in paragraph 10.053, a such change. decision denying the Claim in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of 10.05 Claims and Disputes the claimant or the last submittal of the opposing party, if any. A. Notice: Written notice staring the general nature of D. No Claim for an adjustment in Contract Price or each Claim, dispute, or other matter shall be delivered by the Contract Times (or Milestones) will be valid if not submitted claimant to ENGINEER and the other party to the Contract in accordance with this paragraph 10.05. promptly (but in no event later than 30 days) after the start of the event giving rise thereto. Notice of the amount or extent , of the Claim, dispute, or other matter with supporting data ARTICLE I 1 - COST OF THE WORK; CASH shall be delivered to the ENGINEER and the other party to ALLOWANCES; UNIT PRICE WORK the Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support of such 11.01 Cost of the Work Claim, dispute, or other matter). A Claim for an adjustment in Contract Price shall be prepared in accordance with the A. Costs Included: The term Cost of the Work means provisions of paragraph 12.01.B. A Claim for an adjustment the sum of all costs necessarily incurred and paid by CON- , in Contract Time shall be prepared in accordance with the TRACTOR in the proper performance of the Work. When provisions of paragraph 12.02.B. Each Claim shall be accom- the value of any Work covered by a Change Order or when a panied by claimant's written statement that the adjustment Claim for an adjustment in Contract Price is determined on claimed is the entire adjustment to which the claimant the basis of Cost of the Work, the costs to be reimbursed to believes it is entitled as a result of said event. The opposing CONTRACTOR will be only those additional or incremental party shall submit any response to ENGINEER and the costs required because of the change in the Work or because -30- of the event giving rise to the Claim. Except as otherwise nes, surveyors, attorneys, and accountants) employed may be agreed to in writing by OWNER, such costs shall be for services specifically related to the Work. in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall 5. Supplemental costs including the not include any of the costs itemized in paragraph 11.01.13. following: 1. Payroll costs for employees in the direct a.The proportion of necessary transportation, employ of CONTRACTOR in the performance of the travel, and subsistence expenses of CONTRACTOR's Work under schedules of job classifications agreed employees incurred in discharge of duties connected upon by OWNER and CONTRACTOR. Such with the Work. employees shall include without limitation superinten- dents, foremen, and other personnel employed full b. Cost, including transportation and mainte- time at the Site. Payroll costs for employees not nance, of all materials, supplies, equipment, employed full time on the Work shall be apportioned machinery, appliances, office, and temporary facilities on the basis of their time spent on the Work. Payroll at the Site, and hand tools not owned by the workers, costs shall include, but not be limited to, salaries and which are consumed in the performance of the Work, wages plus the cosi of fringe benefits, which shall and cost, less market value, of such items used but not include social security contributions, unemployment, consumed which remain the property of CON - excise, and payroll taxes, workers' compensation, TRACTOR. health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The C. Rentals of all construction equipment and expenses of performing Work outside of regular machinery, and the parts thereof whether rented from working hours, on Saturday, Sunday, or legal CONTRACTOR or others in accordance with rental holidays, shall be included in the above to the extent agreements approved by OWNER with the advice of authorized by OWNER. ENGINEER, and the costs of transportation, loading, unloading, assembly, dismantling, and removal there- 2. Cost of all materials and equipment fur- of. All such costs shall be in accordance with the nished and incorporated in the Work, including costs terms of said rental agreements. The rental of any of transportation and storage thereof, and Suppliers' such equipment, machinery, or parts shall cease when field services required in connection therewith. All the use thereof is no longer necessary for the Work. cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with d. Sales, consumer, use, and other similar which to make payments, in which case the cash taxes related to the Work, and for which CONTRAC- discounts shall accrue to OWNER. All trade dis- TOR is liable, imposed by Laws and Regulations. counts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to e , Deposits lost for causes other than negli- OWNER, and CONTRACTOR shall make provisions gene of CONTRACTOR, any Subcontractor, or so that they may be obtained. anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and 3. Payments made by CONTRACTOR to royalty payments and fees for permits and licenses. Subcontractors for Work performed by ' Subcontractors. If required by OWNER, CONTRAC- f. Losses and damages (and related expenses) TOR shall obtain competitive bids from subcontrac- caused by damage to the Work, not compensated by tors acceptable to OWNER and CONTRACTOR and insurance or otherwise, sustained by CONTRACTOR shall deliver such bids to OWNER, who will then in connection with the performance of the Work determine, with the advice of ENGINEER, which (except losses and damages within the deductible bids, if any, will be acceptable. If any subcontract amounts of property insurance established in provides that the Subcontractor is to be paid on the accordance with paragraph 5.06.D), provided such basis of Cost of the Work plus a fee, the losses and damages have resulted from causes other Subcontractor's Cost of the Work and fee shall be than the negligence of CONTRACTOR, any determined in the same manner as CONTRACTOR's Subcontractor, or anyone directly or indirectly Cost of the Work and fee as provided in this paragraph employed by any of them or for whose acts any of 11.01. them may be liable. Such losses shall include settlements made with the written consent and 4. Costs of special consultants (including but approval of OWNER. No such losses, damages, and not limited to engineers, architects, testing laborato- -3l expenses shall be included in the Cost of the Work for the purpose of determining CONTRACTOR'S fee. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and g. The cost of utilities, fuel, and sanitary expressly included in paragraphs 11.01.A and facilities at the Site. 11.0 I.B. h. Minor expenses such as telegrams, long C. CONTRACTOR's Fee: When all the Work is distance telephone calls, telephone service at the Site, performed on the basis of cost -plus, CONTRACTOR's fee expressage, and similar petty cash items in connection shall be determined as set forth in the Agreement. When the ' with the Work. value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on i. When the Cost of the Work is used to the basis of Cost of the Work, CONTRACTOR's fee shall be determine the value of a Change Order or of a Claim, determined as set forth in paragraph 12.01.C. the cost of premiums for additional Bonds and insurance required because of the changes in the Work D. Documentation: Whenever the Cost of the Work for or caused by the event giving rise to the Claim. any purpose is to be determined pursuant to paragraphs 11.01.A and 11.01.B, CONTRACTOR will establish and j. When all the Work is performed on the basis of maintain records thereof in accordance with generally cost -plus, the costs of premiums for all Bonds and accepted accounting practices and submit in a form insurance CONTRACTOR is required by the Contract acceptable to ENGINEER an itemized cost breakdown Documents to purchase and maintain. together with supporting data. B. Costs Excluded: The term Cost of the Work shall 11.02 Cash Allowances not include any of the following items: A. It is understood that CONTRACTOR has included 1. Payroll costs and other compensation of in the Contract Price all allowances so named in the Contract CONTRACTOR's officers, executives, principals (of Documents and shall cause the Work so covered to be ' partnerships and sole proprietorships), general manag- performed for such sums as may be acceptable to OWNER ers, engineers, architects, estimators, attorneys, audi- and ENGINEER CONTRACTOR agrees that: tors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel 1. the allowances include the cost to CON - employed by CONTRACTOR, whether at the Site or TRACTOR (less any applicable trade discounts) of in CONTRACTOR's principal or branch office for materials and equipment required by the allowances to general administration of the Work and not specifical- be delivered at the Site, and all applicable taxes; and ly included in the agreed upon schedule of job classifications referred to in paragraph I LOLA.I or 2. CONTRACTOR's costs for unloading and specifically covered by paragraph 11.01.A.4, all of handling on the Site, labor, installation costs, over - which are to be considered administrative costs head, profit, and other expenses contemplated for the covered by the CONTRACTOR's fee. allowances have been included in the Contract Price and not in the allowances, and no demand for addi- 2. Expenses of CONTRACTOR's principal tional payment on account of any of the foregoing will and branch offices other than CONTRACTOR's be valid. ' office at the Site. B. Prior to final payment, an appropriate Change Order 3. Any part of CONTRACTOR's capital will be issued as recommended by ENGINEER to reflect expenses, including interest on CONTRACTOR's actual amounts due CONTRACTOR on account of Work capital employed for the Work and charges against covered by allowances, and the Contract Price shall be CONTRACTOR for delinquent payments. correspondingly adjusted. 4. Costs due to the negligence of CONTRAC- 11.03 Unit Price Work TOR, any Subcontractor, or anyorie directly or indi- rectly employed by any of them or for whose acts any A. Where the Contract Documents provide that all or of them may be liable, including but not limited to, the part of the Work is to be Unit Price Work, initially the correction of defective Work, disposal of materials or Contract Price will be deemed to include for all Unit Price equipment wrongly supplied, and making good any Work an amount equal to the sum of the unit price for each damage to property. separately identified item of Unit Price Work times the -32- estimated quantity of each item as indicated in the Agree- ment. The estimated quantities of items of Unit Price Work 2. where the Work involved is not covered by are not guaranteed and are solely for the purpose of unit prices contained in the Contract Documents, by a comparison of Bids and determining an initial Contract Price. mutually agreed lump sum (which may include an Determinations of the actual quantities and classifications of allowance for overhead and profit not necessarily in Unit Price Work performed by CONTRACTOR will be made accordance with paragraph 12.0I.C.2); or by ENGINEER subject to the provisions of paragraph 9.08. 3. where the Work involved is not covered by B. Each unit price will be deemed to include an amount unit prices contained in the Contract Documents and considered by CONTRACTOR to be adequate to cover agreement to a lump sum is not reached under para- CONTRACTOR's overhead and profit for each separately graph 12.0l.B.2, on the basis of the Cost of the Work identified item. (determined as provided in paragraph 11.01) plus a CONTRACTOR's fee for overhead and profit (deter - C. OWNER or CONTRACTOR may make a Claim for mined as provided in paragraph 12.01.C). an adjustment in the Contract Price in accordance with paragraph 10.05 if C. CONTRACTOR's Fee: The CONTRACTOR's fee - for overhead and profit shall be determined as follows: I . the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and 1. a mutually acceptable fixed fee; or ' significantly from the estimated quantity of such item indicated in the Agreement; and 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various 2. there is no corresponding adjustment with portions of the Cost of the Work: respect any other item of Work; and a. for costs incurred under paragraphs 3. if CONTRACTOR believes that I1.0l.A.1 and 11.01.A.2, the CONTRACTOR's CONTRACTOR is entitled to an increase in Contract fee shall be 15 percent; Price as a result of having incurred additional expense or OWNER believes that OWNER is entitled to a b. for costs incurred under paragraph decrease in Contract Price and the parties are unable to 11.0I.A.3, the CONTRACTOR's fee shall be five agree as to the amount of any such increase or percent; decrease. c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and ARTICLE 12 - CHANGE OF CONTRACT PRICE; no fixed fee is agreed upon, the intent of paragraph CHANGE OF CONTRACT TIMES 12.0l.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such 12.01 Change of Contract Price Subcontractor under paragraphs 11.0l.A.1 and 11.0I.A.2 and that any higher tier Subcontractor A. The Contract Price may only be changed by a and CONTRACTOR will each be paid a fee of Change Order or by a Written Amendment. Any Claim for five percent of the amount paid to the next lower an adjustment in the Contract Price shall be based on written tier Subcontractor; notice submitted by the party malting the Claim to the ENGINEER and the other party to the Contract in accordance d. no fee shall be payable on the basis of with the provisions of paragraph 10.05. costs itemized under paragraphs 11.01.A.4, 11.0I.A.5, and 11.0I.B; B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will e. the amount of credit to be allowed by be determined as follows: CONTRACTOR to OWNER for any change which results in a net decrease in cost will be the 1. where the Work involved is covered by amount of the actual net decrease in cost plus a unit prices contained in the Contract Documents, by deduction in CONTRACTOR's fee by an amount application of such unit prices to the quantities of the equal to five percent of such net decrease; and items involved (subject to the provisions of paragraph 11.03 ); or -33- f. when both additions and credits are in- 12.06 Delay Damages volved in any one change, the adjustment in CONTRACTOR's fee shall be computed on the A. In no event shall OWNER or ENGINEER be liable basis of the net change in accordance with para- to CONTRACTOR, any Subcontractor, any Supplier, or any graphs 12.01.C.2.a through 12.01.C.2.e, inclusive. other person or organization, or to any surety for or employee or agent of any of them, for damages arising out of or 12.02 Change of Contract Times resulting from: A. The Contract Times (or Milestones) may only be 1. delays caused by or within the control of , changed by a Change Order or by a Written Amendment. CONTRACTOR; or Any Claim for an adjustment in the Contract Times (or 2 delays beyond the control of both OWNER Milestones) shall be based on written notice submitted by the Y Y party making the claim to the ENGINEER and the other party and CONTRACTOR including but not limited to to the Contract in accordance with the provisions of fires, floods, epidemics, abnormal weather conditions, paragraph 10.05. acts of God, or acts or neglect by utility owners or other contractors performing other work as B. Any adjustment of the Contract Times (or contemplated by Article 7. Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be B. Nothing in this paragraph 12.Ob bars a change in determined in accordance with the provisions of this Contract Price pursuant to this Article 12 to compensate ' Article 12. CONTRACTOR due to delay, interference, or disruption directly attributable to actions or inactions of OWNER or 12.03 Delays Beyond CONTRACTOR's Control anyone for whom OWNER is responsible. A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract Times ARTICLE 13 - TESTS AND INSPECTIONS; (or Milestones) due to delay beyond the control of CORRECTION, REMOVAL OR ACCEPTANCE OF CONTRACTOR, the Contract Times (or Milestones) will be DEFECTIVE WORK extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in paragraph 12.02.A. Delays beyond the control of CONTRACTOR shall 13.01 Notice of Defects include, but not be limited to, acts or neglect by OWNER, acts or neglect of utility owners or other contractors perform- A. Prompt notice of all defective Work of which ing other work as contemplated by Article 7, fires, floods, OWNER or ENGINEER has actual knowledge will be given 1 epidemics, abnormal weather conditions, or acts of God. to CONTRACTOR. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 12.04 Delays Within CONTRACTOR's Control 13.02 Access to Work A. The Contract Times (or Milestones) will not be extended due to delays within the control of CONTRACTOR. . OWNER, ENGINEER, ENGINEER'S Consultants, R Delays attributable to and within the control of a other representatives and personnel of OWNER, independent Subcontractor or Supplier shall be deemed to be delays within testing laboratories, and governmental agencies with , the control of CONTRACTOR. jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspecting, 12.05 Delays Beyond OWNER's and CONTRACTOR's and testing. CONTRACTOR shall provide them proper and Control safe conditions for such access and advise them of CONTRACTOR's Site safety procedures and programs so A. Where CONTRACTOR is prevented from complet- that they may comply therewith as applicable. ing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of both OWNER 13.03 Tests and Inspections and CONTRACTOR, an extension of the Contract Times (or A. CONTRACTOR shall give ENGINEER timely Milestones) in an amount equal to the time lost due to such delay shall be CONTRACTOR's sole and exclusive remedy notice of readiness of the Work for all required inspections, for such delay. tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. -34- -s£- •(siagio jo 3I1om jo luatuaoelda .i.ro iTedal jo slsoo Ile of paptuil IOU inq Sutpniotu) 'madxo s.110,I0W LNOD lenotuai to uoRoauoa Bans o1 gupulat so 3o Ino Stu sLm is paosldaz pus uoRsnaasgo s, dggMgXg 1q3 pajanooun aq (sisoo uoTinlosar aindstp impo io uotiutgm .ro imoo Ile `dggmDNg Aq palsanba131 `lsnur IT `mNIJNg3o lsonbai pus slsuoTSSatotd iaEio pue `sfatualls `sloaltgom `siaou tra ua14RM aql 01 fts.RUOO pa st X Xtie 3I '`d jo signtIo pue saai Its of paipull IOU inq Suipnloui) so2vurep pus `sassol `sisoo `sunsl0 Ile Xed Ilegs 1i01DWIN00 Vow Su1aaA0,7uD b0• £ I •aARoa3ap IOU ST legl 3I1oM gllm PT aoeldaa pus loafo.td aqI ura.g IT PAOtua.[ `1IggMONg , (q poloafai uaaq seq )lioM - aouou qons of aqi 3T `so `paialduroo so `polisism `paleouge3 iou so aagiaqm osuodsai to ssauldtuoid algeuosew glTm poloe IOU seE 11ggN `iIioM aAR393ap IIe 1 3QUOO Begs 1I013d2L NOD 'd - IONA Ptre aUres alp iaAOO 01 uo s,1I0jDV-i.LN00 JO aoROU XIaUIR - dagMoNg uaATS ssq 1I0.L0VjJL -yjo,k aAyoafaafo jmotuay io uorzaadjq,� 90'£1 - N00 ssafun asuodxa s<1I0.I. VHjN00 le oq hugs g'£0'£I gdmgp -ed uT paptAOad se )[.IoM BUUanooun •3 •uiatp jo Aue jo luaSe io as tolduta .to 1 YO3 foins Niue so `Aigua so Isnpintput .wpo Aue jailddnS Cue `ioioRAuoogng •uOtIvAlasgo io3 paranoaun oq `1Igg DNg Xq palsanbai .Sue `110 L0vU LN00 jo lrlauaq agi a03 lggu sTgl asfwaxa 3T `isnur IT 1 1Igg ()Ma 3o aouaunmoo ualium Inotlltm of 1IgNM0 3o gud atp uo Clnp Pius 01 asu OATS IOU hugs 1IO.L0v L. 00 Aq palanoo si panoidde io `palsal `paioadsuf :I.roM agi dols 0 1 - daKMO 3O IESu STEP `Janamoq 'palsUTurTIa aq o sT legl (sim po jo jjom atp so) �joM .Sus 3I • g uaaq seq aapio qons 1q j asnso atp ITIun `3oa ip yo!liod Niue to SIioM oxg dols of 11010d1L XOD npio Arta daNMO •da NIJNg `sluaumooQ Ios•RuoO otg ol. uuojuoo Iltm 3lzoM paialduroo aEi pus dgNMO of algeldaooe suojl=uuSio Xq pauuoj tad Imp ,tsm a qons uT 3IloM aql uuojtad o1 sgej .to `ivaurdlnba oq Ilegs slenotdde so `sisal `suoRoadsuT Eons >jioM 10 slsTa algm!ns io simpoM pallPis Puorogjns XIddns alp m uOlModioom .I oj 3oaiagl osegoind s,1IO LOd2I.LN00 oI SIIe31IO.L0tULN00 . `aAROalap sT )IlOM ag131 d of loud Isnoidds ao3 pon!tugns Puatudlnba so `suSTsop xTut `slsualetu 3o aomdaooe io :alioM mp m palemodt om xrOM ayj dog ( nN yjyA0 S0•£I aq oP ivatudinba io slsuaistu 3a aotmdamu s, IM IDNIH pus s,llgXMO .to3 pa.nnbal slenotdds io `sisal `suotloadsm '50'01 gdw2wed ,Cue giTm uoiloauuoo uT sisoo Ile Ad hugs pus guTmsigo pus U! papino.zd se iojalatp unut0 a aaleur ,fear d0j.DV - iLN00 2ui2mue io3 alglsuodsa.r aq hugs -d0jDV -&LN00 '(I `3oantIl lualxo io lunoum agi of se Paige of algeun its saTitsd PEI 3I 'uogomisuooar pus `juatuaouldal `Smisal •lenosdde io uoTloadsm `uotloadsut `uoReArasgo `amsodxa `2Uuanooun qons of alge 3o saleogtuao pannbai axp 1IggMf)Ng gsiu.m3 pue `ElTmaaagl - 1nq!.mu Clloanp `gioq io `(souolsapW so) sotuil lotaaluo0 atp uolloauuoa uT sisoo Ile Aed `slenoidde io `sisal `suoTioadsut 3o uolsualxa tm .to aoud ioeguoO aql m aseanui ue pamolle qons guiuimgo pus SuTgueue ioj fsj!ITgTsuodsal IIn3 oumsse , aq Itsgs 2I0i0y2l t 1100 `aATloajap aq oI punoj lou sI 31.10M Begs 1I01DVId LN00 `APoq o►lgnd qons jo aARsluasaidai qons `janamoq 1 3I 'go - 01 gdu&und m papTAO.td ss i0Ja1a1R .ratpo .to aoxoldum us Xq panoadds so `palsal `paloadsut aq urte10 a 03lsut Xsur 1IgNM0 `3o0taEl ltmoure alp 01 se aaaSe of XIlsogToads (;owotp Pled so) iIaoM tut. Onnbat uotimpsunf o1 olgeun a.re satped aql 31 •aoud 13RUtIo0 ag1 uT osealoop Sumeq Xpoq oTlgnd ,due 3o suoRslnSa21 so smsZ 3I •O aleudo.idde ue of poligua aq Ilegs ?igNMO pus `.(sxaglo ,lo 3liom jo Puatuaoeldai ro nedw 3o sisoo Ile oI pallmil •sluaumoo(l loe.RuoO IOU 1nq SuTpnloui) uoRotuisuooat so Puatuaoeldaa Xioloe,IsRss aqI uT papTAotd XIleogloods asrAuaglo ss £ jo pus `Smisai pus `uolloodsui `uotleA.tasgo `amsodxa `Suuanooun qons o1 Sutietal io jo lno Smut (sisoo uotinlosai P� •g'b0'£I aindstp.iatIlo ao uojlarl!yu .to Imoo lie pus sleuomssajoid iagio gdslgewd plus uT paptnotd se pTsd aq Ilegs g•b0'£I put `skausolle `sloaltgoas `stamigua jo sagngo pus saa3 IIe 01 gdui ted o) luensind palonpuao suoRoadsm .to pal!tuij IOU inq ftpnlouT) sagsump pus `sossoi slsoo sunuID sisal glTm uoTlOauuoo ut paitttom sisoo ietT1 z Ile Xed Bugs d0j3 Uj N0D `aATloa3ap sT 3IroM qons lsgi pungj sT IT 3I •Iuatudinba put `teualsm `aogsl tisssaoau `moloq Q•E0'£I PUL, O'£0'£I sgdt:l2md kq Ile Suigstumj `uopsanb in IoM atp 3o uoTl.tod lsgl `annbai pa.tanoo slenordde .to sisal `suoTloadsuT Poi i Astu 2IggNIJN9 se Smisal .to `uoioadsui `uoilsAtasgo .toj algelTene a�teut astm.tatpo io `asodxo `.tanooun hugs `Isanbat :Idaoxa s.1Ig PUDKg Ie `d0jovdLN00 `saagio Xq palsal to sluawnooc losnuo0 atp Xq paimbas slenoidde io `sisal paloadsm ro 2iggNIJNg Xq paA.tasgo aq �I1OM palanoo ImIl `suoTloadsuT Ile uuo3rad of tioislogei guTlsoi luopuadaptn aiges!Ape io tressaoau It s optsuoo 1IggNIJNg .3I •S us 3o sootmias aqi lo3 !ed pus,Coldtua Ilegs 1IgNM0 S - 9E - `Hoj,0d2I. MoZ) lsup e p gnlgo aq IIFA 60'£1 gde12s1ed 01 loud `pus) 2IgXMO `alsoM anuoajap jo luawamidaJ su sapun satpawal pue sltt2u otp Sutstaiaxa ut NaNAW pus IenowaJ 10 U OIIDOIJ03 BUptnb jo pealsui `JI 'y Aq pautelsns so paunout (slsoo uounlosasi alndsip iaglo Jo a o aaunxda0� uousnIcIm io pnoo Ile Pus slauotssajold Jag10 pus `SAOUJOue to ,4f anrjaa I Qf .v .80 "£ l `s,oalW= `&MoutBua jo sa$Jego pus saoj II t, of pol[wtl IOU 1nq •asodai 10 uouepuul jo aln;ins Sutpnlout) saSeump pug `sassol `s1soO `sunsl0 IN '0 1 01gsotlddE Cue jo suotstnosd aq; jo JantsM a so Joj altyt;sgns •qde wud stgi Japun satpawai pus s1gBu aq1 e s pannsuoO aq sou Iisgs LO'£1 11dsa�essd s.q; jo suoistnold os,=xo o; gg1.IM0 aigguo 01 a1tS alp 01 ssaOOe slus4insuo0 atu •rCluausm so uotleStlgo Jaglo Cue of not ;apps ut ass LO'£ [ s,ZI moRg pue xaag uoma Pus `ssoloenuoo Jag10 gdwgujsd stgl Japun suoueStlgo s, D UJN00 'Q s,)IgPIMO `saa,Coldwa pug slua2e `sanuilu2sasdw s,2lgKMO `&gMMO Moile (legs )IO.L0V&Ll�t00 'asagnnasla pasois an pa ;aldwoO �Ciuoloejsues uaaq seq luawaoeldas pus gotgm 1nq �IOJ.OvUJX00 ptud sI daNAMo golgm 3O3 1° Ien°wa] 1 0 uorloamoo gons sags JeaiC auo jo potlad leuot;tppe alts 21p It poiols luawdinba pus sleualew jig xioM aq1 Ut ales us 1 oj papuolxo oq iltnn Jlj gons of loadsas tp!m sapunaJaq - odlooui pue `altg OT rCsautgoew pus ivawdinba uotlonJ;s pouad uouoauoo ag1 'LO-El gds d still sapun paosldas -uoo `soouetldde `stool s,- do.LoVIUt�I00 j0 uotssassod pug panowas so paloasJOO uaaq seg (wosjalagl 2utllnsas 23M `olasagl Pa;sial saOtnJas s,2IO,L3d2LLAI00 puadsns )lioM Jaglo of aBEUMp Ptte) 31JOM 2AR00j2p asagM '0 M pus JIJoM aql jo vad so lle jo uoissassod all `01tS 2111 jo ped so lle wolf - IOJ.OVL NOD aPnloxa -Csw 2IgPIMO luatupuausy uauuM �Cq so suoueogtoadS `uonm Ietpawm PUB anuOaJJOO gOns gun+ UOuoaUnoo 011 ut paptnosd os jt alsp satlssa us wolf aru o1 psls xew wa ;t ul -fisnoutpadxa paaoold ltegs 2IgNMO `gdrA=d legs 1oj pouad uotloamoo 2111 `�I10 A aql Its jo uoualdwo0 stgl lapun satpawas pug Slop aq1 Sutstosaxa ul •g IeuuelsgnS alojaq aOtnJas snonu0uoo ut paoeld st luawdtnba jo walk ssinotpsd s asagnn sa:)IMsumono Istoads ul 'g .4auatogap gons ,Cue kpawaa pus loa.UOO ` -d013V IN00 ' 01 0OOou uautjnn s�Cep uanas save `Agw 21SI•IM0 2IOJ.0�LLPI00 `s UaU n3OQ;oenuo0 oql jo uotstnold Jag10 fus g ;inn ,Cldwoo Aq pled aq IltA� (sJaglo j o Jlionn jo luawaasldaJ 01 S 2IOJ.0d2I.LN00 jt 1 0 `sluaumoo(i 1 3 equ00 aql gltnn Jo Jtedal jo s1soO lie o Pajlwgl;ou;nq Sutpnlout) lu awamidas aouspsoOOS Ut JIJOM aql uJJojJad of sltej 2IO.LDV - dJ N00 pue Isnowas gans Jo nedoi so uol4o2.uoo gons of Sut;eias 3t 10 ``d "90'£1 gdeJSeted gjyA oaueps000e ut 2lgg. jM)Ng J o jo ; no Buisus (slsoo uounlosas alndsip satpo 1 0 uouuugJe Aq partnboi se 3110M paloafal aoeldas pus anowa 01 Jo )1.toM i o un oo IIE pug sieuoissajold J aglo pug `SAOUJOue `sl anrlOajap 10=00 o; �lggNIJI`Ig woJj ao.lou uauunn sa3je `ssaaut2ua jo saBJS110 pus saa3 Its o1 paljwtl ;ou ;nq SutpnlOUt) aural olgsuomi a wgltnn sitsj 2IO.LDVULN00 jI "d sa2eUrep pus `sassol `slsoO `sirtteFO Its Pus `paOeldal pUe- panowas )I1oM paloafal aq1 aneq Arm so patiedal xro,g agjoajaQ iaauo0 dvNYgNMO 60'£I so paloauoo JIJoM antloajap 2q1 aneq Asw -daNMO `a2euml? so ssol jo )lsu snouas osneo pinoea Aulap asagm ,Couagiawa ' 2FgtdMO o1 aO,L0V2I:LX00 Aq Pfd 2 l Ipm lunoum ue ut so `suotlonnsut gans jo suual oql qj!m Aidwoo a;eudosdde ue `uotlepuaunuoaaJ gons Jags sm000 aoueld000e �Clldwold 1ou soop 2FO,L0V - dj N00 jI •wO -4=111 2Uulnsal otp 3I S0'01 gdra=d Ut P2Ptnold s Jojasagl Uti a sass so pull Jatllo 10 slaglo jo 3110m 3q1 01 `11oM 1211 ;o a�Istu �isw 2ISNMO `joasagl lunowe ag1 o1 s oaAL o1 algsun o1 aSswsp Cue aosldaJ pus anowal 10 nsdaJ so loauoo Afliol ass satped 2q1 3I •paldaooe os )IsoM jo anlun pagstmunp - oejsilss (rat) pus `antloajap sou st 1sg1 :I1oM q;tm it aosidal agl SutloaUal `gaud losnuo0 alp ut ostwoop alsudoldds pus loafosd oq1 wolf 1! anowal `UgNMO Aq paloafal uaaq ue of polulua aq Ilegs 2ISI�TMO Pus `�l1oM aq; o; loadsas seq 3110 an[;Oajap aql Jt `10 JI1oM aApMap gons loauoo tp!ta s4uaum3OG 1OSnuOO aq1 ut suotstnas �tssssaoau 2111 (tt) so `ssaJS so puss antloajap gons ltsdal (t) :suotlonnsut Sut;ssodiomn ponsst al Ittnn JapsO asusg0 s luatuCud lsui3 uau4m s12I9NMO ql!m 2OULIP1003e ui Pule 2IgNM0 jo u01WIpuaunuoom s,- dggNIJNg o; loud sm000 sous ;dame of lsoo lnogj!m 1 411dwosd Ilsgs dojDV - dj l00 `antloojop aq gons Cue jI •aoualuas stgl 01 lusnssnd 2FO.L0` 'd1 N00 01 PUnOj St `d't i'9 gdel8eted ut paleldutaluoO s suo1eln2oX Aq Plsd asmuaglo lou lualxa 2111 01 JI10M 2111 . jo pug snne7 ,Cq palltuuod 10 2IgNM0 4q asn s, - aojD ldj K00 onlen pagstutunp aql pue (ssauolgeuoseas o1 ss - d9aMDN9 soj olgsltene apses sgare 10 pull aq1 01 saSswsp ,(us jo Aq panosdds aq of slsoo gans) NioM anuoajap gons idaoos Medal aql jt 10 `antloajaP aq of punoj st :l1oM Aug `sluaumoo(I 01 uousutu0alap pue jo uouenlsna s,ggl.IMO o1 algsingtJUe loenuo0 2111 jo uotstnaid ogtoods Cue Aq so sluaumooQ (s;soo uounlosas alndsip Jag10 Jo uoutwt;tgls so mw Ile losnuo0 agl 4q pannbw aalutmiB lstoads olgeoildds pus sleuotssajold saglo pus `s.Cawoue `s ;OaitgoJa `slaaui2U2 Xus jo Sum) 2111 �q so suoileln2a21 so smu-j Aq paquoswd jo sa2Jego pus saa3 IIg of patrons 10 u 1nq Sutpnlout) saSsump oq Amu st own jo pouad JaSuol gons so uopoldwo0 pus sassol slsoo sune10 Iis Xed Ilsgs gO.LoV'dLNOO lstuislsgnS jo alsp 2111 sage lea! auo urgltM jl -y - op Aj!w ZIgXMO ` ;t ldaooe o; slajasd (gggNlONg `luouUCsd lsug jo uouspuaurwooas S,ZI'JaKIfk2 poirad uouoa��o� LO-Cl t a an onus ao `ssalSo.td to .to o loadse ltn t e un a n aut s uoueot dd oea °luotuXe Pa [� P P [ . x M a � 3 t P 1 . tfsq .I d q d faana o; popua;xo `antlsnegxo uaaq aneq pauuol.tad io3 uopuollddy pu000s atp tp!m SutuutSag z uaaq sgq a se xioM atp }o . aqi so ,Clgenb atp >[oago o; apgtu suot;oadsut (t) : legl paluasardai ggNMO o1 kloloe3s.1BS aq;snw gotgm jo aneq 01 pauraap aq Agasagi IO U, [IIM IMNIDN3 ITS `utaiagl ;saaalut s, loalold o; s ;uauiaSumm luautted gons Cut, Sutpuattnuooaa ,Cg £ .taq;o io oouemsut kpodoid aleudoldde Aq pa.ianoo an= 1uauudmba pug sleualetu atp lgtp aouaptna pus •1.toM aq1 antasgo o; Ajtltgtsuodsal s,gggNjONg seat -1 lie 3o igolo pus aag luotudtnba put sleualwn s► 1t sg ael os ui patlUpU uaoq aneq of mcIde atp panlaoaa seq -daNM0 IMP Sutlut,ut,M uoyt,luaw lumArd gons of paptiva Stnoq s, - doj,3 UN0o -noop laglo so `aotonut `ales jo lltq a Aq patuedtu000e of ;uapooaid suotltpuoo aql o aq osle Ilggs luauutsd ioj uotit,oilddy aqi `Sup" U! of pooa u uojlsaol iaglous is so alts MIT le palo ;s pus :(uogspuounuooaa atp ut pals ;s suousogtlsnb Algslms pus pa.tanilap ing ilioM aqi to palelodiooUn 1aq ;o SUB o; pus `80 gdr amd iopun lou luouidtnba pus sleualeur 3o slseq aql uo pa ;sonbal x ooyd ltun ao3 suoueogtsselo pug sat;tiut,nb st luauixed 3I •sluatunoo(I ;oea;uoo aqi Aq pamtbat jo uotleu!tuiMap mug t, of `sluaumooQ loe.quoo st ss uotle;uaumoop Sutuoddns gons Aq pamedui000t, aqi ut .to3 Palled sisal luanbasgns Cue jo sllnsal otp put uotleorldcIV atp jo a1up aql 3o se palaldwoo xjoM o; `uopolduioo letltmsgnS uodn zo of .loud alogM otp Suuanoo Ndoj oVIUN0o Aq pauSts pue lno palig Sutuoti3un3 a se xjoM atp ,lo uotlenlena ug o; luatuAed ioj uotleotlddy ue Matnat l03 2IffgPlI'JNg loofgns) sluoumoo(I losquoo ag; g;tM aougpi000t, o; ;ttugns Ilegs -doy3yyl,mO;3 `(gluotu g aoud in AllmouaS st xioM atp jo 14gmb atp •q ueql ualjo oiotu lou 1nq) ;uauiAvd ssa Soid goro aoj pagstlgelsa alep otp oiojaq sAup OZ lseal ly .1 .pa ;eolput lutod oql of passaawd seq 3TOM aql •e sJuaur,Cvd.rofsuorrvarlddV • :3atlaq pug uoueuuopzl `ogpalmoR s;uaru1(yd ssa.120 rd ZO'b I s,2IggIjDXg 30 lsoq aq; o; Imp `solnpagos pug elep SuTXusdtu000e atp pug luaurAud ioj uotleotlddd atp pajoldwoo shun jo 3o Matnat s,- daaNj[)Na uo pue Isuotssajoad uStsap iaqumu otll uo paseq aq ll!m KiaM aoud;tun,lo lun000s uo pa3tlenb pug poouauadxa ue se )poM palnooxa aql 3o sluoul,Ced ssa.iSoid '2IgatZDNg of olgsid000s MUL4ed ao3 alts atp uo suopumosgo s,?IggNjDMF[ uo paseq `,lg not ;eotlddd jo uuo3 g olut palraodioout oq IItM pug sluatuxed - NMO of )13MUJN3 Aq uotleluasaidw a ainit lsuoo ssalsotd ao3 stseq aqi se antas IIIM YLO'Z gderSeaed 1pm luowALd ioj uotleollddy us ut palsonbai ;uatuXed ut pap!nold se pagstlgelsa sanlen 3o alnpagos aq L •y Aug 3o u01lepuaunuo001 s,2IgaIIgNg Z santvA fo alnpagoS IO'tbl not ;t,otIddV aql lttugnsai pug suopoauoo kmss000u atp a4etu Xgui 2IO.LOVLLNOO `oseo lallel oql ul •luoutAed NOI 9 puaunumat of Stnsndai ioj suoseat s, dggMJNg QNd N013d2l.LNOO OZ S.LNEIWA 'd - t d IOI.LHV Rugg& ut Sugrotpui do.L0'v'WXOD of uogRogddy alp tcmlat to 2IgNM0 0; uot;sotlddV atp luasaad '60'£I gdwBmd pug luou Ard jo uotlepuounuoma g SutluM to al - emput snli aapun soipoural pug s;gSu s,2IgNMO 3 - dgNMO iaWa `luawkq joj uotleotlddy goea jo ;dtaoai 4q astolaxa aqi of algemnqulle :ltoM at{l ,lo oouguuojlod otp loge ssup 01 utgi!m `mm xaamONg 't ut Arlop Cue jo asnsoaq (sauolsol!W so) satut,l, loe.quoo aql jo uolsualxa ug pomolle aq lou Ilggs - do LDVWI N0o •Q suopvoyddVfoma •g 3lioM antloalaP s.2tO.LOV2I.LN0o 3 •luatuaai2v luatuaoeldai io `Isnotual `uolloamo Aq paSetusp to paAogsap atp ut paiglndtis se aq IItM sluawArd ssaigoad saaglo jo )lioM jo ;uatuaoeldai m `.ngdas jo slsoo Ile o; pallWtl of loadsai qm a5rutelai jo ;unoum xLL £ oq lou inq apnlout lltM sagutuep pug sassol slsoo `stuirlo gonS SO'01 gdrlSrmcf ut paptnoid se aojaiagl tutglo g luauvCgd io3 suot ;t,otIddV a)letu ABU] - dHNAf1O `luattg atp 3o lun otue agl o se aaae loud qvm palt,loosse suotleSilgo a ;etuil!Ral o; algeun we salusd atp 3I •aoud loequoo aq1 Et osuo nap s,2IO.LOd2LLNO3 agntios►p of ltm000e uo pagdde aleudoidde us o; poligua oq llsgs dgNMO pug `3poM atp uoaq aneq 3I101A aqi jo lunoaas uo panta301 s;uatuXud o ;oadsai glm s loequ atp ut suotstnaJ ,ftessamu ssa.tSoid snoinald Ile legl Sutlgls 2IO.LO` - ?I.LNOO 3o aqi Supyaiodloou► ponsst aq IItM iapio aSuego a pug •suatZ Ilia jo MID pus aaz3 ang sauroaag luawl(vd 'D ;uauLCsd jo awg atp ugtp ia;el ou 2IgNMO o; sssd l[!m `lou zo loafozd atp to palwodzootn zaq ;agnn ;uatuArd zo3 uogsotlddd V gduziszsd Aug 4q pazanao luawdinbo pug `slsua;etu `)110M llg o; ui palgzawnuo sluana otp 3o Aug 3a aouaunno 9111.1 IMP saalummS pug s;ueusm 2IO,LOVULMOD 'V oql 3o aspalmog [sttlou seq gg9MONg 'P allu fo �ouvuvId s ?IO.LOY'YINOD £0'bl 10 :60'£1 gdrAwd gjjm oauepzoaoe ui 31zoM alaldwoo zo 1lzoM angoO3ap ['O'Z0'bI gdpAmd Aq paunuzalap su anp lunowg ;oamoo of paztnbw uaaq seq ggNMO 'a ug sg pa ;¢az; oq [lugs platltp!m Alln3suozm ;unotuu aql `pag!lsnf lou sum luauLtgd 3o lusnjaz s, damM0 `.szapzp a$ugg0 zo luawpuautV ualluM 1gt11 pouiwzalop Alluonbasgns s! 1! 31 £ Aq paonpaz uaaq stq aoud los4uo0 aql •q •uo!1og Ions zoj suoseai otp u0noRisugs s,ggNMO :luaw 01 s;oazzoo 2IO1OV2LLAI00 UOWA `210,L3V NOO - aogldaz zo uotloazzoo 2mnnbaz `passwep uaaq sgq pug - daNMO Aq of pa2Bv olazatp luauusnfpg 3poM palaldwoa 10 `3ngoa3ap sr )[zoM atp •u Am zo `ploggl!m os ltmoure atp uoloW LNOD Aud Xlldwozd llsgs ZIaKMO 'Plow!^ :asngoaq ssol woz3 ggNMO os lunotug all jo uogonpop zaps Sutummi lunows loalozd of uo?u!do s,gggl�ONg u! Smsaoau oq Amu Aug - doLOVg. ROo Cud Klldtuoid pus uopag Ions se lualxa gaps o; `apuw Xlsnoinazd uogepuauuuooat 103 suoseaz aql sugms (gggNlONg of Adoo g Il!m) luatuArd Ions Aug mlonaz 10 astnaz `s1sa1 aopou uallum alstpautwi 2IO.LOV -djNOO 9Al2? lsnw zo suoi;oodsut luanbasgns 3o sllnsw aq1 zo aouap!na - aN) Ao. `,daaNjONg Aq papuatuwooaz lunows lln3 pazanoas!p Xpuanbosgns jo osnuoaq `zo ;uautXed atp jo 1ummW a�lew o; sasn331 'daNMO R z Ions Aug puaunuooaz o; asnjw osle Amu 1 d99MDM9 Z'g'ZO'bI gdgBwed ut o; pauajaz ggNAO 01 WWI gdezSezed - eluasazdaz aq1 wpw o; ;oamoaut aq pinom 1! `uonndo zo o•S'fi'ZO't l gsnoap s'S'fi'ZO'bt sgduj2md s,gggj 1g ui `3! luoulAud Auu jo jmd Aug zo alogn+ M pa ;ezawnua sluana aql 3o Aim jo aouaun000 aq1 puawwooaz 01 asnjaz Artu gggNIONg 'S am jo aspalmotnl lunmou suq daNmo 'P •sua!Z Aug 3o zgalo pus 00 z3 2IgNM0 zo `.popuawwooaz;unowe otp 1su!u2e,jo - Jas of passed seq luawd[nbo zo `sluualew `zlioM atp jo B o; ggNMO stnpguo swall zatpo am azagl •o -Aug 01 011 1eg1 ou!ttua;ap 01 zo `aoua ;ogzluo0 otp ,lo lun000u uo p!ed sAo' uow aql pasn seq 2IO,LOVujNOa `.suatZ sasodznd lugm zo3 zo moq utulzaose 01 uoggu!wgxa Ions 3o aSzegosip pug uogogjsugs aI1 amoas 01 Aug o lsw of gggNIONg uo /4!I!gtsuodsaz asodun ggNMO of Aiologjsges puog ogloods g pazan!Iap lou [Jiro uo!lgpuOurwooaz z0 matnaz p!es "(lluuog!ppV seq ?IOL,)VRINO0 azagm ;daoxo `)IzoM aql WoM oql ,!o aouutuzopad s,gO,LOVg.LI` OD ql!m uogoauuoo ut polg uaaq aneq sua!Z •q of olquoilddg suoilelamd pug smeq ql!m Aldwoo o; ampq s, OD zo3 z0 `o lazagl `I IzoM atp jo 8u1gs1wn3 luop!oui swgzsozd pug suopngoazd Alajes atp zo zo aouvuuojzad s,gpyDVg.LMO3 3o lun000s uo `uog0rulsuoo 3o sazttpaoozd zo `saouanbas `sanb!uq Dal -daNMO lsum2e spew uaaq ansq swrelo 'e `spoglaw `susaw aq; zo3 zo )[zoM alp 101lu00 zo `;oaz!p `astnzadns of aggNIDNg uo ,cl!l!q!suodsaz asodun :asngoaq [[!m `luatukod Itug Sutpnlau! `luatuAvd Aug 3o uog - dgal HDNg Aq popuatuwooaz lunowg lln3 aq1 -epuatuwooaz s,g99NION9 zou sluawAud Sutpuaw 3o luatu,Cgd algw o1 asn3az Amu daNMO l -wooaz jo sasodind aq1 zo3 )IzOM s,210.L3V2L MOZ) 3o malnaz s,2lggMUDNg zagl!QN b juawdvd ur uollonpad - Cl `2IO.I. 1 'Idolovldl oo 01 - OVUNOD of 1uauIAW plotlgltm o121aNmo allgua daNMO , q p!sd oq lltm anp uogm pug `anp ow000q zo ggNMO Xq Allguo!lippe p!ud aq of 21ALOVdL ((I'ZO't gdrawd 3o suols!nozd aql of loafgns) -NOO allpua ;gsiw 1ut11 sailed aql uaamlaq sanst zo ll!m popuawwooaz ;unowg otp `uo!lgpuawwooaz szangw zag aq 1ou Am watp;etp (p) zo !s;uaumaoQ s,2133r11O1 R Tim 2I3NM0 01 1uauLCgd 103 uoil loeuuoD oq1 u! 2 3aNIDNg of pouS!ssu Alluog!oads - ga!1ddV atp 3o uoilmuasazd zagu skap ual l sa!1!J!q!suodsaz otp puoAaq 31zoM otp 3o suoi ;oadsu! -6E- r r an se samseaw gons wim ,Claletpowun [leis doliv IN00 - antloa3ap Jo alaldwo0ut St 3 flOM agl legs slganaJ uo!loadsui sn g0!gM ut szelnogit,d lle 3o Suilu ut d0j:)vILL - N00 r144OU I[!& Pug ?IO.Lovd N00 PUe ?IgNMO il!M uopoadsw leug a o3pw ,Clldtuold Ipm - dgatZE)Ng •is!l antigival `alaldwoo s! 3oaJagl uotuod paaJSg ug Jo XJOM aigw aql uo swan lo_auoa Jo alaldwoo of smou olgeumou aip Imp ZIO.LOVI.I,NOO uiog amlou uaupM uodfl 'b H0j3VdjN0D Molls llegs dg"o inq `uoilaldwo0 jupuuisgnS ;o alep oqi cage al!S ail wcJU ?I0.L3ddjN00 uoipadsul Jnutd 90•l,l apnloxa 01 lg2U agi angq I[eiS lIgNMO 'S aou unsm •1uatuAsd Iew3 Itlwt - IO.LO` ILLNOD Pug dUNM0 ,Cuadold STitpnSaJ OI'S gdpawd 3o sivawaimbaJ uo SuTpu!q aq ll!m uopepuawwooaJ p!gsaJoje s,2lggPllJNg Pip tplm aougtldwoo of loud mono Xgui il.roM agl 3o uogaldwo0 l gtlugl sgnS 3o aleogpiao ani aql ued jo uotlgJado alumdas io ,Couedn000 ox Z Sutnssi s,2IggNI0N3 o loud Sugym in xaamJNg uuox os pug Su!lum ut astMJaglo aaiSe 2I0 L0`d2LLN00 pus •oiaJagi ssaooe 2IgNM0 ssalun 'saalug.ie18 p ut, sat nM pug `aouemsin Pug joamp loodsw in f4!I!gtsuodsaJ 3o uotstntp aql `satl!ltln `igaq `oommolutgw `311oM ail 3o uopoaloid pug Pug jJoM aql jo llgd legs jo uopoldwo0 lg!lumsgnS `,4;Djus `uoilwado , moas o loadsoi i !m 110.L0VEI N00 jo uogeognuao of loadsw il!M Xldde Illm b0'bt p ut , 2IgxM0 uaannlaq luauirCgd lets SutpuacI sou gdei and 3o suo!s!noid aql `alaldwoo Alletiumsgns aq -il!gtsuodsaJ 3o uotstntp of su uot;epuawuio3aj u2ui Im g d0j, of xJOM all Jo ugd wil sJaptsuoo daamDNg 3I 'Jo3 - :mLLx00 Pug w NMO 01 JQ^!IaP ll!M 1Igg1`IIJNg u011 -aaagl suosew oql Stnm2 Suilpm u! IJOID di N00 - aldwo0 letluelsgnS 3o aleogipgo antlelual alp JO ,Ciantjap 30 pue , da MO 4pou ll!m - daaMJNg ` aialdwoo ,Cllup awu aql id - dgNMO wo-g suogoafgo ,Cug jo uoilwaptsuoo - uglsgns aq al VOM aipjo lied legs Japisuo0 I OU swop Jaiju pag!lsnf Sanallaq - dgglJ1oNg se a OAIIMU31 2IggxIEJxg 3I monaldwoo jo sniels sil oumuolap agl wog saguugo gons Sutloagai (paloomo .io palaldwoo of ) lJoM ail 3o uud leis ;o uo!loadsut ut, aIrtu llugs aq of suialt 3o l s!l a ntleival postnai a ql!M) uotlaldwo0 - daaNUoNg pue `dOIDWIN00 `dgNM0 `isanbaJ jupuelsgnS jo PILOgiu30 anq!wIJaP g ?I0.L0VWJN00 gons Jallta .iage ouip olquumaJ a u!Tll!M *10M p ug 2IgNM0 01 12Al12p put a sdep },j p igs utgliM ail 3o ugd lgil JoI uotlaldwo0 lerluglsgnS jo also mm, wgamONg `alaldwoo ,illgiluglsgns xJOM am siaptsuoo -guuao a onssi ol - dgaNUgNg isanboi pug alaldwoo dUaNIDNg `suoil02fgo s,ZIgNMO 3o uo!jwaptsuoo sage f-llt,tlueisgns pug asn papualut Sl! Joj ,Cpuai NjoM `3I •iojaiagl suoseai oql Suums `Sup" u! ?I0.L0VUN00 Pip jo ugd gons ,Cue sJap!suoo 2I0,L0V - djN00 legs X3!JOU 2lgNMO 01 ale0giu00 anuelual otp ;o uotssiwgns 2un4m u! llaamomg Put, daNMO ,sl!lou Arta Quip Jage Mep b I u!il!M II!M 2IgatZ0M3 `alaldwoo ,Clletlunsgns ,sue w doiovuLN00 '31ioM ail 3o ued mqi ioj lou si NJoM oql mig sapnlouoo gggNIJNg suotioafgo u0!laldwo0 lgqut,isgnS jo aleog!uao g anssi o 2lggll gons S Jage `3I ls paloeltg J o a all -IOl lg lsonboi pug alaldwoo Siletlumsgns st )IJoM 3o suotstno.id ,Cue of se , dgg DNg of uotioafgo uallpM x1aw ail 3o lied gons legs IIHUMONH pug jaN of 01 gotgM Sutmp algogtuao an!lgival alp JO lcliaoaa Jape s,Cep Aip ma ll!m - IO.LO`d2LLN00 `alaldwoo Xlletlumsgns st uanas aneq [leis - d NM0 - ivatuXrd luug aJojoq poloomoo XioM ail ;o Lied gons legs sawfe - golob alMO0 3I io palaldwoo aq of swalt 30 lst[ anilelual a ale0gtluao •alaldwoo Alletiuelsgns pure asn papualut sit Jo3 ,Cpgai ali of pagot,iit, oq llegs aJagjL •uo!laldwo0 lgtlumsgnS jo aq of sanatlaq ggNMO g0!gm 3IJoM ail ;o ugd gons amp aql xg [legs gotgM uotlaldwo0 lepugisgnS 3o aleogtua0 ,Cue asn of 2IgNMO 1!uuod of Supum ui g0jDV -dL an!leivai g 'dF[NMO of iantlap pug aJgdaad lt!M dggNIOxg - x00 isanbai Auto aunt .sue le 2IgNM0 • I `alaldwoo Sllgtiumsgns )l.ioM aql si ap!suo0 - d 3I •io,IaJall suOnaJ atp SutntS S uppm u! - d0jDF12IJN00 -suotltpuoo SUlm01103 aq) 01 10afgns AJ4 lum waag ffJNg alaldwoo ,cllgtluzlsgns 3ltoM ail Ile ,lo uotlaldwo0 letlueisgnS of Jot.Td pagsildw000e 3I10M all Japtsuo0 iou saop X99MON9 A 'uotiolduio0 aq Agw `)IJOM agl 3o JaputewaJ agi 3o aouewTOpad 3o swis aq) au!wialap of 3lioM agi jo uopoadsut uu qew s,'d0.L0d2LLN00 qpm aouaJapolui iugoiU!uSts inogltM [Iggs IMMIJNg Pug `dolo`ddiN00 `daNMO `Jagea.iagl asodmd papualut sl! Jo3 agNMO Xq pasn aq un lgil �JOM ,ClidwoJd - uo!loldwo0 leguelsgnS 3o aleog!uao a onsst otp 3o wed algesn pug Sutuo!10un3 ,slalgiedas g sa 2IggxIJNg legs i sanbai pug (olaidwoom Se - doll` Ul N00 00at' X013VILLN00 Pug `2l MIDNg `d9N2A0 gotgm Xq pais!I Xlleo3!oads swat! Jo3 ldaoxa) alaldwoo ,Clletluelsgns Jo `sluoumoo(I 13er;uo0 all cn pagpuapt uaaq Xlleogtoods st 31 10M aJtlua aql legs S u!1uM ui U99NION9 Pug - daNMO seq go!gM xJoM agl to ugd paialdwoo ,Clle!lmisgns XJ!) llegs 2IO L0d2I.LN00 asn papualut sit Jo3 ,(peas ,iug jo uogdo s,ggNMO le 2lgN.MO Xq asn ;b, SIJOM anlua agl s.T3ptsu00 W010` IdIN00 WgAM •d u0110211!j j 1n11.rnd SO'bI uoYajdwoD IvyuvisgnS b0•bl r r _ob - uotlga?IddV leug atl 3o ldtaow loge sAup ual un11lM `IffM 2I33NION3 `POIlgln3 uaaq aneq slumtunooQ loan puu :sluawnooQ lou -IuoD -PT -uoD aql lapun suoge8ilgo latpo s,21O,loV&LNO3 iapun suollla8ttgo Sumuuuoo s,lao j DWJ NOD wo$ puu pololdwoa uaaq seq 3110M 01 11 19111 Pagsqus to `malatp poiltaads somuetutt8 luioads Auu 3o mull St wa3NIDN3 sluaumaoQ 1aell at1 Aq paitnbal agl to sluatunooQ lm-woo aql tp ?M Aldwoo of ainlre3 se uollmuawnoop BulAuedw000e ptm Iuou Aed IN UOR W04 `40'bl gde18eled of luensmd uotloadsut leug -Bogddy IEUU aqi 3o MQUai s,ggatgONg PUS `uoq la8u 8umadde 3110M anllo0;ap wolf `suarl paluasun - oadsut lqug puu uotlonnsuoo 8uunp 3I30M OIR Jo U011 wolj 8u?suu sunulD ldaoxa `2IOLD`d2iLI�IOD - en.tasgo s,g3allIDM9 Jo stseq atp uo `3I t Isu?la8e - agNMO Aq stutuiD file 3o .10AI M e 1 ' aouvJdaaal+ pun uouvorlddyfo ntainad •g :alnitlsuoa If ?M 1uawAed Ilaug jo aoueldaooq pule 8u?)law OU 'y ua ?Z Aue lsu?u8e 2iaNM0 A3tuutaput of - agNM0 01 tiolale;spes Irialelloo su11vjO fo aaAMAI 60111 10glo 10 puog a gs?wnl Auw doj.D`d2I LNOD `fln3 U? ld?aoal to asealal q gons gsltutg 01 sltu3 la?lddnS •swtu103o lan u alnlu 1 0 lolagnuoaqnS Atm 3l 'pogsllus as?nuotpo to piled lou lluts II lugs ldaoxa `luatuArd IVutj 8u?tttano8 suotltpuoo uaaq aneq algisuodsoa aq Aenm Aue ui 1t18tw Allodoid p suual oqI laptm apew oq iletls luawAud gons •luomt ud s,Zlaf•LM0 to agNMO gorgm l03 x agl g11M tons lo3 uolleottddd oql g1lM ldaaNIONg 01 - dOJ D` UL paloouuoa ssaupalgoptu laglo pule `sll ?q ivawdmba - NOD Aq paulwgns oq llegs pmd000v puu palaldum ptm Ivuallaw `sllolAud Ile (n) put °pglg ag pinoo AIIn3 NIOM atp jo uolltod IrT lo3 anp aouullaq ag13o 1uawAud uar u goTgM ioj lua wdinbo pure `19pal `saa►nias mp of dams 0111 3o luasuoo uauunn agl 1 10'S gde Bmvd `loglal Itla apnlout sld?aool ptm sasualal oql (i) :ltgi ut paltnbai su pagstum uaaq aneq spuog3? Pula `luoul2oi2y 2IOLDH2I.LNOD 3 I?nepUJle Ue Puu Iln3 U! 90990101 ' aql ut palulndps a8utn01 oql uugl ssal st Paloauoo to to sld�aaal gsltuttl Auw 2IO LD'd?I LNOD `2I3N�410 e1 palaldtuoo X11n31ou XioM ioj - daNMO Aq plaq oq of ootmIuq Aq panoldde sla put Z'y'LO'bt tdet8lallad u< pagloads 8ulmuival atp 3l - paldaom pus palaldwoo Alltt3 31.toM agl JO SUa1-1 Jo slantlaM 10 saslaatat OT Jo nall UI £ uotytod Iuip s41 anp oouuleq otp jo luouard aNew `wowa218y 1 atl 8trnlaunwal 1n Pule ` 3o u0►llapuaww030l •)IJOM aql glint uopoauuoo to patg cua ?Z to jo pus luatuAud ioj uo?luottddy Ilatnij s,ZIO.LD`d2IMOD lno Suisile sigBu uarl isle 3 OdaNAO 01 AsaloeJstlus) 3o idlaow uodn `Ilsgs -dgNMO `suuguoo os 2 99NION3 slantgM to sasgalal anlloa la Alte8al put alaldwoa I? pue `paAglap Allueagni8 ?s sl x10M agl 3o uo ?latdwoa (rtt) ptm :luamW luug of `Aue 3? `A ;arcs atl JO lugs Ilew3 do.L3'd2LLMOo 3o 11ngj ou g8non11 `31 'd .-UOa ( ? ?) `L'g'b0'S gft2 tBdgns Aq pa.nnbal aouwnstn 3o aauapTna aqI 01 pal ?w ?l lou inq 8tnpnloul `sluaw padviaQ uortaldwoo Imij 80'bt -nooQ MUIUOD at1 UI 103 POtigo uotleluawnooP IIE (t) :Aq (Palanttap AIsnoitaid se Idaoxa) palUedw000la '2IO LDN2I3.NOD of -agNMO Aq aq (tugs ivawAlad lo3 uouuollddy lqutl oqj 'Z pled aq lltnt anp uagM `pue anp awooaq Ilion dgaPl - IONa Aq papuaunnoow lunoun aql `uoiluluawnoop sluatuAlad ssa t8old lob ampaoold atl Sul Su?Auudw000u puu woulAud aol uoplaotlddy agl3o 2Ig - M011o3 luatUAed Ilaug lol Uaplaogddu a�tuw A= 2IO L -i`lMO of uolllaluasald otp loge sAup Aingl I -DVdiNOD `sluawnoop impo Pula `(Zf'g gde 2md U? pap►nold sla) sluoumoop plooal dn- pa3lmw anQ sawooag luawe(vd 'D `uonoodsui 3o sollaogtuao aoulamsul 3o aouaptna laglo to satuogtuaa spuog `saalumnS `solttpagos •lumixud 103 uoliuollddy `suotlotulsu► Bupriodo ptm ommuolutuw flu `sluaw atp ltwgnsai puu suotloauoo kmssaoau oql xima -noOQ iola.TiuoD aq gllM aouuploaoq ut `Paianifap sug llugs dolo`d2INGO aseo golgm ut `luatuAud flaug put= uotloadsuT luug aql 8uunp pag ?luopt su01130noo puatuw000i of 8ulsnjal ioj suosual aqi BwluM ut 3ut [Iq paialdwoo Atuoloulsties `d9aK1DK9 JO - 1EO1P `dolo` ILLNOD 0l IuaurAed loj uoillaoTlddy uotutdo aqi uT `seq 2101 Dv t oD 10 811 t aql ultual IIfM 2I3gNIONa `as ?MlatiO '60'bI gdvAund 3o suo?slnoid otp of loafgns olquicl000e luawdvd.rofuorrvoyddy 'y si illoM aqi Imp 2IO1D` X LKOD Puu 2laNM0 01 aotiou ual3pM an ?8 oste Il ?^n - dagNIONa awl) awes lua tu�Cvd Ivu�d LO'bt aqi ly 'Iuamw ed 103 -daNM0 01 IuatuAud 103 u011 - eotlddy oqI Iuasald put luawAud 3o uotlepuatwuoogl satauatagap s,2lggt•1 DN[3 BtnluM ut aluotpul `IuawAed 10J gons Apaww to X1OM gons alaldwoo of Alussaoau Ib- r aft, o M in tgd se o q f .l q 2IO.L0V2LLN00 P. g ?I3NM0 q m m uol jo a1tS agi le paiols l uawdmba pus sleualew IIe xioM MR Pug :sjoglo pus ui alt,jodimut `(uotsjanuoo io ssvdsaul jo3 2IOL.7V2i.I.N00 `sjatiddnS `sjolaguluoagnS cptn+ slagquoa palt,utwjal 01 1 4i1lgett lnomiM) 2IO.L0VEIN00 Aq Pam aq Pinoo Amp 3o luawaluas ut pa mour (sisoo uopniosai alndsip lualxa lin3 aql o1 awes aql asn pue `aztS otp le fjoutgoew pug jaTo jo uorl=!gm io linoo lie pug sTguoissajoud `luawdinba uoilorulsum `saouvildde `slool s,gO,LOV?I.LN00 iaglo pus `sAaujout, `slaaltgo.m `siaaut3ua Iie 3a pug �ioM atll 3o uotssassod aiigl pug `alts aql wail 3o saRugga pug saa3 [It of paltwg lou zng 2utpnloui) 2IO L0V2I LN00 apnloxa `dO.LOV?I. KOD 3o saotnjos atg saogump pug `sassol `slsoo `swtgio tit .103 £ alt,utuual `aotlou uauuM SAUP uanas (ALM 3t gams MR pug) 2I0.LOy 2I.LN00 $utntg cage `htu )fgXMO- `maoo b''ZO'g l .sasuodxa qons uo lgoid pug pgagtano gdg dgJgd uI pogtluapt sluana Dill 3o ajow io auo 31 g joj stuns olquoseaa pug ml snld `SlioM palaid -wootm t ptm uopoauuoo ut sluaumooQ lorguo0 otp •sluawnooQ Xq paitnbau su luawdinba m `slgualm `togel �uigsiu lornuo0 aql jo suoisinoid Aug 3o km iuiluglsgns -irg pus saoLu2s Sutuugliod in uocleuiuual jo algp Aug ut uogg lotn s,-dO LDV21.LN00 'b mpoajIa aql oz joud pautglsns sosuadxa io3 Z J `Ugg DN3 jo ' `.)IjoM - joglnt, oq jo pivEajsip s,2IOL0V2LLN00 £ qons uo lgoid pug pgagjano io; stuns olquuoseat pug =till gutpnioui `uotlguiuual 3o algp antloajIa all `uotloipsunf Suint,q Spoq otlgnd ,Cug3o suotlginRag of loud sluaumaoQ lagjluo0 aql gzim aottgpuoaa13 to pa jo sMg7 3o pugSaistp 2I s,O L0V?I LK00 Z - lnaaxa IoM algt,ldaaot, pug palaidwoo io3 • l • `•(b0'9 gdgifted oz lttensmd Drug oz atutl woj3 :(swalt gue jo uoiluo!ldnp 3nog3tM) ptt,d aq palsnfpt, sg LO'Z gdw2=d iapun pagsilgmsa alnpagos tuts XO.L0V)I.LN00 `oseo qons uI •lot,4uo0 aql alt,umual ssai�?oid oql of ajagpg of ainprj to watudtnba jo oz lama `ggTgMO jo Apauuai jo 3tISu jaglo Aug of aotpnfajd slt,ualt,w aigglcns so sjailjoM palinTs luataljUns Aiddns lnotimm pug asngo 3notwm `dt,w damm0 ` JNg Pug oz amTte3 `ol paliwil zou lnq `2utpniom) sluatunoo(I 2iOL0V2LLI�i00 of a:)gou uauum sAup uanas uodfl •V =41100 oql q /A aougpi000t, ut �TjoM aql uuojiad of ajnitg.I lualstsjad s,�O.L0V2I•LN00 • I aauatuantl00.rgda1vutuua,L dVNYyta0 £O'SI :asnvo io3 uoneunuial Xjgsnf Iltm sluana ' tuo.0 2IO.L0V - d LN00 asealai lou dutmO1103 aq1 jo ai0w jo auo Stru jo amaam000 OU •V lI m - dgNM0 Xq ZIO.LOV�I.I.N00 onp sfauow 3o luaujXgd to uoqualai AuV •otuaos iaUeajagl Aim gotgM jo Suilsixa asnvD , ofaivurwaydvWWgNM0 ZO'SI uagl uO,LOV- i.LN00 3suigSg damm0 3o saipatuau io sigsu Aug laagg lou lum uotlgutwual aql `daNMO Xq paleunwaz 'S0'01 gdziSmd ut paptnojd os uaaq angq samAjas s,gO,LOV?I. NOD ajigM . 0 se io3ajagl tut1310 g sa)igw gO,L0V d LNO0 3t uotsuadsm qons Aug of aig13lnquuu ,Clloagp `ipoq io `saun lorquo0 •po uio3uad 4joM atp aql 3o uoisualxo up io aoud lot,guo0 agl ut luaxajsnfpu ug joi aoud lsamol aql uingo of pajinbaj aq lou tiggs - d NMO paMOIR a q llggs'HOI.Dvdj,N00 'poxg os alup aql uo )I =oM r gdv,am' d sitg iopun saipatuai m slqi?p Am 3uTsioma uatuA aql awnsai liggs - dO.L0V - d LN00 'patunsaj oq Igm JIj japjO aSugtlO g ut palgjodjootn 12lggMJNg Xq panojddg gatgm uo a1gP Dill x13 Itim goigA 2IggNIJNg pug 2IO L0V2I l os uagm `pug ssauaiquuosvw imp of se 2IggI [)Mg Aq - 1 lO0 of 2uiluM ut om ou Aq sAgp anilnoasuoo 06 uggl ajow patAomai oq Iltm 2IgNMO Aq paujnout so2uwup pug `sassol lou jo pouad g ioj 3oaja41 uoiljod Aug io �tjoM oql puodsns `slsoo `sunvlo gonS '2IgNM0 of oouaiajjtp aql Xud Ilggs Cgw - daN-YAo `osnva lnogltm pug awil Sur 3V - V 2IO.L0V2LLN00 `aaueleq ptgdun qons paaoxa saEgwgp pug `sassol `sisoo `swtgio gons 3I '2IO.L0V -djN00 of pied aq lltm 3 ljoM puadsnS XvW - dgNMO 10 ssaoxa qons 1 31ioM aql &gjaldwoo of Suilulau jo jo ino SuisLm ,IgNMO Aq poutglsns (sisoo uoilntosai alndsip iaglo jo uotlt:j yt io moo ile pug sluuoissa3oid jaglo pug `s�Cawoug NOILVNIY1I2I91 `sloaligam sloatusua 3o sosjugo pug saat 1113 01 paltwtl (INV NNOM 10 NOISNgdsf2S - S1 3 zou lnq Suipniotn) s02gurup pug `sassol `slsoo `swtgio Ilt spaaoxa aoud loanuo0 oql jo aouglgq ptgdun all jl •pogsiug st JJO /A aql 19un 3uaui, ed iaggrj AUE aniaoau 01 paililua •paivasun llps am gotgm duppm aq IOU ltt doLovUjN00 `asuo qons ul 'luaipadxa to opetu Aisnotnaid asotp ump jaglo -daNMO lsutg$g tuaap Agw 2IgI.IMO sg ilioM Dill gsiug put `ojagmasia palms 2IO.L0V2l.LN00 Aq swlg10 ilg Jo ianit,M t, Z r - Zb - sr oafol a o nn ut Palgogl d R f .q alu;s aqi 3o Mgl atp Aq paumAOS aq of st loeiluoo sRL 'V a iue30 l oadsat tit suouelnSa21 io snne7 Aq io sluautnooQ lo=uo0 aql jopun angq astm1otp0 Auut ntn Sutllo.11u03 SOLI lagpa s2 satpauiai io slgSu qons aslwaxa AM W I DVII,I, - NOO Pug IdaMMO `50'01 Pug 60.6 sgdrAuaed jo suoistnoid •ivamaadv oql jo uoualdwoo so uoprunwal agl of loafgns pus `quo3 las uaaq suq ampaooid pug poglaut ao :IaoM aqi 3o aoueidaoog pus `uoualdtuoo ° uatuAvd lung ou 31 'suoptpuo� tisluautalddnS aql tit guo3 1as su aq llegs oAtnms IIpM `sluaumooQ 1o=uoO atp tit paleotpui suoileStlgo Cue 3t `Sainpaao.id pus spoglaui uounlosai aindstQ 'V Sumuuuoo Ilia su Ilann Se `sivaumooQ 13guuoO aql glint aoulqu000s u< uantS so `Aq pannbai `tit apetu soaluu 2 pus sainpaoord pun spoylayy TO'9T `sautte MA% suousogtuutapT suoilmu2s2idai ITV •V su0:1DSrl40fo Innln.ms tb0'LI NOI.Lfl IOSa2I gincisla - 91 alioLLUV �Cldde Aagl gotgM 01 ,Cpatuaz pus `lgSu `uotlgStlgo `,Crop telnotugd pea gltM uouoauuoo tit sluattmooQ -gdeiSmd sap Aq pautuuad su ioeaiuoO alp ut Alleagtoads paisadal 3t se anuoa�la �lioM aq1 $utddois s�2IOLOV2T.LN0o of algmngt=R 4poanp se aq IIIM gdu2amd stgl ;o Suotstno.td ag1 pus `SluoumOoQ o tuep to sasuadxa 103 astMtaglo .to satuts 13e4uo0 i0 aoud 1o=uoO agijo suotstn0.td ntpo Aq so `oaluetenS so Aluwnm jaiMuoo ut luaugsnfpe tie io3 SOOT gdrB=d iapun unulO letoads Aq `suouelctSa- .to sMe-t Aq olgeltune so pasodun g Sut)lulu w04 210,LOV2L NOD apnl:)wd of papualut lou asinuaglo an gotgnn uiatl;�o IIg to �tue o1 aigeltene Satpauia� am b0'St gdraSuted st jo suoisteoid aqs 'uoaiagl 192talul pug SigSu Alm `30 uotlguunl a se ,Germ Cue ui pangsuoa Sutpniout `2iO LD'd`.I LAIOO anP siunoute eons IIe 3o apeut aq of iou an puu `01 u0lltpps tit 0 -m 010 satugd aql st luatu,Ced Ipun 31zoM aqi does `aaaNIJN3 Pug - daNA o of .tapunalaq 214el1ene satpauiat pug S1gSu alp pug suotitpuoO 01 aotiou uauunn iagu s�Cep uanas xetu do,L `anp IutauaD asagl Aq pasodun suoueStlgo pug satinp aq j 'V aq of pautuuaiap Alleut3 ums Owe -HojovajxoD ,Ced of s,Cup 0£ joi Pouri seq 2IaNM0 So `paultugns st 11 iagu shop satpatuayanunlnwnD £0'LI 0£ utgitM ivautigd .to3 uoum!lddV uu uo log 01 p211e3 Seq dagMtoMajI `Apauzat so igSu taglo ,tae of ootpnfaid 1nopm uouelndutoo aqi uto.0 paiituzo oq lltM Cup guns pug to AUOD aq1 Suuuttttutal ,lo nag ul '£0'51 gdeAutsd `uotlotpstmf olgeotldde app noel aq1 Aq Agptloq IeSaI a apeut to paptno.td se suuai gums a p uo luotu�Ced - daMMO C u uo m ArpunS .to �CspmieS a uo sllej pouad qons ,Cue 3 q o uio ianooa.t pug loeriuoO atli aleutuuai `atuu iegl utgitM ep ,Cep isul agi,ll 'pouad gons jo Cup lsel aqi apnlout puu 1sni 211 amltu3 so uotsuadsns eons ,tpatuat lou op gggl.Tl'Jl lg 10 a n oxa of aindutoo o iM a `sA AC sluatunoo ioe�luo 'agNMO paptnotd puu `uaaruoma puu uaKm0 o aotiou P I P g IT. gP q Q � aqi tit 01 paualar si atup Jo pouad Cue uagM - V u21111M Sep uanas uodn ,Cent 21OZDVUIMOO uagi `anp aq 01 pautuuaiap Alleug ums Alm 21OyOV2LLNOO Aed of sAup saUgL fo uotlnlndtugD ZO'LI 0£ Iq3 slte3 UgNMO to `paiituigns st 1t .rage s,Cup 0£ unP!tA lumixtd iol uotieot[ddV .Cue uo 13e q1 sltg3 2IaaNIrJNa 7 O 'aotiou ag13o 1 2AIS aq 01 unl oinl `f4poglne otjgnd .tag .to unoo 3o i 2pl0 tie tapun 1 0 2IaNM0 Ssaippe ssautsnq iml oq1 of `ptedaid aSeisod `Tutu pautuao 4q S,Cep antlnoasuoo 06 uegl glow Jo3 papuadsns st iltoM so palalsisai Kq luas io 12 P 210 AI1 2 P 3t 10 `papualut sI 1I tu0gM a ql `2IO.LoV?I. Moo 3q jlnq 1 0 iou ou tlSnoap °lI 'V .tql uotlemdim aqi 3o mgjo ue 01 io uug agl jo iaquiatu a 01 so Ienptntput aq1 of uosiod ut paiantlap.It uantS XIPtisn uaaq alnurw.ia,L ,oxaol2 doig�ivylyoLDvy.LNOD 170'9 T aneq of pamaap oq ll!m ii `aotiou uallpm JO Surat$ aq1 sannbal sluaumoo(l 1oe4uOD alp 3o u01stnold Aug ianauogM 'V 'uopeuiuual qans uutog Suulnsa.t jo jo 1no Sutsuu ssol otmouooa jaglo .to onuanai 10 %Uoid paledtotlus 3o ao:lo)l 2U I0 - L I ssol jo lun000e uo pted aq 1ou 1ptls - HojoV2LLNOD 'S •uotluutuual of algelnqune SfIoaN " IIH3SIN - L 19'T01.L2IV A113011P sasuadxa olgeuoseai iql 'b 88 I006PA I •Apeoluoaloala aoloealuo ay1 0} alge11eAe spew aq lou lIlM sluauanoo( panss! aq illM suopogpads pue sueld 10 s s IIn1 AIuO •palsenbai sluawnoop ayI aol slsoo Ile aeaq lleys b010bb11\100 ay1 uo aol (lea le"Ou s,Mulbu3 ayI le b010`db1N00 ay1 of payslua aq ll!M 6ull}pied ll OI Popw lou Inq 6ulpnlou! `�1aoM ayI 10 uoilnoaxa ayI aol Ajessaoau sluemoop 10 saldoo [IV : ayl 91nI!lsgns pue , 49allue s1! u! 91919( :S1N3Wf100(i 30 S31d00 Z0'Z SU311VW AlIVNIWi1321d - Z 31311UV JOUmO qPm Iuauaa9J6y s,Jaaul6u3 Aq peupialep aq lIlM sly •slseq auall ped a jo slseq 9uall lint a uo loaaayl lied �(ue ao ells ay1 of pau6lsse aq �(ew (bdb) 9n!lelu9s9jd9b loafoad luap!sab ayl - 3AI1d1N3S3bd3b 103m' lcl 1N3(IS3b : 9y1 PP`d 'Z5'b' 60' I• •pauaaolaad aq of )IJOM ayI aol P!8 a 6u11 wgns aanluan Iulof ao `uolleaodaoo `dlysaau:ped `lenp!nlpu! Auy - b3((19 :6u[mOIIO1 ayl PPV 15'V 60' 6 'b33NION3 ayI Aq Paullep se asoclind papualul ilayl aol sa11I11oel mau ayl to seinleal Ile asn 01 b3NMO ay1 to AIII!ge ayI Aq paullap s! uollaldwoo Ielluelsgns `lea9u96 ul - elnpayos loafoad pasodoid a 6u uegm Iun000e aadoid o1ul luauaaalnbaa sM ONel Ileys b010HbiN00 ayl 'uollolpslanf 6ulney s91ou96e Ile W04 aouuas aol asealaa 10 luauaulelle ay1 6ulpnloui sall!Iloel nnau ay1 9ol/UGS o lui d9aN pue eoeld of Al!I!ge ayI Aq paouap!na aq lleys NJOn 10 uollaldwo0 le1luelsgnS :uoll!u!lap sI! 01 6 u 1 mOIIOl 9 y1 PPd - N01137ldW00 IVI1Nb'1Sef1S 'Eti'd ml, Aq panss! aq IIlM paaoad oI aolloN pue penny 10 aoR 'b33NIJN3 ay1 ON ay1 y10q `b3NM0 ay1 Aq palsenbei 11 :uoll!ullap yoea 01 6u1mOIIOl ay1 ppy - (133008d Ol 30110N 6Z'y 60' 6 (NV (b`dMV d0 30110N WY 60' 6 A90IONm31 aNV SNOI11NId3a - I. 3101121V •suo1l!puo0 leaauaO ayI u wegj 01 pau6lsse s6ulue9W ayl 9ney (uoll!Pa 9666 `8 'ON 0(0f 3) Ioe.aluo0 uollonalsuo0 ay110 suoll!pU leaauaO p.aepuelS ay1 ul paullop aie yolynn suoll!puo0 tieluawelddnS asayl ui pasn swial ay1 •109,19 u! uleuaaJ Ileys suo!1!PuOo leaauaO ayI 10 suolslnoid paaalleun IIy •(uOMPa 9666) `8 - 0666 0(0f 3 `„Ioealuo0 uo gonalsuo0 ayI 10 suoll!puo0 lea9u99 paepuelS„ ayI 01 ppe ao `woal ebueyo `ApPow sluawalddns 6 ulnnollol ayl SNOI11aNO3 WHEIN39 3Hl Ol SN011ION00 ANVIN3W3Iddf1S 881006JAk Z 'ails a4j le suoljlpuoo ooe}insgns bululwaalap o} joads9i 4l1M AI<lllglsuodsaa llnj 9ne4 IIe4s 21010` IN00 a41 :4}lnn 9oeld9a pue Alaalju9 sjl ul 91919p -1, V Z017 uo :S1NI0d a30N3213:11321 !SNOI11aN00 TdOIS kHd aMd 30v321nsanS 'SaMdl 30 All IISV11VAV - V 3101121H - s}uewnoop }oe.iluoo a94jo Ile J9no eouapeowd seNe} luawaaa6y aqj pue suoljlpuoo ao lelJajew 6ulje01pu1 Spua691 aano uJ9no6 IIe4s s anlldljosep `pewao}jad jo pa4sluanl aq IIe4s slepejew Jo l.iom jo Ajljuenb i9jeaa6 eqj `sbuimeip 9leos hews J9no ua9no6 Ile4s s6UIMeJp aleos 96ael `s}uewainseew p9leos .lano ua9no6 (legs sain6lj `s9nl9sw94l u 99a6eslp s6ulmeJp a4j JI - s6ul�neap 94j J9no ua9no6 llegs suol}eol loads aqj `sbuimeip a4} pue suolleoljloads a4j uaamlaq Aouedajoslp ao aoiaa ue spur 2]010 "1N00 9 41 `NjoM a43 jo eouewaojaad 94j 6uunp `jl 'J9uuew anlsuadxa ajow 9qj ul paaooad of palo9la se4 - doio -LN00 9 41 1egj aouapina se pawaap aq lle4s Aoued9aoslp ao Ajln6lgwe `aoaa9 `Iolljuoo a }iodaa o} 9anile3 'Q 1 :I,0'E uo!}oes 016ulmolloj a4j PPd 3snm `9NIaN3WH `1N31N1 :S1N3W(100a 10V211N00 £ 3101121V 'Ienoidde s,J9au a41 o} 109fgns sl pue Mul6u3 a4j �(q pailnbei se 9q llegs sanlen J0 elnp94os a43 aoj pasn po4law uoljejuasaid pue jewjoj a41 'b33NIJN3 aqj Aq 9oue}deooe of joafgns sl pue s1soo }oefoid }o uoljngljjslp aadoid a4} molle of `squo6aleo a}eudoidde Aq pue `Ile}ap jualol}}ns ul umop ualloaq aq llegs sanlen Jo alnp94os a41 E'9 90'Z u0 016ulmolloj a41 PPb' •sluewnooa joea}uo0 eqj jo sluewaalnbaa a4j 4}iM suollemasgo s14 pa}elaijoo pue `pewaojjad aq of sl �joM aqj 4o14M aapun suol}lpuoo leool 941 Qm ilasw14 pazl.ielllwej `salj!I!oej bullslxe jo sueld elgellene p 9M91AGJ `91ls 94j p91lsln se4 a4 1e43 sluesaadej 2j01Ob211N00 a4j joealuo0 a4} 6ullnoaxa A9 '3 . i JoM aqj jo uorpod 4ons aol ejed }onpoJd ao sbuimeip do4s panoidde `pa.unbei ejggm `jo sjuawnooa joe.iluo0 }no4linn awl} Aue }e NJOM 941 jo uol:pod ou waoja9d lle4s UOiO dZ11N00 941 4 :50'Z uoljoes o} 6ulmolloj aqj ppy - Aoued9aoslp ao Alln6lgwe joaaa `}olljuoo 94j `Aq pasneo jo `ql!m pajeloosse s}soo Ile COI 210lO"iN00 94j 9sodx9 lle4s pue jeuuew anlsuadxa ajow 94j ul paaooad 01 p910919 se4 2J=Vl I1N00 a4j je4} aouapina se pawaap aq llegs Aouedaaoslp jo Alln6lgwe joaj9 `}oll}uoo a :podej of ajnlle3 :'b' 90'Z u01139S 01 6uimolloj aqj PPS/ M110nUISN00 ON1 IViS 31:10=139 507 •ul9a94j p94s aq �(ew se 9}ep X9410 - di 4ons jo luawe9a6y UOiO NOO a4310 91ep 94j 9q lleq's it `paaooad 01 9011ON ou sl 9J941 A - paaooad 01 9011oN a ul p94sllgelse 9}ep a4} Si NJOM 94110 1ua1JJ93u91JJ J0 9jep 941 :buimolloj a4} ajnjl}sgns pue fqail}ua sp ul 919190 :4330OUd 01 30110N 'S3W1110`d iN00 301N3W30N3WVV00 E07 881006AA1 £ :9Al1091ad s,aoIoeaIuo019 saaunnO >Isib Ily :suoljeaad0 V saslwaad 6ulpnloul) :Al!l!gellleaauaOleloaawwoo z 000`005$ Al!I!gell s,a9Aoldw3 •o AjoIn}ejS s,uewaaogs6uol (•6•9) leaapa3 elgeoliddy •q AjojnjejS GIBIS •e :uoljesuadwo0 ,saaNaoM I, •slunowe 6uimollol aqj uegj ssal IOU COI Obeaanoo ap!noid llegs to gdei6eJed Aq paalnbaa aoueansul eqj aol Al!l!gell jo sl!w!I a41 '0 : 9 41 PPy :30N"nSNl ki[IIBVII S-a]= b1N00 ti0'9 •pallslles si juewailnbaa sl4j Igun pewaojjad aq llegs Wm ON 'b33NION3 941 o} 6ulpaoo9a 4ons jo aouap!na ap!noid pue pawaopad aq of s! N iom eqj 9i9gm Ajuno0 a4i ui spuoq juawAed pue eouewao}aad Ile paooaa Ile4s UO10"11\100 9 41 : 9 41 PPy '8 60'5 �s�uawnoop plq a4� u! papinoad swaoj eqj uo pallddns aq lle4s spuoq Ily 90'S9Z uoljoeS sainjejS ep!aol jo sluawaalnbei aqj 4j!M Aldwoo (legs spuoq a41 •sluewnoop }oeilFuoO 94j aapun suolje6llgo s,2�010b2�1N00 Ile jo juaw�Ced pue eouewaojjad lnj4l!el aqj ao} Apinoas se aou ' joea }uo0 aye 10 %00 of lenbe junowe ue u! 4oea `spuoq iuewAed pue eouewaojaad 4sluanj llegs b010y2i1N00 :buimollol a4j ajnj!jsgns pue aoualues isig a4j 91919( :SaN08 b3H10 (INV 1N31N kVd `30NVMJ0A13d 'y 60 33NvunSNl aNH SaN08 - 9 313112tH r - pajou aslnna94 }o ssalun wnlred leolIJan 0 leuolIeN a4} uo paseq aie suoilenala Ily •suolsuawlp paleos aano aouaiajaid 9ne4 suolsuawlp U9:4!JM •sapea6 pa4slu1 aae UmOgs sape.i0 •aoAananS IeuolssaJoad s,aojoeajuo0 a4j Aq pap!noid eq llegs bu uoljonalsuoo Iiy •s6uime.ip 941 uo p9111juep! aae 4o1gm jo julod 6ullaels pue 6uljeaq a4j `aullaseq e woaj pegsligelsa aae sbuimeip aqj uo umogs suolleool IIV :'90'•b uoljoaS 01 buimolloj a4I ppy 60 4dea6eaed `sjuawaalnba�j lejaua0 '61,01,0 uol}oaS 4I!M aouepa000e ul sbulme.ip aqj uo umogs we sainjonals pue salj!I!jn 6 ullslx3 :6U1MOIl0j a4l P9SUI PUe '8 ti0••b U a}alaQ r •uollewaojul paooei oljua4Ine pue aleinooe jo uoljejuasaidai algeuoseai a eq 01 2133NIJN3 JO 213NMO eqj Aq buipi ui pewjijuoo uaaq IOU se4 j! ssalun aleinooe aq of IOU pajoadsns Algeuoseaa aq pinoo je4I elep Aue ` ve ZO'i :'8 ZO'b uol}oaS o} 6 ulmolloj 9 41 ppy r 8810063m tl-DDS sl Ioajegm Idlam `210i0 iNOO ayl of seaAoldwe s,�133NIJN3 ayl PUB `�t133NION3 ayl `2ANMO ayl Aq Pled puey ul (00' L$) JelloP aUO L :ale saslwoJd s,�JOlO` iNOO ayt Jot suolleJapisuOo ollloads ayl `salnlelS ep!Jol3 `90'gZL uolloaS to sluawaJlnbei ayl yl!M aOuewJOluOO ul '3 •suolsslwo Jo sJoJJa IeuoissaloJd woJl 6ulleuewe Al!l!gell sll JOI 1:133NIJN3 ayl 6upaloJd eoueJnsul Xlddns of pelebilgo eq bOlO"iNOO Jo 2ONM0 ayl Jaul!a leyl `item Aue u! `6uumbei of se perulsum aq of IOU s! 2133NION3 ayt JOI 96eJ9noo )(!I!gell leuoll!ppe ayi L LKE: ep!Jol=l `yoeaa wled ISM AemMied elsln L09Z seeAoldwe Jlayl pue _Oul `slpeoJy - b33NIJN3 69KC l3 `elsenbal 9AU(] elsenbal gtC elsanbal to a - H3NMO :saweu 6ulmollol ayl ppV "Aollod ApipB!l IeJauaO sAJOlOV'diNOO uo paJnsul leuoll!ppe se IuawasJopue Aq papinoJd aq Ilegs H33NION3 PUB H3NMO JOI 96eJanoo Al!l!gell leuoll!PPb a 000`000` L$ aouaJJnooO yoe3 :96eweQ A:padOJd 000`000` L$ aouaJJnooO yoe3 000`000` L$ uosJad yoe3 :Ajnful Al!po9 'q (JO) 000`000` L$ eouaJJnooO yoe3 :a6eweQ ApadOJd - Q Ainful Allpo8 B ( pally V paunno- uou- paseal- Jaunno) :Al!l!geil al!gowolny anlsuayaadwoO £ (say() lenloeiluoO T (sayO uolsnloxe anowaJ `a6eJ9noo no 'o 000`000`Z$ :knfulleuosJad - q j 000'000`Z$ ale69J66y suolleJadO palaldwoo V s,lonpoad ' 000`000`Z$ ale6aJ66y 000`000` L$ aoueunooO y3e3 :96eweQ A:pedOJd ig ijnful Al!po8 'e (96eweQ AIaadOJd wJO3 peOJS 88 to063m S - 0JS Vv 90 UOII096 016ulnno o a } ppy II � y :jl wa }l us of lenbe Alleuoljounj paaapisuoo aq stew juawdlnbe jo lepajew }o wep pasodo.id a `L•y 90 ydei6eied slyj jo sesodind ao :bulnnolloj ayj yllnn eoeldaa pus • L •y 90 uoljoaS ul „b„ 6ulpeaygns of aoud eoualues Isel ayj a}alaa •6ulllann ul 1 2:133NIJN3 Pus b3NMO ayj aslnpe yjlnny}Joj Ileys bOlO"iNOO ayl `aauuew aVl- ueLUNJOnn `pooh a ul pajeougej IOU sl awes ay} sapnlouoo bOlO`v?J1NOO aye pue lelaaIew 10 wail Aue jo uoljoaaa ao uolepe }sul aye sanoadde a3NM0 ayj 10 anlleluesaadaa aayjo ao }ua6e us }ey} Juana ayj ul •sjuawnoop asayj ul y:pol jas eq view se `aa}laq jO `b33NIJN3 ayj Aq peuljap se `tilsnpul ayj jo piepuels ayj of `Isoo leuolllppe Inoyllnn leuoljounj Allnj pus epledwoo `a}aldwoo aq lleys swelsAs Ile pus sped ay} jo uoljeulpa000 Pus uoljonilsuoo ayj aol elglsuodsaj eq Ileys UOlOVIlNOO 9y1 WOM 9qI }o adoos Pus }deouoo `u6lsep eqj jo oinjeu ayj aleolunwwoo of papualul aae sluewnooa joe.iluo0 ay1 uoi Oa o 15UIMO o a • b LO 9 .� S � II � 41 PPd S31111181SNOdSSIH SM013VNIN00 - 9 31011W •aaunnO ayl 01 u9n16 ueaq sey aoljou ualiunn aolad s,Aep 4!qj Iseal Is pun pebueyo Allelia}ew ao peleoueo aq }ou IIIM papio}}e 96ea9noO ayJ jeyj uolslnoid a uleluoo lleys 9 90 pus y 90 sydea6eied yjlnn eouepj000e ul aoloeiluo0 ayj Aq paulelulew pus peseyojnd aq of pajlnbai aoueansul jo salogod ay1 •juawAed aol uoljeollddy us ul pepnloul aq of aae NjoM ayj jo suoll od yons uaynn Ilsuejl ul ao ajls ayj }}o Pus uo pajol!s NioM ayj jo suorpod uo aoueansul Apadoid aepwls ulelrulew pus aseyoand lleys aoloealuo0 ayj `suolllpuo0 leaaua0 /GejuewelddnS asayj ul papinoad esi/vueyjo ao aoueansul ,,Nsp Ile„ ayj aapun paaanOO IOU 11 •(sleuolssajoid aayjo pus sAauaope `sjoajlyoae `siaaul6ua 10 sa6aeyo pus seal 6ulpnloul) Apeclo id painsul Aue }o juawaoeldai ao aledaa ayj ul pajanoul ssol Aue ao ssol painsul Aue `woaj buillnsaa ao `jo }no 6ulspe sesuedxe pus sessol `so6ewep apnloul lleys pus `suolllpuo0 Ie.aaua0 Aje}uawelddnS asayj ul papinoad aq Aew se sllaad aayjo yons pus `96ewep aajenn pus asdelloo `jalyoslw snolollew pus 96ewep `jjayj 6ulpnloul 96ewep pus ssol leolsAqd joj aoueansul ,Nsp Ile„ apnloul lleys `a6eaanO0 papuajxa pus sllaad ayj Isule6e einsu! lleys `NaoM ay} ul s.ioloealuoopS pus aoloealuo0 `aaunn0 ayj jo s1sajajul ayj apnloul lleys aoueansul slyl - (noel Aq paalnbai se ao suolllpuo0 leaaua0 AjejuawalddnS asayj ul papinoad eq Aew se sjunowe algllonpap yons of 139fgns) joaaayj anlen algeansui llnj ayj Is ajls ay} uo lepajew paao }s pus NaoM ayj uodn aoueansul Aliedo.id ulelulew pus aseyoand lleys aojoeajuo0 ayj `suolllpuo0 lejaua0 AjejuawalddnS esayl ul papinoad aslnvuayio ssalun •y :6ulnnolloj ayj liesul pus Alanjua sal ul y 90 a}alaa :30Nv'dnSNl Alb3dObd 90'9 2�010b211N00 ayj y }inn joeajuoo,uoljonajsuoo ayj olul paaajue aney IOU pinom U3NM0 9qI `suolIlpuOO lea9u90 9y1 ul pouleluoo se seslwoad s,U010b211N00 9y1 JOJ }nq `asneoaq joea}uoo uoljonAsuoo 9y1 Olu! 21010b211N00 9 y3 Pus U3NMO 9qI 10 fuIU9 ayl Z :pue `sajn }e }S eppolj `90 uol109S jo sluewaalnbaa ay} aapun seeAoldwa s,H33NIJN3 9 y1 Pus `U33NIJN3 9 qI `H3NM0 ayj jo suo ayj 6ulllljlnj �tlajaldwoo se sjdaooe b]OiWiiN00 ayj yolynn }o �(oenbape ayj pus pe6palnnouNoe Agaaay 88I006d,& 9 •ao oea uoo ns �(ue ao a �(q 1 lnela(1 . 0 � � q �1010t�I1N00 1 4 •91!s uo s! aoloealuo0 941 saw Ile le eps uo eq Ile4s 9n!1e1uas9ad9a s!4 ao a9au!6u3 ay} ewnsse llegs aoloealuo0 a41 uolleulwaalep s!41 to sasodand ao3 •1oefoad 941 to paeme 9 pue s asa 10 s 941 o f }uensind p9 se sano4 bul�aom lewaou ul 41!M 1ou �aoM •9 •9lnpegos laom 941 to uo!}eaaleooy d : a41 1 'Ile ao 'Aue Aq /Gessaoau spew u9gm �133NION3 9 41 Aq paaapu9a seolna9s Ile l0 lsoo le1 941 aol 2i3NMO 941 asingwl9a Ile4s X10- LOV - 81N00 9 41 : a4l PPb 6Z'9 •�aoM 941 to uolleldwo0 le!luelsgnS `lo uo!l!puoo leped a se pue 'ol aolad �13NMO aol b33NIJN3 01 p9a9n119p 9q 11e4s pue uo!leu!wexa aol Z133NION3 941 o f algel!ene aq Ile4s 9sa41 :buimollol 941 alnl!lsgns pue aoualues l sel 9 91919(1 :•Zi,•g u01109S a6ell!n 941 of Allowip aaumo 941 Aq p!ed aq Ile4s els9nb9l to 96ell!n 941 of anp seal 1!waad •elsenbal to 96ell!n 94101 anp 9so411deox9 seal 1lwaad Ile Aed llegs aoloealuo(1 941 •1oefoad sl41 of palel9a sl!waad uo kesseoeu Ile bu!a!nboe aol alq!suods9a 9q Ile4s 2i010�I1N00 941 •els9nb91 to 96 ell!n 9 41 pue A1uno0 4oea8 wled woal s1!wa9d Aaesseoeu Ile aanoas of p9a!nb9a 9q Ile4s 21010b2i1N00 9 41 :80 u01139S 016ulmollol 941 PP`d luawAed aol suo!1eo!lddy s,aoloealuo0 41!M 9ouepa000e u aoloealuo(1 of p!ed slunowe to aou9p!n9 'algeo!loead 1u91x9 941 of 'uo!1ez!ue6ao ao uosaad aa410 ao aa!lddnS 'aoloealuoognS 4ons Aue of 4sluanl stew a9au16u3 ao a9umO :•0•90 u 0 1 6 u!nnollol 9 41 PPb' •saapp!g o1 suollonalsul a4l u! 41ao119s aanpeooad 941 Mollol Ile4s paeme of aolad 96uego aoloealuoogns Auy •2133NION3 JO b3NMO a4l Aq 9noge 941 aad pelsenbaa AIleollpeds ssalun 4010` HiN0(1 a4l Aq pe6uego aq 1ou Ile4s waol lesodoad 941 uo p9weu saoloealuoognS :19 90 uo1109S 01 6 u 1 nnoll 0 l 9 41 PP`d •A1aa!1u9 s1! u! '8 90 uo!1oaS 91919(1 •aouepeo9ad aNel Ilegs 'sluaw9a!nb9H Iea9u9O 61,010 uo u! 4laol 19s epapio 941 •p•Z•v 90 u01109S 41!M 1oguoo u! aae 4o!4M suo!1n1!lsgns o1 p91ei9a `sluawemnba�j lea9u9O '61,060 uolloaS to suolslnoad Aue ao3 •peiep!suoo eq lip suoppIsgns 4oigm aol swat! a411!wy a941an1 osle Aew sluewaa!nbeH leaau9O '66060 uoiloaS 'sluawaa!nbeH lea9uaO '66060 uo u! 4laol 1as se 9q Ile4s aanp9ooad uo!1nl!lsgns 941 •luawaaa6y 941 10 alep 9n!loalla a41 to s�(ep 08 ul41!nn spew aq Ile4s swel! 9 1 n 1!l sgns to asn 941 aol s Auy :• 90 "9 u0110as 016ulmollol 9 41 PPb' •lela9lew ao luawd!nb9 to wal! aelnoped 941 to uo!lduos9p 941 u! „ lenba ao„ '91els Alleogloeds suo!1eo!l!oeds ao sbuimeap 941 ssalun p9aap!suoo aq 1ou II!M swel! „lenba ao„ `ieaauab ul 8810063Id L eqj ssalun pelueiB aq 1le4s uolsualxa 9w!j ON •joeiluoo 94j of 6ulpi000e wiolied of ainl!el io r `Ai9n!19p `Bulinloelnuew lelialew io /pue juawdlnba of enp sAelop iol paluei6 aq llegs uo!suajxe awll ON lloiO`d JIN00 9 4110 loijuoo 94l u 9q of p9i9p!suoo 9q llegs (•ol9 `Aoua eouewioliad ia!lddns io iojoeijuoogns pue �(ian!19p le!ialew io /pue ju9wd!nba 11V :'b' to-z6 uollo9S of bulmollol a4j PPV •i Om s!4j 9lepowwo00e of 213NMO 9414j!M s911!n!loe p19!j i1941 al (legs 21="iN00 941 `in000 sigl pino4S •saoiol ia4lo io umo i!a4j 41!m `paau 9ql 9leu!wl19 9s!nniaglo io `i9pi0 eBue40 a iol paau eqj of es!i 6 u[Al6 u011!puoo P1911 941 loaiioo il!M b3NMO 94l luan9 SM ul •i9pi0 96ue40 941 anoidde jou of l4B!i 941 saniasai 213NMO 941(si9pi0 96ue40 to lenoidde pue eoueldeooe of pejelai ulaia4 41io1 las e!i9l!io 9lgeolldde ia4jo to uolloels u! pue 2133NION3 PUe �13NMO 9 41 �fq of peaibe se) iapi0 96ue40 a iol pa au a aonpui pue suolleolj!o9ds io sueld 94j iajle of paau a 9je9io 4oigm suolj!puoo P19!j sielunooue �1010"-LN00 94j legj Juana 941 ul •.v :'9 60'Z6 uo!loaS of bulmollol a4j ppy :S3W1110b2INO3 30 3JMdH0 !30RId 10b211N00 30 39NVH0 - U 31011NV •wio3 p!8 94j u! suollooilp 41!m 9ouepi000e w spew aq llegs pamolle AIleo!jloads sluawlsnfpe Auy wio3 p!8 941 u! pamolle AIleo!jloads ssalun `slu9wnoo(] loeiluo0 eqj u (s)w9j! 4ons to � l!luenb p91ew!ls9 941 pue i1ioM ao!id j!un to (s)w91! �(ue to � lquenb leulj uaannlaq eou9ial4!p a to llnsai a se p9iinoui sesuadxe leuolj!ppe iol wlelo 9� ew lou Aew ioloeiluo0 :aoeld sl! u! 6uimo1lol eqj 9jnl!lsgns pue Alai!lue sl! u! •0•£0• uollo9s 91919(] suo!leo! j!oads loafoid a4j to 09 6 60 uo!loaS u! 41101 19s suolj!puoo pue swi91 9qj 4l!m aouepi000e u! Alalos p9zll!ln pue paz!io4lne aq llegs `wiol p!q a4j uo pa!j!luep! j! `aouemolle Bulpp!q eqj jegj poolsiapun ia4linl s! 11 :'ZO' 6 6 uoljoes of 6ulmollol eqj PPd :N110M 33INd llNn !S30NVMO - l - lV HSHO NNOM 301S00 - � 6 31:Dlitl / •eouai9luoo uo!lonilsuoo -aid 941 le pajuesaid aq ll!M jua6e iaglo 4ons to Alpoglne to suoljelpil pue s9lj!l!q!suodsai `sa!lnp a4l `99Aoldwe io juebe s,i99u!6u3 lou s! Oqm al!s 941 le iaumo 941 juaseidai of lue6e i94loue s9jeu6!s9p iaumo 941 11 •90uaialuoo uo!lowlsuoo -aid eqj le 4laol jas se pue i99u!bu3 pue i9umO eqj Aq paai6e se aq llegs saljlio4lne pue salj!i!q!suodsai `sa!jnp (s,�J&J) s,9nljeju9s9id9y loafoid luap!s9�J pue i99u!6u3 a41 •poliad uo!lonilsuoo eqj Bu!inp an!leluasaidai s,�13NM0 aq UP 2133NION3 `99i6e b33NIJN3 PUe b3NM0 9 4111 :6uimo1lol eqj alnl!lsgns pue eouajues lsig eqj 91919(] :3AIlV1N3S3bd3H S,H3NMO 60'6 N011onNISN00 Mum sniviS S.U33NIJN3 - 6 31311NV •uo!lowlsuoo 6u!inp sesneo ia4lo io 9i!j Aq p9Bewep NioM '3 •pasodx9 eq Aew d010b�J1N00 eqj 4olgm iol sa6ewep pelep!nb!I Aue of uo!j!ppe ui aie slsoo 4ons Aue legl 9loN •suolsualxe awll panoidde b33NIJN3 Aue snld `sluawnoop asegj Aq palelnd!ls seweil awll 94j u!4l!m `4loq io `uo!laldwoo leu!j io uo!jeldwoo le!luelsgns i941la `lo9foid eqj 9191dwoo of ainl!e3 (] 88I0063A1 8 • „9A11 f%1u9Anl `luewAed pue luewajnsealN `091, l,0 uollo9S ul iJealuoO r ayl of p9lelndlls ssalun„ :6uimollol 411M aoeldaa pue spiom OAN lsail 941 alala0 •aaumO ay1 Aq ulaaay swell pue slepalew saoiA.igs uollonilsuoo ayl 9191dwoo 01 ioloeiluo0 ayl 1 A1111gisuodsei ayl aalle lleys ulaaay 6uigjou 6u1o69aol ayl to ssalpje69�1 :'b' tl0'jv I• u0113aS 01 bulmollol 9 41 PPb' 'met eppol Aq p9pinoid esimia4lo ssalun `aapee ao `1uawAed to ldlam i911e sAep (0L) u91 ulyl!m seped 9sogl anp luewAed 1Iw9a lleys ioloeiluo0 ayl `Joloealuo0 ayl Aq paa14 siallddns ao/pue sioloeiluoogns Aq pegslwnl slepejew ao saolAjes `aogel aol aaumo 9yl wal luawAed s9Al939a aol0ealuo0 941 U 9 4M •pemollol eq 11eys 09L L0 suo1loaS ul pol las se sluawailnbei leuolllppy '1uawAed ssa.i6ad y0e9 aol a99ul6U3 ayl Aq peplAoid 199ys J9AOO ayl 9191dwoo pue asn llegs .aoloeiluo0 9y1 :6u'mOIIol 9 41 PPb' „luaw�(ed pue luawainsealN `091,1,0 uolloaS 411M eouepj000e ul uolleluewnoop Aq„ liesul • „uo11e1uawnoop jay10 ao 9010AUI `ales t o lllq a Aq„ aou9lues puooes ayl woal 91919(1 ..... OE lseal ld :6upollol ayl liasul pue 9oueluas kill 941 10 spaoAA 99ay11sall 941919190 :S1N3WJltld SSMIE)Obd b0J NOUVOI1dd`d ' V Z0111, N0113IdW03 aNV U013VH.LNOO Ol S1N3W"d - K 3 110iOVi 1N00 a41 Aq aol pled aq Ile4s b33NIJN3 941 Aq palsenbei 6ullsel-ai II`d 'b33NIJN3 ayl to aoueldaooe 941 01 loafgns aq lleys tiaolejogel 941 Aaoleaogel 6u11 luepuadepul ue Aq pew.aolJad eq lleys suolloadsul pue sisal yons IId 11010"1N00 a41 Aq pled aq lleys sluawnoo0 loeiluo0 941 Aq paalnbaa slenoidde pue suo11eo1111aao sisal -ai `sisal `suolloadsul Ile to lsoo ay1 :6uimollol pue 80•E I, 4dea6eied 919190 MHOM 3AII33d30 :10 33NV1d333V 210 IVAOW311 `NO113321I03 'SNO1133dSNl aNd 1S31 £6 3I3I1MV u p9pinoid � lleollloeds lu9lx9 941 of pue qpm 9ouepj000e ul `s�telep 6ulllnsai yons aol ApawaJ 9Alsnloxa pue alos ay1 se ewll loeiluoo 9y1 to suolsu9lx9 01 �tluo p911!1U9 9q lleys aoloeiluo0 'algeploneun jo elgeplone ao `algeaasaaol `algeuoseaaun ao elgeuoseaa eq eouejpuly ao 93u9jap9lul `uo1ldnislp Aelep yons .aaylegm `a9A9os1egm asneo Aue wool 9oueipuly ao `9ou9a9pap `uolldnislp `Aelap to asneoaq bulspe `Aoualolllaul ao uO11ej919ooe 1 s1soO `01 pellwll 1ou lnq `6ulpnloul sa6ewep jo `sasuedxa `slsoo j9y10 ao loedwl `lelluenbasuoo `109a `loaalp col Joumo woal pu1N Aue to uollesuedwoo ao 1uewAed ao wnS 1oeiluo0 ayl ul eseaaoul u e of pellllua 9q 1ou lleys aoloejluo0 's�fel9p �(ue to uoseei Aq a6ell!A lsule6e p91j9sse ao 9pew aq lleys awll to uolsualxa ue aol ueyl aaylo wlelo �(ue ao sa6ewep col wlelO ON :buimollol a41 41!M aoeldaa pue 'y 90'Zl, uol 919190 •uo11eoippow `peimbai 9Aey pinomio `sajlnb9i yled leollljo leul61ao a411e412�33NIJN3 941101u9w99J6e 9y1 yllnn aleJlsuowap ueO �1010VIiNOO 88 I006JAk 6 •eplaol3 `Aluno0 yoea8 waled aol pue ul jno0 ilno.il0 ayl u eq of luawaaaa6e sl to ino 6ulsl.ae uollebipl �tue aol uollolpsl.anf pue anuan alelndlis luawaaaa6e slyl of saiped ayl •aoaol ul aalleula.aay pue mou se eppo13 to alelS ayl to smel ayl Aq pauaano6 aq lleys luaw eeibe slyl g L0 uolloaS of 6ulmo o a II � yl PP`d NOunioS321 3indSla - 96 3131111V •anoge 80.9 L uollOaS ul aol papinoid swaall Ile apnloul lleys inq `silload to ssol ao se6ewaep of pelique aq lou lleys .aoloeiluo0 ayl pue suolilpuo0 leluawaalddnS ayl to 80 uolloaS ul aol papinoid se aOUaluanuOO col paleUlwWal pewaaap aq lleys loe.aluo0 sly} `luana yons ul uayl 9 10eilu00 slyl paleulwaaal AIlnl6uojm 96ellln ayl leyl spur uollolpslanf lualaduaoo to lano0 e lI "loefoid ayl to .aapulewaaa ayl aol s96ewaep aaylo ao `Ieloeds `loaalpul `silload isol Ile papnloxe lleys lnq `alep uolleulwaaal of aolad lInl ul pewaaolaad Allenloe saolnaas apnloul lleys luaw Aed •uolleulua.aal to alep ayl of .solid pa.aanoul sesuedxe .pue palnoaxa Niom Ile aol pled aq Keys aoloealuo0 ayl `ula.aay papinoad se paleulwaaal s JolOealuo0 ayl li 'awes ayl 10 aoilou uall im s�(ep (v0 uaalanol .aoloe.iluo0 6ulpino.id uodn aouaivanuoo aol loeiluoo slyl aleulwaial Aewa aaumo ayl :eoeld sll ul 6uimollol ayl liasul pue A}aallue sll uI •E0•91, ydei6eied 919190 SNOIIHNmm31 aNH NNOM d0 NOISN3dSf1S - 96 31311MV palnoaxa Allnl `suolilpuo0 leaaua0 AjeluawaalddnS ayl uI pallddns uaaol ayl uo papinoad aq ileys Ulaaay paOUaaalaJ se .aolOe.aluo0 to ilnepllle 9q : ayl PPb' :1N3VY,kVd IVNl3 TV L017 I, "ula.aay ylaol las se uall to saseelaa Ieug Alddns lleys 2io10v�I1N00 ayl `luaw wed leull a.aola8 'Ilnl ul pled u99 aney s.ioloeiluoogns pue siallddns `saopuan Ile leyl selelndlls yoigm isanbei Aed leUll ayl yIIM ilnepllle pazl.aelou pue palnoaxa Ue apinoid osle lleys U010`d IN00 ayl uaaol ayl uo pagp se suolle6llgo ayl JO b331\1I91\13 ayl PUe 2ONM0 ayl 6ulseelai V 0 L - 0JS abed) swaaol aseelai ayl to saldoo palnoaxa ilwagns lleys b0.1.0b' iN00 ayl `luaw wed leuil aaolaa •. V LO'V L uollOaS of 6 uimollol ayl PPV 8810061M 01 1 :sa.ndxe uolsslwwoo AW (gd3S MJViON) 96ae1 le eplJo13 10 9 3e3S `onend AI:lViON 'E i oz ` 10 Aep slyl plesaaole a3e3s pue Ajunoo eqj ul leas lelol}}o pue puey Aw SS3N11M -awes aqj pa3noexe ay Iey3 aw aaojaq pe6pelmouloe sey p Iuawnilsul bulo6aiol ayI pa3noexe oym pue ul peglaosep uosied eqj aq oI umouN ew 01 ` paaeadde Alleuosaad `s3uawbpalmouNoe aNel oI plesaaole AIunoo ayI ul pue plesaaole a3e3s ayI ul pezlaoy3ne Alnp jaol}Io ue `ew aaojaq `Aep slyl uo Ieyl AJU1 130 ASMOH I 301k1Nf10O 'SS ( ( ` C]NOTA =10 31d1S :913!1 :A8 :b0lOb211NOO '2133NION3 Aq paaed suol3eo1lioadS pue s6ulmeaa pue e3senbe13o 96ellln 9y3 PUe 2:]OlO` -LNOO aqj uaam3aq pa3ep I3ealu00 a yllm eouep.i000e ul Iuaweoelda�j Jue1 96eaoIS IOOeN IUeld Iuaw3eai1 a93eM e3sanbal jo a ayI se umou� Ioafad a jo aouewaoped jo `uolslnaadns `uo!Ie1lobau ublsap ayI 0I pa3elaj Aem Aue ul ao 'jo Ino 6ulspe sw!elo Ilb' :o3 pa3lwll Iou Inq `bulpnloul `umouNun Jo umou){ a9y39ym `a9n9os3eym 6ulyl ao asneo japew Aue jo uoseaa Aq ao uodn `aol `umou� un jo umou� Jay3aym `A13oaj1pul ao AII b33NIJN3 Isu sey mou ao pey Jana �IOlO` _LNOO yolym `J9n9os3eym spuewap pue swlel `sebewep `suns `uoijoe jo sasneo alge31nbe jo le6al Ile pue �tue wOJJ „�133NION3„ se oI paaaalaa A19AII091100 MUeulaiay slue6e pue saaAoldwa `sio3oajlp siao!,4o sal 'oul `sn SIaymm se6aeyoslp aan pue saseala.i Alleuo13!puooun Agaaay ..UOlOb'11NOO 94, se oI p9aJa39J JOIJeulaaay ` 3SV313H 88 T006JAA, :saJldxa uolssiwwoo AN (Id3S kHV -LON) 96ae le ep!Jo1310 aTeTS `onencl AHViON '£ l, OZ ` 10 Aep s!yT p!esaJoje a}eTs pue ATunoo ayT ui leas le!o!}}O pue puey Aw SS3N11M - awes ayT paTnoaxa ay TeyT aw aJolaq pa6pelmou�oe sey p TuewnJTsui bu!obaaol ayT paTnoaxa oqm pue ui pocIposep uosJad ayT eq oT umoul aw oT ` paJeadde AlleuosJad `sTuaw6polmouNoe a�eT oT plesaJole ATunoo ayT ui pue p!esaJole ejeTs ayT u! pez!aoglne AInp Jao!}}o ue `aua aJolaq `Aep s!yT uo Tegj A3ilb30 Ae3b3H I JO A1Nf10O "SS ( VaRJ07l3 30 31b1S :911!1 :A8 HOlOVI1NOO •eTsanbal To a ayT PUe HOlOb211NOO ayT uaangaq paTep ToeJTuoo a qpm eouepJ000e u! TuawmelcIgH duel 96eJoTS IOOeN TUeld Tu9wle9Jl JaTeM eTsanbal To a ayT se umouN Toefo.id a To eouewjo}aad Jo `uo!s!nJadns `uo!Teilo6au `u6!sap ayT `oT paTelaJ Aem Aue u! Jo `To Tno 6u!spe sua!elo Ilb' :oT palpil Tou Tnq `6u!pnlou! `umoui un Jo UMOU { JayTaynn `JanaosTegM 6u!yT Jo asneo `Japew Aue To uoseei Aq Jo uodn `Job. `umouNun Jo umou� JayTaynn `AlloaJlpu! Jo AlToaa!p H3NMO I sey M ou JO pey Jana HO_Lov - d1NOO yOILIM `JanaosTegM spueuaap pue sualelo `sa6ewep `sps `uoijoe To sesneo algepbe Jo lebel Ile pue Aue wOJI ,,H3NMO,, se OT paJJajaJ Alan!Toalloo JaTjeulaJay `sTua6e pue saaAolduaa `saoToaJlp `sJao!}}o sT! `eTsanbal To 96e1l!A ayT sa6Jeyos! JanaJOj pue sasealaJ AlleuolT!puooun AgaJay .HO1OV'diNOO ayT„ se oT paJJajaJ J911eu19Jay ` 3SV313H M 006JM aoud seep (p£),faiiip ut,ill ssal ou aaftmW loofoid uoiloiulsuoD s,ast aul of uoilisinbai icons Rut, ianilaP (o) pine :uoilisinbaijo uiioj sANIIiA aul uo luouudinba pine slt,ualt,tu dons .ioi uoilisinboi t andaid (q) : .ia2tuvW loafozd s, aul of uoilt,lidtuoo icons liuigns pie `loafozd oqj zoj paiapio oq of paau luauu inbo pie slt,ualt,tu st, `loafotd aul jo uoplulsuoo aul Suunp `otuii of otuil uioq `Iot,iluoD uoilotulsuoD aul jo sluatuaiinboi olgt,oilddt, aui ulim aout,pz000t ui szolot jo .iolot,iluoD Xq paainboi joazaill saililut,nb put `sluaivaunbai ouuil It,lliuigns pine XJQAilap 2uipju2oi sioilddns uo posodim ag of suoilipuoo pine suuol pie `luatudinbo put slt,ualt,ui oidioods aill Jopio of pazinbai are It,ul uoilt,uuojui put suuol ogioads iotllo pine `suoiloiulsui Xzanilap `scagwnu .zapzo .Io aaolt,lt,o �szopu3A zo ,sjamlot,jnuuu `slsoo Iiun `soiliiut,nb 2uipnloui `luaiudinba pine slt,ualt,ui ioj luotuaimbai poziuuali �saojot Put put s,zolot aliduioo (t,) :Ilt,ils Iolot'4uoo atu I'I •suoilt,oidioodS It,oi oo L a put ili suo uo put suua t,lsonbo .mi u P ..P � P Z Z jo o aul jo sluotuaamboi auI loam of palt oq Iltgs Tut, 20.I l XJanooa -I xt,Z salt,S aul iapun popinoid oq of luauidmbo jo jailddns luauidinba ilot,g •uoiloos still of V luouitlot,llV st papnloui am tut siili of olgt,oilddt, suoilipuoD pie suuas t,lsonbojjo a2t,lliA pit,put,is aill, •loafoM atll JOJ 32 t , 111A aul Xq posuq ind oq of Iuouudinbo pine slt,ualtmi polsonbaz aul Jo aifit,liiA Xq lsanbai caljt sSup anpuaiva of ut .ualt,l ou o t,lliA aul Xjilou Ilt,ils iolov.4uoD oql •nnoloq popino.id st pun saoud pun swigut,nb polt,iuilso `poilddns oq of slt,ualUm otll jo uoiiduosop t, st Itaen st, `s .IopuaA aul tuoj solonb ooiud Iiuugns Ilt,tls iolov.4uoD oTU •sonit,A jo olnpagos Xnuiuuilaid aul st auiil cures aul It pallitugns ag Ilt,ils lsil sitl1 •slt,ualt,y� past,iloand O &ILIA st, uoilt,iapisuoo JOJ uaui It,ualt,uu pue sJopuaA `smilddns popuolui Iit 3o isil t, o t aul apinoid Ilt,ils iolouiluoD o,gjL pig sli ui slt,ualum uoilorulsuoo Ilt ioj oozed aui apnloui Ilt,ils jowuluoD atLL •siolot,ilumgns sli pie zolot,aluoj aui Xq pig XIaAililaduioo ag Iltgs siailddns It,ualt,w •loafozd aill jo uoilottiilsuoo oqi aoj palt,00ltt, (Iltogloods spun] ulim o2t oql Xq opum aq Ilt Iuauidinba put, slt jo sast,go.ind Ioomp IIV • .iapio o2ut,ilo t jo uuo3 aul ui aft oqj Xq uodn paa.12t, put Iolot luoD oqj Xq of paaaft, st `loafotd aul olui paltuodiooui ag olio ` .ioj post,iloind luauidinbo put slt,ualt,uu Iit jo sost,ilomd loaiip oVu-i Ilvgs 32VIIIA OqJ, •( « loafOJd„ OT .iaIFuiaiail) ' ju amamIdag xut,Z ateaolS laoic i nlsanba,L jo aguntA aul olui polwodiooui put `.ioj post,tlojnd luatudmbo pare slt,iialt,iu uo saxt,l asn put solt,s 2m vd uuo4 Iduuaxa sr o t,lliA oil saxt,l, asn put, sait I SrIVIHH.LV Iii QgHSIKHfld I'IIA HOA NOIZdIVHXH XV1, asfl (INV 21'IyS VQIHIO'I.I 90 H.LVVZS ONINHUAOO SNOISIAOH;f SNOI,LIQAIOO 'IvIJgdS suoilipuo� It,ioadS i?uimolloj aql gjInn Xldtuoo put Xq opigt, of sooBt .iolot,aluoD `a .Iouuaill ind '32UHIA aul of Isoo It,uoilippt ou It urei2oid s2uint,s xt,l still ui olt,dioiitt,d Ilion put (s).iapio 32u qD dons olnooxo Ilion `(s).iopip afuego aul ui papnloui aq of Iuouudinba put slt,ualt,ui olt,udoiddt, 5ui�iluapi ui 32VIIIA aul Isisst, Ilion zolot,IluOD `(s)zapip o2uvgD dons anssi of saaisap a$t lt saaz2P zolot,iWOO loafozd aul ui asn zoo iolot,zluoD of ilstuinj put Xlloaiip ast,ilomd oI sazisap aftlliA OT TUT suialt uit,laao lot,zluoo oql uioij alalop of smpzo ai?utgo io iopio o2ut,ilo t anssi Xt,tu ( st, ,suolllpuoj It,ioadS IoaaiQ jaumo, aul ui of pa.uaja.i jagumaiail) t,lsanbaZ jo a - aul `IoafOJ l still jo osinoo gill i?uunQ SNOIJLIGNO3 'IVI39dS 13HUIQ UHNA10 99 WO UM Z uotjuiit,lsut g2nozgl juautdtnba put, sipuaw eons 3o a2pzojs puu i?utiput,q `2utpoolun aqj zoj parmbaz saoinjas Ilt, aoj a2uput, to aptnozd Ilvgs ioao 4wo ag,L •pogslwnj sit,uait,uz m1nolind agl ioj iolov.4uoD gons Xq paiinbaz ,Kliuuuou sIuatuaSupuu zagjo pup `uotjujuauo 2utpu01 `faantiap Jo aouanbos `sainpagos Xzantiap aIuutpt000 hugs iojot,.tjuoD ag,L •Xitt,d zagjo zo simmuluoogns Xut, zo tojoujjuoD Bons jo aoua2tisau aqj of onp sutalt jo oouuid000u futmoiioj luautdtnba pup sipuaiuut 01 a&utt,p Jo ssoi put, `,4ZJantiap Jo aurtJ aqj jig juawdinba pup siuualuut aqj jo aouuldaoou pup uoiloodsui `sluautnooQ lot, tluoD aqj Xq pazinbai saalumn2 puu satluLlmm lit 2uiurejgo pup futpinord `sasugoznd 2utipuipz000 `jauuuw Siauttl t ui siapto zo sluawnoop but uan satitlut,nb Ioaztoo 2u uan JOJ Xjtiigisuodsaz aql `ol paituui jou inq Tutpniout `uotjtpuoD IuioadS sigl gjIm aouupmou ut OiNIIIA aqj Xq pagsltunj luatudtnba pup siuuajuut jo idtaow aqj of 2utipia t szallptu Iiu ioj aigisuodsa t KllrLj oq Iipgs Jojob aq,L S' i • aq} fq Spoaup posmloznd luautdlnbo puu siuualuw aqj jo isoo agl sowli 90• i Xq puoq uotlotulsuoo oiignd sit jo urns Iuuad oql pup junourV lot, rluoo aqj aonpa i Ilugs jolouz4uoo oqi `uotldwoxa xul asn pup saius sAull!A aql of jut,nsznd posugotnd ant, juawdinba put siu!joww luql lualxo aqj 01 b I •j3u4UOD pup sjuatunooQ u0110r ISUOD asa141 ut papinoid ostmaagjo st .to moiaq II'I uotlooS ui pwinbat 02uaano3 zagjo Iit, 01 uotItppt, ut aq Iit,gs 0 219Jan00 stgj •uiazaq utt,tBozd 2uispgo n l paiiQ zaump oql jo llnsai u st posugotnd luoutdmba puu siuualt,uz Iit joj anion mgt, -Insut iinj agj JOJ aouWnsui 3 1st2i s, .Iapitng utuluiuw Ilugs a$uiliA aqs, •moiaq p I • i uotloos jo suoistnoad oql of loofgns `uotldtuaxo xul asn pup saius sit of jupnsand pasugomd juawdinba put sipuajutu Ilp uo ssoi jo �isu Iit awnssu Bugs 02 p111A QU £ i quawdtnba put Itlio pw Bons 10010.1 hugs 32 VIIIA OT put, Sutlum ui O &IIIA agl Xjilou Xiajutpouzuu Ilugs iojoanuoo agl `Sutuuojuoo -uou am juawdinba puu siu!joww aql lugl sautuualap .zojouuuoD aqj JI •43010zd oqj olut papzodwoui an juawdinba put sit Bons ajojaq juawdinba put iu!jopw Bons jo uoissossod put mill wit ITT4s 32VIIIA age. `2utuuojuoo 3M luautdtnba puu siuuajt,ut aqj Ipgj sautuualap iojouAuoD oqj jI •sluautnoo(i jouuuoo 3111 pup Japzp aspgojnd aql jo stu of oqi gltm juawdinba .to sit,uajt,ut Bons jo Xjtuuojuoo aql XJuan llpgs 'juawdinba to siprjajuut Bons Auu jo U)ATIap oqj uodn `.tojot oiu Z' i •jun000t s gull!A ag1 tu04 dopuan aqj of juamu vd loa.ttp a-iuw Iit,gs 32 ' 9 111A OU 'alpot�tj tao uotldutaxa xpl asn puu saius s,32ulIIA aqj jo Xdoo u `japip osugoind Bons SUL gaim apnioui Itugs 32VIIIA aq.L '(.tapjp osugoznd t,) aluQ zapio oqi of Ioud `ivauudtnba to siuuajt,ut aqj Jo Jopuan aq} 01 X1133.11p zapzp ast,goand u onsst Iipgs o2ulliA aq,L •luou4ndaQ ftsugoind s, OT 01 autus aqj ptt,mzoJ Bugs za &uuuW 1oaCot l u0143tuIsuoD s,32piliA age uotltsmbaz gons puu 3o ldtaoat uodn •alt ioptp oql xjiluopt slugs uoiltsinbai aq,L ( aapzp„ ogl) ainpogoS loafoij gill gjIm aouupz000t, ui ollS agl 01 luautdtnba zo sIviloptu gons jo ftaniiap amssu of poouid oq oa luatudtnbo zo siuualptu gons .toj saapio sartnba.z `aq ,it asuo oqj su `juawdinba JO sipuaIutu aqj Jo r zo minjoujnumu oqj 31up 341 01 i 996006AM sluuajuW pagstuzn3 aft,lliA agljo saaluuzunB put sattuuuunn Iiu toy aigisuodsai ag hugs ti Jugt sJuuuanoa puu sjuasa tda.t sJuu uuen zolou .4uoo oq L •aojowjuoognS io ioilddns `aopuaA olujidotddu agt gjyA uotjnjosw .toj jotouituoD agl of a2ullIA agt Xg pop AUoj ag jjugs sjjuo .itudoj- aSuuzup to aauuuatuiuut `ztudat IIV •sjuuajuW pagsnund a Iju toj saalutumi? put satluumm Ilu 3utst,uuut put 2uiureigo .toj olgtsuodsaz ag Bugs iolouiluoD otU 6• I •3Iaorn agj olut paluaodtoout uaag anug sluuatuW pagsivand 35 uIITA golqm fuiiuoiput `ajiS agt of pa.zantjap sjuitajt,W pagsivand oBvIIIA Xuu .Lod ai? t,lliA puu aa2uuVW 133fotd uoilotuasuOD 8,35uIIIA agt of Xlgluouz jun000t, Ilugs iojouuuoD N •slur_talVw pagsivand a$ulliA jo Nook agj utotj 3I.torn agt olut patuuodaoout slulioly i pagsnund aguil!A Ilu jo sptoaai pajiulap puu minim umiumui Bugs .toloualuoD agZ 8' I •osuodxo put, Isoa OI sti Ju `sjuu34uut SuturtoJuoa -uou .10 anttoadap jo Iuautaoujdat put mudat agl ioj algisuodsaz ag Bugs iojou4uoD agl `sjuuajuW pagsiujnd 32VIIIA 2utuuoJuoo -uou .to antloajap Lions Torn age olut satuuodtoout ostnnaagjo to uoiloodsut Bons uuojtad of sltu3 .toptu uoD Bons Jugj Iuana ago III goafotd agt of uottdnuo4ut .to Xulop onpun Kut jnogj!m zn000 uuo sluuatuW pagsiu nJ 3SVIIIA asoT Jo juauxaouldw zo imdat jug4 os uotjipuoo 2utuuoduoa -uou .Io antjoajap agj JO ` UTIU n ut `zaSuuuW 133fozd uottatutsuoD s,aSujliA ago ,Kjllou XItduzozd (p) put `3jzorn agj ut sjuuajuut anijoajap zo 2uiuuojuoo -uou gons ozill n of .toloutluoagnS nmoilu jou (o) `.3jzorn agt ut siuuatuut antIoaJap ao 2uiuuojuoo -uou Bons aztittn you (g) `luautdtnba put, siuua�uut �utuuojuoo -uou Bons jo oouutd000u puaututoow you (I) :Ilugs aotot4uoD `um oadsui junstA Bons uodn sjuu34uW p3gsium3 O &MIA i?utuuoJuoa -uou ao 3n1403j3p s.zanoosip J UODJI •.zapzp asugaznd agj put Suipujdo jjig agl do uotlduosap agj goo ut puu paiapto sjuuatuuz agt of Iuoquopi a.tu sluuolvW pagsiutnd 32 VIIIA gons roigjoq n put `antJoajap Xpualud on sluuaiuW pagsiujnd 32 ulliA Bons Rut aag4agnn liOrn agj otut uotlutodioaut of aoud ouiuualap o4 put `suotjuoUjoadS put suujd agj pup s5utnnt,tQ agj Butpnjoui `s4uautnooQ jouttuoo agj of uuojuoo sjuuajt,W pagsiuund 32 ulliA Bons wgt ouiuuopp of sjuuiop I pagstuund 32 VIIIA jlu podsui Bugs iojou4uoD oql L' I zopuan age. of XItoaatp 4uouiXud joj a &t,lltA agj ol aotonut Bans J OAij ap put, sjt,uajuut Bons 4d000u Bugs .taffuu - eW pofo.zd uoi�atu4suoo s�a�ujlTA agl `sluttaIuW pagstu nj 35VIIIA JOJ aaionui Xuu Jo idtaoaz uodn •zapzp osugoind agj put slummoa 4ouzluoD agj of Kjtouxa uuojuoo juautdmbo puu sluuapnz agj jugj topuajuoD Bons Xg uot�uotjuaA uodn juauzdinbo puu sluitaiuuz zod saoionut [It' I35vut'W toafotd uoilotulsuOD s,33ulI!A age 01 aaniiaP Bugs zotauiluoD agZ atmbaz Xuut a&ljtA agj su uottuurtojut Iuuot�tppt Bons gjIm Togjo2o4 `.tapzo asugaznd agt of 5utuuojuoo .topuaA agj utoij aotonui uu puu Ia1311 X.tanijap u jo isisuoo Xuut uotlu4miLunoop sItU •opuuz st osugotnd agj golgm 4sutufu .zaptp ost,gomd agt (3ijuopj of alunbopu uoiluluaumoop Xg pagsijdutooat, st sjvulojew pagstuJnd 35VIIIA agj Jo X.tantjap goua pgt ainssu Bugs Iopu14uoD oqj •uoitipuoD IuioadS stgj gJI/A aauupzoaat ui 041S ago 01 pagsiumj azu sjuuajuw pagsiutnj- ai?ultiA su `pa .13ni13p tuautdtnba .to siuuatuut toJ saotonut �s.zopuDA agj anoiddu put ( I pagsiutnd ai?ulliA„ agT) uotlipuoD IuioadS sigl g4lm oouuptoaou ui aft,tlTA ago Xg XI1owip pasugoand s.topuaA luoutdinba puu juu34uuz utog sluotudigs Ilt joadsut Xllunsin Bugs ioloviluoD oq L 9'1 M 006JM tl - os pgzpunq -guo jo lunoure oql ui puoq Xlddns v opinozd of szopuan luoutdinbo put Itrzaltut uilapao azinbaz `uopazosip aigvuostaz ziogj zo sli ui ` (tut 32 PIUA OT .10 put zoloezluoD ag,p, S i' I •(s)zolot oql zo (s)zoioezluoD aql `zopuan oql zggiia Isureft sltltzaleW pagsiuzn3 aft'IpiA uo uoiivalaz ou aq Iltgs azaU •za2uuuw loafozd uotlotulsuOD s, oql Xq 05UHIA agi of pazanipap aq lltlgs golgm `lt'nozddt' pue aouazznouoo s,zoiotziuoD aleudozddt aqI inoglim luaut<(ed Kuv o l m lou 1pugs aft oU •airudozdde s szantUm Jo M1alaz Itutd zo peilzud urelgo XIoltaipoutu i of 32UMA aql Isisse Ipogs iolomzluoo olU •zopuan agl of Xploaztp palltuMI pine pazanipap `pasualaz aq Ilim joago slq L pz)plAozd eltp jo idiaoaz aqI uodn posuq zopuan aqI of aigtXtd loogo u andgzd Iit'gs 3SUMA aql `uolirluautnoop aieizdozddu oqi jo Idiaoaz uodn •329111A oqi Aq paunbaz Xlquosugz oq fivuz se uotleluouznoop ioglo gons pine `Suzan pazantpap oql jo aoueld000t uailum `slg)poil Xzanipap `saoionut `zapzp gsugoznd olgeoildde aql jo Xdoo u aq Ilugs isii oql ButXutldut000V •spt zo spoof pins jo idtaoaz jo seep (Sp) uaaljU uiglim sptlizal w zo spoof agl jo amulcl000e oqi jo Isii u zaStlut1W loafozd uotlotl4suOD sAVIIiA gill of apinozd Ipvgs zolotzluo3 agI `zopuan aql of iuom(ud Idutozd aql zoj afuuzz, of zapzo uI t l' i antloaJap zo $utuuojuoo - uou zaglig azam apuuz uaaq iou s - eq luouixud goigm zoj speizajtW pagsiuzn j OSUIIIA aql jo Xue ioglogm pur aliS aqI of pazanipap spUizgluut Jo spzooaz s,zololzluoo gons uodn paseq `szopuan aqI of ivaut!(ud jo aouenssp s,aSulliA aql of loafgo zo znouoo zaglia put gluout zoud oql Sutznp alts aql of pazan SIPPOIEW pagsiuznd a$UppiA Jo szopuan plu Xq paiitutgns sootonui matnaz Ilegs `stsUg Xlgiuom t uo `zoio - eziuoD oqZ £ I' i sleizal lW pggsiuznd aft'pliA agl `ut sloaJap zo `Jo f(zantpap aqi ut Xepgp Xue utog Sutilnsgz sisoo Lzlxo Xu zoj zo `sluual W pggsiuznd 3SUMA agi Suuapzo Jo aniztn Xq loofozd oql glim suzalgozd zaglo zo sloajap Xuu zoj `speizal 1W pagsiuznd O &MA aql 2uu3pzo Jo anlztn Xq ioafozd aqI ut saftump folop zo uoildnzzalut Xut zoj olquii oq iou Ipugs 32 VIIIA QTU ZI'l •spurz31 pagsiuznd 02VIIiA agi of saVIaz ii su Xmssoogu suzagp z02eu W Isrd s, oqi Icgl slunouzu apgilonpop gons gltm you unsut zaglo xue uitlureut ospt piegs zoiov.4uoD aqZ •3IzoAk oql jo uotlolduzoo ltuu Iilun sleuaiew p0gsiuznd 32 UIIiA gons jo Auu jo uotssossod pine of aliil sa7i isz3 sluasu sIi zo zoiot zo put' 321 ell!A agl aurti agi uaamlag siVuallW pagsiuzn3 agt'IIiA Xue Jo onit'n llnj gql zanoo Ilegs ooueznsut gons 'SjVP3IUW pagsiuzn j- 3SulliA of aBUuzep zo Jo ssol isum2t ioalozd of luaiotdjns aoutunsui 31su s, zapping ureiuiuut pine osLgoznd Iltgs zolot'zluoD oqZ 11 • t a oofoz a l Ip.A gi g i d g jo oomidaom pie uolioldutoo luug uodn OBUIPA oqi Xq futiizm ui pold000e 3n Xogl pine loofozd aql 2uilolduzoo jo ss000zd oqi ui paumsuoo zo loo foil oqi olut polvzodzoout aze Xogi st auul gons iu luaugivq ziagl jo sgsodznd zoj a2upliA oql of pouzniaz pazapisuoo aq ppegs speizaleW pagsiuznd oftIIiA 'sltlizal W pagsiuznd a$UIpiA agl Jo oalltq aql zolo uluoD gons pine zoliug aql pazapisuoo aq lltgs agelliA ail L uolouzluoD gons pine 32LIIIA gill jo ltdauaq It oql zoj luoutlleg L olmlisuoo llegs zoioLIziuoD agi oI Oft , 111A aql utozJ slt'tzaieW pogsiuznd a$t'ppiA Jo uoissassod jo zajsuuzl oq L •ootlou lnoglim zolouzluoD oqi of zaisut XIpuotiuutoinu pine �ilal�ipauzurt pp�gs p�tzal�y�i pagsiuzn3 sAe111A oqi jo uoissossod 4 311S aql iu spvizajtW pagsiuznd 3513 1piA oqi jo uoissassod sa3Ti aft oqi zal V 01-1 M 006JM 5 - sOOionui uo lsil put sa5Iugo Kvdand of panmban si nolloS `uoileuiisOQ - g - 0 . 3 lou on polels sooud aiaum sasuo osogl ul •Iapxo agl jo lxed opeui put fuilum ui aq Isntu Iuai5 gonS -nallaS ogl jo loxluoo oqj puoKoq sosnuo of anp si pine ulsonbo jL jo o5VIIiA agl jo isonaiui Isaq otll Ioudtui Xlasxanpu lou Ilim Xulop atll3i xapunanag tunojnad of Onnliej no Xulop Xuu ioj ouuil lt,uoiiippu jut 15 Keuz nosing oqj sxVZaQ a iaysfiDxa - sa5It,go I Ouilpuug no `05t,xols `Xlanilap -On uo -ppt, Xue Jo IaIIOS of i?uilltq agl ui llnsan Ilim XnAilop Jo Odin still 5uiuza3uo3 .iaxng oqj Xjiiou o 3rnlie,4 - 5 uipuol jjo Ioj ooueisisse no/pue 5uilpuug leioads aunban legl souanilap jo ioXng agI Xjilou Ilmis iollaS - polelndiis asinniatllo ssalun `sXvpilog 5uipnloxo `Xepud g5no ql XupuoW ` 0£:t, of 'Lu'e 0£ :8 sinotl i?urinp opmu oq of ant sauanilaQ SEIMHAI'IgQ - figojogl pouoist,000 sisoo ssaox0 Xuu .ioj algisuodsan wallas Ogl plod puu sooinos nagio uiog napxo sigl Xq pananoo sOOiAlas no sajoilne OgI Oxnoond Xetu ioXng `nallaS oql Xq llnejap jo l uanO Oqj uI Z'If1V3aQ - IO,ing Xq 5uilum ui of paluasuoo lou luouni5isse Niue napun nalloS jo OOu5isse Xue of suoile2ilgo ou OAeq Ilegs IaXng put fuilum ui naXng Xq of paluasuoo ssalun pion oq Ilegs iopunanag anp otu000q of jo anp somom no `ixud ui no ologm ui `iapunaiaq �Inom jo oouutunojiod `.iopio sigl jo luouni5isst, XuV S,LNHWNJISSV ' - uopoolos $uiuiunl put `spogiatu uoilesuadum Iaglo jo Xvd jo solid `sooilot, id luatu ioldtua 2uimolloj oqj of poliuiil lou inq of p iia i glim uoiiuluauo Iunxos no `sniels lelinetu `fi ilsooue `ui�uo It,uoilt,u `35u `xos `XIIIIgesip `um2ilai `Ioloo `ooen jo Osnuoag luago no `iut,oilddt `oaxolduz0 Xut isuiegu Summiuiuosip tuog paligigozd axe ulsanbo L jo a2t,lliA oqj gli ssauisnq 5uiop sia NOI,LVNIWIWDSIQ - Iapno jo aiep nauu sxep nepualt (0I) uol uiglim naXng of `2uilinm ui `uoildooxo so2polmou3loe nallaS ssalun potunsaxd oq Ilim Iapno sigi 3o aout,id000e s, .MIIOS gONV,LdaODV - (IOIIaS st of pOIIOJOI) IopuaA put, (naXng st of p011ajal) ulsonboiL Jo aielliA oql uaamloq put Xq olui paxaluo napno sigl of Olgeoilddu ant, suoilipuoO pue suUal guimolloj oqj V luouig SNOLLIQNOO QNV SWUH1 - saw .2ilgo leuoilippe se Iolot,ll OO OT put, O OT Oumu Ilim spuoq IIV - puoq ,ilddns t, IqSlUltl ut,o IopuaA e It XJilaA llegs noloenluoO agZ - napnO ast,goxnd Ogl jo lunoum oqI of pappt aq llim joanagl slsoo Ogl `paxmbOn si puoq X[ddns aql jI 'OSVIIIA agl of olgeid000t puu eprlol j jo Olels aqi ui ssauisnq op of pozuotlint Suudtuoo Xlaxns pOgilunb e Xq ponssi oq Ilugs `pOlinban ji `puoq Xlddns aq L - aoud xapio asugonnd oqj jo ( %001) luaoxad 88 W06AM 9 - OS - Xuedutoo all jo .zaogjo pozuoglnt ue Xq pou2is `ptagaaliai Xuedutoo ietoljo uo 013.13li 32utlo L paisonboi sul jollos all ssalun zapao uo glzoj las st ssazppe put Xutduioo alI of Xluo apmt aq lllm sluoutxtd SRDNVHO ,LMaWA,Vd •zapzo sill 2uiujaou00 aouapuodsouoo pue `slllq lglo -U `saotlou 2uiddms `sdtis Supped `sooionui IiL uo moddv Isnut ioquin& tapio 2IggMIN NE[CFd0 •(SQSW) I aalS 7 aIrQ XlojLS I liop W E Xq pomdm000, aq i snuz .zapzo slll jo Jm L su paaaAiiap aotrelsgns otxoi XUle IVII `salnMIS tPPold ` Ztltl aaldegD zapun paunbai oomidwoo rallo H,L'IVHH GKV ALg3VS IVNOILVd11000 •oogj0 ifuisuloznd s,aaKng jo antieiuosazdat pozuolinia ue Xq panozdde ssalun nXng uodn 5utpuiq oq Iitls zopio sill jo suoil7golipoui ON SNOI LVDIJIQOW •aapio sill jo oommu%iod all ui posn to joXng of plos lonpotd Rut jo asn alI jo Iun000, uo .to ioj Ilotjfdoo .to �I.zeutapeal ll !"Woo io )I.zvutapetl `ivalud salmS poitun Xu'e jo luautafuujut .10J 'KItitg it uto4 sivai?v put saafolduta slt `rlsanbol jo 05VIIIA all ssoluLmq plot put oAt's timis .13113S XXVWEIGV d L/J NEIJ Vd /ZHJI'dAd0D I •Xititgtsuodsaz uto4 jatla.t ioj asnuo v oq Xtm ou ui tivls jallaS ali Xq aSpaimou3i jo jovZ •suoilVIn2w put sopoo `saini `sooueuip .Io `smei Itlocq put XlunoO `alms `Ir.tapad algoilddt litm oounldwoo ui pouuojiod zo plos `painlovjnu*eut aq iit,ls `pazapuaz oq of saotA.zas ao `utazal pazanoo sutalt all lull sowft pue spuvisrapun lallaS 1 .13pio sili guild000e Xg A,LI IIEIISNOdm IVJgI •u13.13I P olt'Is ss01 P all 173 saotAZaS It'luauiuOJIAUg put 2uuaautsug To PP .ioloojl(l oli put aoutuld jo JoloaziQ alI of Xdoo t llim bib££ 'Id `ulsonba L `•pAig jeuquooig OOObI 2utsvl3znd Jo . ICI uotluollV `rlsonbo 1, jo OBEIIIA 34I of aotonut ltuT2uo Iopua.1 Isnut .iailo ONIOIOANI •asuodxa s, .iallaS ali Iu paumlai oq tllm pue iallaS all jo Xpodozd all uivwoj tlmis satllpounuoo poloafaz IIV •iolsonbay jo 3 SVIIIA ali jo antleluasazdai u Xq Idiooa.t uodn uolloodsut of loofgns WE .zap .Io sill uo pataAtlap saill poututoO IIV NOI LOgdSNI zapzo sill jo suual ali of Iuensznd saougtssu jo sioloealuoogns `sluast `saaxolduta sit ao `.iollos all Xq uotsstuto zo lot Xuv jo Ilnsaa L se paunout saaj Sotuollt put sasuodxo `sisoo Sutpniout spteme l cnoo put Xjjjjgeii `sailuump `suuelo ilt, put Niue Isum2t sivaf a puu saoXolduta sit `elsonbaZ Jo 39VIIIA all ssatuumg Piol put oAvs `Xjiuutaput llVls zallaS `mel Xq pozuoglnt luaixa ali o L NOI.LVOI3INL aam i 88 WOUM L - 0S ffQOD 'IVID'EMWOD mOdINfI •zapto osngoznd sigj jo 1 i?uisrre wirlo io aindsip Niue ui saaJ s,X3u.IoTIL' s,.topuaA Xvd ol u1sonboI Jo 3SVIIiA agP Fuutnbaz uotstnozd XuL apnloui jou titgs Iu s,.topuaA •slL3ua1eux io `spoof `juoutdtnba s,zopuaA `jo. arnjoujnueuz zo usisop agj zou `ut powiodiooui sleualeut agj ut spajap Xq pasneo saftump zoj X1tligetl s,JopuaA Iluttl XPm Xue ut Ilegs slt io `juautdinba `spoof pa.zapio age Xjddns of luoutaat2e s,aopuaA JO uotstnoid oN SLR WHI ff IffvI(iRDDVNa •bas 1a `OL'S I 31MUIS vp?jold `joV juauiXud Idutoz�l tlpuold all gjim pj000e ui oq Iltgs suual juouiXud jegj saallu ialloS agj `aapio stgj 5ulTda3ou gig SWUH1 - juauua nootd -at jo Isoo ssaoxa aoj algeil oq Ilim .talloS •ulsonba jo OSUIIIA agj Xq pald000e pine patanilap sutalt palaldwoo zoj }daoxo .taping of X1iiigeii jnogjim oq Ilim uoilruiuml Bons XuV •szolipon jo lgauoq oqj ioj juautatsse .to dtgstant303J `uotjeztueScoaz `juauzai?uejte `fojdnnlueq of Euqelaz mul IL io ajujS Xut npun .tallaS Isum5u io Xq paouau moo 5utpa3ootd jo paltg si uoligod Xue.It ao suotletado sii3o Xue spuodsns zo Iuanlosui sauiooaq tallaSji (q) ao rapio sigj jo sjuautaunbw agj jo Xue gjim aouupt000e ut uuojtad of slrel aalloS ji (e) jjnejap zoj ated ui io ologm ui npto sigj ajeuiuuaj of IgSu agj soAmsa.z awing NOLLVNILiUH L •sletaajeuz Bons Suunoas ui aaquznN uotjdutaxg xe L s,t sonbQ L jo aft'IItA agj asn of pazuogjnv aq .tallaS Niue Begs .zou ` isonbU, JO 32U1IIA age grim suotIe2tlgo Iun4oealuoo IIrjInj of sluiaajuut aoj saatlddns atagl of xel sales 5uiXud uzoaj Iduzaxa aq jou Ilegs ejsanba,L jo 32elliA age gjim ssauisnq Sutop szalloS - Xpadoad Ieuosaad algi2uej ioj saxul 31tIS pie Ieaapod uto4 jduzaxa si LjsanbaZ jo 3 iNIIIA ags XVJL •aapao asrgoand ejsanbo L jo aft'IITA pazuoglne Xlnp n Xq paaanoo ssolun pauuojaad sootnaas ao paaantlap spoof XUR aoI p31daooe aq jou Iitm Xjili gisuods 3 - d AZI'IIgISNOdSff2I - solved pies puiq of Xltaoglnv 3131dwoo put IIng ssossod pue opg Luoq `jovj ut `aae utazag pauzeu santjejuasaadaa agj jegj aaa2e aapao sigh of satPud IIV SffAI,LV,LNRSRNdHN •asuodxo s,.talloS it paumaa aq Xeut paluu2tsop X11juenb jo ssaoxa ut paddtgs spoVO •IUAOaddu uajjiam aoud s,.ioKng Inogjim p32uego oq joumo mpao age ut poUjoads satitlumo SHIIIINVT rj INISIPanpLI ao aanjeaaitl jonpoid ut uuoj ao nuueuz xvm Xue , ut aallaS Xq pasn aq Ig /A ooinaas io/put jonpoad agj jo tjsanbaZ jo 32ulliA agj Xq juauzasaopua oN A,I.IOIZfffld 88 W06JM 8 r r r r r •uotloolord IsalvaB aq1 glim igisonb L jo O &MA aqj s3ptAo .1d Aluvinm .1anagoigm `umioq pale .1odroom are gotgm jo suual oql `toe .1�uoo uOROWIsuoo Dill Jo suotstAord Xju umm oqj glim aountldtuoo ui .10 `satlutlinm Intu.1ou s, .1opu3A glim aoueildwoo ui uta .13q p3 .1ap .10 Sutaq slvrrajvtu ro `juatudtnb3 `spoof slt Tueuem jlegs 1! WT s33.1Su .1opuaA • .1010' .1Iuoo uotlotulsuoo -e iilim jo 4uoo - e of juens .1nd elsonbol jo OSUIUA 341 .1oJ lImq futaq pafo.1d uotjon.1lsuoo v olul uo!jviodiooui .1oj are p3 .1ap .10 Suioq slut.13letu aql vagl saspalmou lon IopuOA Ai xv VVM • . Bpuol j jo olt,,S aq, jo smel 3qj trim aoutp.1000e ui oq Ilugs uoilailgo lvMoeuuoo jo uotlnla .1d.1alut pine ss3oo.1d jo ootn.1as oqj pine npuold XlunoD got tuiud ut ploq oq Illm jo guoo stgi 33.10Jua of Xmss000u .10 tuo.1J Sutsut' WOMB heal IlL, p ine XUV .1ap .10 stq1 ut pales XIitogtoads you suotlipuoo pine stu of Xun ioj elsonbol jo OSUIIIA put' .131138 aqj uaamgaq suolltSilgo 17an4oe4uoo .1oj siseg oqj st Irena .1d Ilvgs (ZL9 .13jdeg3 solMI31S eppol j) apoD IntojounuoD uu.1ojzun oqs i i 991,006=1M 1, :1senbaa ul apnloul •uollnlllsgns aol lsenbei to s9ldoo 9n1111wgnS '8 alea 10ea1u0O 94110 sAep 9n11 ulyllnn a 991 JI 161 - 1 3 91 -11 of 6u1lpm ul apew aq lsnw slsenbaa uo1lnlllsgns IIy • „suollnlllsgns ou„ spiom 941 �(q p9mollol aae �(9y1 Jan9Ue' qm swell payloads Aue uo paaaplsuoo eq lou osle Ilp suo1ln1llsgnS • „Ienbe jo,, spiom 9y1 Aq pamollol aae A941 ssalun peweu uaaq 9AB4 si9.inloelnuew aaow ao onnl ejegm s6uimB ip a4l uo paylluepl jo ulaa9y payloads swall Aue uo p9111waad eq lou Ilp suo1lnlllsgnS •y :SNOIlf1111Sens ti0' I• 91 S11b'13a NN`dl EIEMAOlS NNyl 30V�10iS IOOeN 910 ti NV 43S0610�ld ANyl 30"O1S IOOeN 910 £ Mdld N011110W3a ANb'13!DVHO1S 100 910 Z NVId 311S 910 6 1 33HS 31111 'ON 133HS J1210931v0 I •sluawnoop loeiluoO ayl to lied a wjol 4otgm s6uimeip 6 uimollol a41 of waoluoo lle4s �aoM ayl :SJNIM"G 301SI1 £0' 6 •aa9ul6u3 91-1101 fuOloelslles aauuew a ul a010eiluoO a4l Aq 10 pasodsip aslNuaylo ao >IaoM a41 to alls a4l woal p9n01.U9a 9q lleys pasnai lou slepejew pa6enles IIy •a99u16u3 ayl to lenoidde uapim uodn ldaoxe �aoM ayl ul pasnaa aq lou Aew sleualew p96enleS •aoloealuoO 9yl10 Apecloid 94l awooeq lleys loeiluoo slyl aapun p96enles slelaalew Ile `s6uimeip a4l uo pelou ao polels 9slnna9ylo ssalun PUB s901n9p uolleluawn.ilsul pue siolow `sdwnd Aue 10 9nlsnlox3 :71VRi31b'W a39ynlyS MI, •9oinuas yons 10 uo1lelaada9lul aol aaumo ao Auedwoo A4!I!ln elgeolldde 9y1 woal peinoes sl bu1lpm ul Ienoidde ssalun `sall!pIn yons 10 (aaumo ayl 6ulpnloul) saawolsno luesaid Ile of saovuas A4!I!ln a9ylo pue euogdelal `oploele `96emes `a9lem snonulluoo 1 90ueu9lu1ew ayl aol 9pinoid of aoloeiluoO ayl 10 A4I1lglsuodsa.i 941 sl 11 `seipp1n aa410 se Ilam se sa1llliln s,aaumo a4l 1 suo1leo4lpow ao `s9bueyo `saledaa 9alnbei NioM ayl pinoyS •ftllllln ao aanlonils a41 of a6ewep a9ylanl esneo 1461w 4olgM suo110e Aue plone pue a9unn0 A411!ln pa1o911e ayl Apou pue)( ales ao1 Aiesseoeu aae sdals a9na1e4M aNe1 `NaoM a41 1 uollnoesoid a41 ul pa6ewep ao paganlslp aae pue 9noge pau11lno se peleool ao umoys Al.iedo.id uaaq 10u 9ne4 yoigm salllllln pue seinlonils 10 9seo 941 ul - einlonils ao ,4411!ln p96ewep 94110 JGUMO 9y110 lenoidde ayl pue eo1loe id piepuels lseq yl!m eouewaoluoo ul Alelelpawwl paaledai eq lsnw Aa41 `NjoM ayl 1 uollnoaxe a41 ul pa6ewep ao peganlslp aae pue pe liew ao umogs Alaadoid uaaq 9ne4 salllllln pue 9inlonils u9yM •sbuimeip a4l pue suolllpuoo bullslxa ueamlaq uollein9p Aue 10 ae9ul6u3 ayl Aplou Ileys aoloeiluoO ay1 •saanlonils ao sall!I!1n 6ullslx9 10 �4luioln 941 ul suolleaado sdoloeiluoO ay110 asneoeq paunoul slsoo ao paulelsns se6ewep ao1)(!pgell ou awnsse llp-199u16u3 9y1 pue JGUMO 941 'A4!u101n 941 ul s911910e1 al9yl to U0118001 94110 w14 9slnpe 01 Aou96e fq!l!ln pea 1senbaa lleys aoloe iluoO ay1 `5laoM 10 laels 91-1101 JOUd •lela91ew m9u Aue 6ula9pao of aolad paleldwoo aq llegs s141 •jaoM Aue 6ulwaojj9d of aolad sa!1!Loel jo sainlonils `s9l11II1n Aue 1 awnsse Ileys aoloeiluoO ayl •alemooe Aleigue aae umoys aso411e41 ao umoys aae sallllloel 6ullslxe Ile legl apew 1ou sl A4uejenO •spaoo9a a9y10 pue s aaumo 941 woal p91e aJam s6ulMeap ayl uo umoys sa!1!I!oe1 pue seiplp 6ullslxa ayl :SMin-.Omis (INV S3111111f1 JNIISIX3 60' 6 S1NEIVYM 10321 WdEIN3J 66060 NOUO3S 996006im Z=66060 panoidde pus palsenbei aq Aew sinoy )uonn p9pu9lx3 •suoijeaado Al!ep Iewaou unnopinys of W d 9 I!jun ails eqj uo Aels few pus Asp �Jonn 941 aol suo!jeaedaid uibeq o} •W •y 00 :L Is 91!s ay} Is aAwe Aew ao}osaluoO 941 •sAepilaann uo (•W•d OC:9 o} TTV OC:L) sinoy 6uiNjom a6ell!n Iew buunp palonpuoo aq ileys joeiluoo s!yj uo �Jonn lie `sunnopinys jo an!snlox3 :ajnOH JNN80M 60'1, •jojoejjuoO ayj Aq asn Aue wojl jueld ay} Is sa!}!I!oej bulls!xe ayl }oulsaj pus smaao plag iol sa!l!l!oel woojlsaa Ajeaodwal ap!nojd lleys aoloea}uoo ayl :S31111I0V=I �:13NMO 90' I• •91!s ayj Is asn ui aannod pus spunodwoo `sleo!wayo ay} jo Ile pus `Aue of ainsodxa Ie}uap!ooe aoj saanpaooid p!e Isig pus seo!loeid dales piepuels 6u lauumad plaq pus i(aoswadns Ile ejeonpe Heys aojoeajuoO 9y1 •anoge paweu swat! ay} jo i(}!wo!n a}e!paww1 eqj u! aq II!nn joea}uoo s!yj japun peimbei AJonn ay }to suo!:Pod •p!oe olanjlns pus ap!xoapAq wn!pos `ajuolyoodAq wnlpos `ol pal!w!l }ou aae jnq `apnlou sleolwego ay1 •A4!1!onej sigj Is asn oullno i u! s! aannod Ieou1oaia 96ellon y6!y pus sleo!wayo snoaa6uep snouen JeyJ pasinpe � lleoq!oeds s! aojoea1uo0 ayl :SNOiinVO38d A13:AVS LO' 1, •uoileldwoo le!luelsgns of ao!ad aoloealuoo ay} Aq panowaj Alajaldwoo eq Keys pus sepoo algeolldde lie yl!m eouepj000e ui jo}oea}uoO ayj Aq pau!elu!ew pus pajoauuoo `palle1su! `paysluanj eq Heys sau!I tieaodwej IN •J99u 94110 lenoidde eqj of loafgns aq Ileys fq!oujoala aol suo!loauuoo tieaodwel IIy •wajsAs Ieouloala jueld eqj woaj peinoas aq ueo Inq asuadxa unno s!y Is payslujnj eq ileys aoloeiluoo eqj Aq paj!nbaa jueuno Ieoujoala II`d :A-LIoiblO3'13 90' 1, •asuadxa sioloeiluoO eqj je aq lleys bullsel Ile a01 a91eM •J99u! 9 41 0 1 tio13els! }es Jeuuew e u panowaa aq Ileys aoloealuoO eqj �(q palle1sui 6uldld pus suoiloeuuoo fueaodwal `eoueldeooe leui -. 01 Loud •spJepue }S 96ell!n 01 bulpa000e pallelsu! aq Ileys saoinap 4109 •96e1l!n ay} woaJ poulelgo eq Ileys aajaw ay1 •jejew pus aaluanaad mollNoeq adf} ald!ouud einsseid peonpaa a yj!m peddinbe aq ileys wajsAs 96eli!n ay} o} sjulod uoiloauuoo Jejem IIy •Mulbu3 ay} Aq panoidde aq Aew se jeuuew yons ui pus suo!jeool yons Is Aluo }nq awes aol buldld pus suo!}oauuoo tiessaoau ulejulew pus Iielsui 01 pus `uoildwnsuoo oilsewop pus uo!jonulsuoo ao} asn siq aol jejenn 10 AIddns ejenbepe ue `asuadxa unno s!y }e `u!ejuiew pus ap!noid Ileys ao}oeiluoO ayl :�131VAA 50' 6 •uoijeniena 94110 :ped se siallddns pus suo!1nj!jsgns pesodoid eqj pus juewd!nba payloads eqj jo `sa!j!i!oej Jeumo uo aoueuedxe yons AIIe!oedse `aouewjojjad }sed elgea}suowep pus /(4!leuowwoo sped jap!suoo UP a9umO/Jaau!6u3 ay1 :eouewaojjad pus 4Ieuowwo3 shed •9 uosuedwoo Isoo INVO pus Iel!deo leipui apnloui ileys s!y1 •peg!oeds poylaw ao jonpoid yj!nn uosuedwoo ui uo!jnj!jsgns pasodoid uo e}ep Isoo a}einooy •L •sloealuoo ajeaedas of uoijele�j •9 •alnpegos uollonulsuoo ui sabueyo 01 bu!lela.i elea •9 - payloads pogjew jo }onpoid 41!nn uo!jnj!jsgns pesodo.id jo uosuedwoo pazlwell 't •spoy19w 6u!lealsnll! sbu!nneaa •q •pogjew pasodoid jo uo!lduosep pal!ejea •e :spoylaw uoijonalsuoo j03 •g •uo!jelle1sul jo alep pue `pesn seen jonpoid yo!ynn uo sjoefoid ael!wis jo sseippe pus aweN •p soldweS •o •spiepuels aouaa919�1 (g) •elep Isal pus aouewJo}Jad (Z) uo!lduosep jonpad W :aanjeaaj!I s,aainjoelnueW 'q •ssaippe pus aweu s,aainjoelnuew 6ulpniou! `uoljeogiluep! jonpoad •e :sjonpad ao3 .Z sjuawn000 }oeiluoo yj!nn uo!jn}!jsgns pasodoid jo eouelldwoo 6u!le!}ue#sgns ejea 9191dwoO • !, 99 60063M C IIe4 VOm ON •6ullnpayos ao} awll molle pue suoljoedsui j ol paau jo aoijou aleudoidde ap!noad lleys aoloealuoO ayl •slseq awll linj a uo �joM ayj 6upedsui aq jou II!Maaaul6u3 ayl :uolloadsul loafoid :SNOI1b213GISN00 1b'103dS L V I. •uollowlsuoo ayj jo uolsnlouoo ayj 1e panowaa eq ileys eaae 6ul6els ayj u! pesn (Mau pue 6ullslxe) lepolew uollezilpelS •6ulpeolun ao 6ulNaed aol sAemNleM ao juawaned bullslxe uo paddols eq few salolyan ON •ssaooe jelnolyan 91e1llloel of pezlllgels eq of paau Aew ease 6u16e1s ayj 01 s}uawano.idwi awos leyl alou eNel lleys joloeiluoO ayl •91!s uollonalsuoo ayj luoij yoigm sAeMpeoa ao sAeMpeoi lueld ayj 6uole jou pue eaae 6ul6els ayl ulyl!M eq lleys bulNaed aoloealuoO IIy •sall!!loel 6upixa of ssaooe ao}eaado }oedwl leyl seaae u1 ao juawaned 6u!}slxe uo an000 jou Aew 6ul6els •sueld aye uo pal:eu6lsep eaae 6uibels ayj ulyl!M Aluo an000 Ileys 96eaols juawdlnbe IIy V32JV JNIJy1S 9 6 • I. •aoloeiluoO ayj Aq of paaaype pue pags eq Ileys sl!wjad angoodsaa ayj ui q:pol las se `suoll!puoo IIy •sp.iepuels elgeolldde aaylo pue elsanbal 10 96e1iln ayl yl:!M aouepa000e ul aq lleys joefoid slyl uo pewao}aad NjoM IIy :SCIUV(INy1S 9 VI, •s6uilaaw ssei6oid lie pugge lleys saoloea}uoo ns a udoidde pue ua ua udns q e ua }. P � P �. `aa6euew joefoid s, ojoeajuoO ayl •peseaaoap ao peseaaoul aq Aew s6upaw sseiboid ayj jo Aouenbaal ayj `uo!} s,aaaul6 ayj IV •91!s qof ayj je piay aq Keys s6ullaaw yons IIy "sn}ejs qof Ileaano pue `swalgoad pa}oefoid pue bullslxa ssnoslp ol aige aq ifeys pue ssaa6oad loafoid ssnoslp of sNaaM (Z) ON /Gana 6u!}aaw snjels a puape' of pajmbaa si aoloealuoO ayl •passeooid eq jou !lp alnpayos pelepdn ayj Inoyl!M panlaoaa slsanbaa Aed •wal! iGana a01 suolloafoid awll uollaldwoo Mau pue sluawlsnfpe `ssai6oid lenjoe `alnpayos panoidde A!!eul6lao 9y1 A4!lu Alluepuadepui pegs alnpayos y3e3 •Isenbei fed yoea y l!M a99ul6u3 9y1 01 p94!wgns aq lleys alnpayos pelepdn ayl •a99ul6u3 ayj of saldoo (Z) oM} I!wgns pue alnpayos joefoid ayj jo a}epdn qtly }uow a aaedaad ol paalnbaa aq peysaoloeaWOO 9 y1:S9N1133VY/S31f1(13H0S SS3UE)OUd t VI, •Al!l!glsuodsai woaj aoJoeaJuoO ayj anallaJ AeM ou u! Keys `•oja `sMel algeolldde yl!M sanlaswayl azlaeli!wel of aan!!e3 •�aoM ayj joage aauuew Aue u! Aew l:eyl suolleln6ei pue sapoo `salni `saoueulpio `sMel leool pue ajels Iejepaj Ile yl!M iell!wej pue yl!M eouelldwoo ui eq of pownsse si aoloealuoO ayl :SMVI H11M.1 IWIllWb'3 E VI, •fi4lanoes a }!s of pajelaa uoljewaojuj leuoll!ppe aol saapp!8 o} uo of jejau Ole `spien6 lanoas `6uloual i(ieaodwa� of pa�lwy aq you inq apnlou! Ileys s!yl •A4!1!q!suodsaa s,aoloeiluoO ay} aq ileys eaae ayj jo fi4pnoes ay} ulelulew o} paalnbaa saanseew AGeaodwel Auy •91!s pue ilaoM ayj jo fi4lanoes pue f}ajes ayj aol aiq!suodsaa AIInj aq Ileys aoloeiluo0 ayl :.kii 1f103S 311S Z . I, •uoljewaoju1 ssaooe 91!s J leuolI!ppe a01 ZZ' I, `8l uoiloaS 01 aajaU •panoadde eq jou lip slulod ssaooe leuoll!ppy •ails NJOM ayl o} Mod ssaooe panoidde auo Aluo Alluaaano s! aaayl •ssaooe ayj asn of Aiesseoeu sl!wjad Aue 6ululelgo aol alq!suodsaa aq ileys JOIOBJIuoO ayl •a99ul6u3 pue a15BIHA ayl Jo uo110e1siles ayl 01 salnoi ayj 6upolsaa pue 6u `6ululelulew aoj aiq!suodsaa eq lleys aoloealuoO ay1 •suol1e001 VOm ayl 01 ssaooe aoJ a ayl Aq paleuftep ssaooe ayj Aluo asn Aew aoloealuo0 ayl :311S Ni IOM 3H1 Ol SS300`d I. I.' I• •wa}sAs leuollounj AlInj a eNew o} pn ayj jo jainjoejnuew ayj Aq peimbaa se s}ied lueuodwoo lie ys lleys aoloeiluo0 ayl `l!un ao �(lgwesse ue ile}sui pue ysluanj of paalnbaa s! JoIoeJluoO ayl aaayM :S11Nn b0 S3ll8W3SSy 01, ' I. •pa}sal bulaq pue pailelsui si juaweoeldaa ayl Igun Alienulluoo >laoM Ileys aojoeJjuoO ayl~ aolnaas woad. panowaJ s! NUBJ 6ulIslx9 ue a9}4y •uollelie}su! �uej jo spol.ied bulanp 99 60063M V •uollonalsuoo 941 bulanp A11llge lueld a4l ulelulew 01 '019 `suoi1e0019a luawdlnba `6uldld fueaodwal apinoad of iesseoeu 9q Aew 11 leyl palou Alleogioads si 11 •9oud loealuoo ayi ul pepnloul aq pet's sunnopinys azlwlulw of iesseoau aogel ao lelaalew 411M paleloosse slsoo IId •unnopinys a 10 uo1leanp 941 azlwlulw of tiessaoau sdels Ile aNel of paalnbaa aq lie4s aoloealuo0 9141 `lea9u96 ul •pepwa9d 9q 1ou limn sunnopings 9nllnoesuo0 •panoadde eq lou Ilp sunnopings lueld leloi •aoloealuo0 9 141 Aq bulllim ui palsenb9a aq ile4s sunnopinys lueld lerped ao lelol •u19jaq pol las aslnnaa4lo sselun `aa9ui6u3 9 141 Aq uollezlao4lne u a411no1411M nnoleq 41aol las suollellwil 9y1 p goo xa ase0 ou ul pue pez aq Ileys sunnopinys lueld lerped ao 1e1o1 •6uldld ao /pue 6uldwnd fiGeaodwel 10 uolslnoad 9141 uollonalsuoo ay11 9sanoo a41 uollipuoo 6ullea9do ul s Ile ulelulew of tiessaoau uo1loe Ile pue Aue 9� el Ileys aoloealuo0 aqi :sunnopinyS lea9ua0 'y :SNMO(i1flHS tiZ' 6 •loafoad slut to Maonn a141919Idwoo of paalnbaa luawdlnba Ane914 Ile to asn ayi woal (6ulned 6uipnloui) sallllloel 6ullslxe a1411o91oad of uaNel aq pinogs suo1lneo9ad aleudoaddy •loafoad 9 141 1 uollonalsuoo ul pasn eq of si 1! aaolaq a9aulbu3 941 Aq panoadde uaaq ane4 Ile14s pue `uollipuoo 6ul�aonn sselo -lsall u! `ails uollonalsuoo ayi uo eq llegs loafoad s1141 1 uollorulsuoo a9doad ayi aol p9ainb9a pue tiessaoau luawdlnba uollonalsuoo IIV :1N3lNdint)3 CZ I• •a99ul6u3 9 411 0 S 9141 le nn91n9a aol 9igellene aae s}lwa9d 9141 '1!waad slyl 10 sluawaainbaa ayi 141iM 9ouelldwoo ilnl ul aae s911!n!loe uollonalsuoo Ile 1941 bulansu9 pue sliwaad 91416u1nn91n9a aol9lglsuods9a 9q llegsaoloealuo0 9yi:SlIW0J3d.lbOld ZZ' 6 •luewaa luawd ao apeal y0e9 01 luenalaa u011ewaolu1 aney �(ew uolloas �(uy •peouaa919a ssoao All lou si uoileogioads 9141 1e141 p9slnpe si aoloealuo0 ayi :JN10N3a33321SS01:10 6Z' I• luawaa siyl 14l!M �(ldwoo loafoad s141 uo pasn slelaalew Ile 1ey1 wa!luoo pue aansue of flglgisuodsaa alos s,aoloealuo0 ayi aq Heys 11 '101ps!anf 41!M saioua6e of algeldeme pue a9lenn elgelod QM loelu00 aol panoadde 1,9/09 3SN aq Ile4s �11oaa!pul ao Ailoaaip a9lenn algelod 141!M loeluoo ul aae yoiynn loafoad ayi uo pasn slepalew Ild :S"JdIb31VW OZ' 6 •san000 uoileZlligow ails ao �aonnXu aaolaq algeld9ooe se panoadde pue lewaol and ul a99u16u3 94101 paaanl19p 9q Ileys oapin a141 10 Adoo y •ole'6u `uollonalsuoo 914110 seaae Ile adel oapin Ileys `a99u16u3 94110 uo110elsiles 941 01 pue `aou9s9ad 9141 ui `aoloealuo0 9 41 :JNId`dl 0301n N0110f1b1SN003ud 661 leul6iao ue141 aa}19q uollipuoo of paaledaa aq Ile4s seaae bul�aed pue sAennpeoa 6ullsixa 0196ewep Fu 1 pauoilneo Alleoilioads si aoloealuo0 941 •a99u16u3 ayi Aq panoadde aweal awll a ulyl!m ue69q NjoM aaolaq 1e41 of lenba uo!1!puo a 01 aoloealuo0 a141 10 asu9dxe ayi le paaledaa ao peoeld9a aq lle4s saanlonals ooelans pue Apedoad Bons `spaen6ales algeuose9a pue lensn Aoldw9 of 9anllel y6noa41 ao 'aa9ul6u3 94110 uoilowip oi1i 9 141 ao saoueulpao ledioiunw `snnel ale1S `sluawnooQ loealuo0 9 411 0 sluawaainbaa 9 141 1no itaaeo of aanl1el 146n0ayl ao Alaleaag!lap aa41a4nn `aoloealuo0 ayi Aq paganlsip ao p9nowaa `pe6ewep uaaq aney saanlonals 9oelans ao Apedoad a9410 ao seoual `keggna4s `s99a1 `1u9waned aa9yM :AiU3dObd CINV S3unionuiS `S3ov:mf1S 439VVYVa 30 NOlIV8O1S3b 96'6 •sluawaainbaa leaap93 ao a1e1S 'a6ell!n 9141 Aq paalnbaa suo aaylo to na ul pewao}aad aq 1ou Ileys a9au16u3 ayi Aq suolloadsul •aa9ulbu3 ayi �(q sseullnn aoiad 1no411nn pald9'ooe sllnsaa lsal aou 'dn p9a9noo eq 88 6006dM 9 •sa inseew ssaupaaedaad aueouany JoloeJluoo to ssaueleldwoo ayl Jol �4!1!geil sawnsse J99ui6u3 Jou Jaunnp ayl JayliaN '96ewep luanaad of seil!l!oel pue luawdinba 'saanlonJls 'sleiJalew ile to bui.inoes Jadoad pue an pue sa6elno Jannod papualxa 6uunp uoilounl of sail!I!oel 6uilsixe ayl to A4!1!ge ayl ezipJedoef Aew leyl sailiniloe l0 6uilnpayos -aJ 'ol peliwil eq lou lnq 'apnloui pegs pue Jeunnp ayll0 uoiloelsiles ayl of eq pegs saanseew yonS •6uivaem aueoiJJny Jo yolenn eueoiJJny e to eouenssi ay} to Juana ayl ui leaau96 ui lueld ayl pue Nionn siy loaload of suoilneoaad aleudoadde pue tiessaoau Ile gNel lleys JoloeJluoo ayl :ssaupaaedaad eueopinH •Q •suoseei Jo sAelap Jaylo aol pelndwoo slunowe Aue ui pepnioui lou pue sa6ewep leuoilippe se paaapisuoo II!ls lnq 'sa6ewep pelepinbil of palejaJ luewnoop ayl ui aaaynnasla pessnosip suoiliuilap pue eiJaluo awes ayl Japun passasse aq llinn sa6ewep asayl •Jaau16u3 ayl Aq pueyaaolaq 6uiliJnn ui of paaJ6e si uoisualxa ue ssalun 'uiaaay yljol las sliwil ay} spaaoxe uoilonJlsuoo duel leyl anoy lInl yoea Jol 00l,$ to lunowe ayl sa6ewep pelepinbil se.ieumo ayl of Aed of saaJ6e Joloealuoo ayl :se6ewea •0 - elgeldeooeun si welsAs peal leoiwayo ayl to umop -lnys aleldwoo - loefoJd siyl to luawaouawwoo ayl of Jolid welsAs aylto uoileaado se peuilep a.ie suoileaado Nuel lewaoN queld luewleaJl Jalenn ayl Jol suoileaado Nuel jewaou aaolsoi of peiinbei sailiniloe Jaylo Ike pue walsAs papelsui AIMOU ay} 10 6uilsal 'NJonn 6uidid Ile 'luewaoeldaJ pue lenowaJ Jol sNuel ayl of spew suoileJedaad Ile epnloui ll!m awil siyl sNuel yloq Jol'lelol'sNaann anilnoesuoo g paeoxe lou lleys sailiniloe plag luawaoeldaJ pue lenowaJ Nuel ayl to uoileanp ayl •aouenbes umopinys pagioads ayl of eleuaalle ue se paAoldwe aq lou lleys lnq paJinbei aq Aew swelsAs peal leoiwayo i(Jeaodwal queld luewleaJl Jalenn ayl to fq!leuoilounl /AliJ69lui ay} ganlsip lou seop leyl Jauuew a ui pue Alleiluanbas aoinJas woJJ panowaJ aq of aae sNuel eliJolyoodAq wnipos ayl •uiaaay y}Jol las se sapoo algeoildde lie glinn eouepa000e ui aovuas olui peoeld pue pelsel Aliedoad ag of aJe sNuel nnau ayl pue peoeldaJ aq pet's sNuel a6eaols eliaolyoodAq wnipos 6uilsixa 9y1:aliJolyoodAH wnipoS •8 •loeJluoo ayl of uoisualxe awil a Jol asneo luaiogns elnlilsuoo lou lleys suoilipuoo luawleaJl Jo 6uidwnd lueld to linsaJ a se umopinys polsenbei a to leaaalep Aue 'JanannoH •slsenbei unnopinys lie alepoww000e of Jaunnp ayl Aq epew aq pinn:Jolla aIgeuoseaJ AJan3 •sumopinys ayl Bump peAoldwe aq ll!m ao pinoo yoigm saipl!oel ssedAq Ajeaodwel Aue to uoildiJosep palielep a pue eoinaas woal liun ayl anowaJ of pasn eq of poylew ayl to uoildiJosep pel!elap a 'luawdinbe Aoua6aawe to A4!1!geliene ayl 'unnopinys ayl 6uiJnp paloeluoo eq Aew oqm lauuosaad buiNew uoisioap to Jagwnu euoydalal pue uoileool 'aweu ayl 'uoileanp polsenbei ayl 'umopinys aq ll!m shun sseooad Jo luewdinbe leynn elels Apeelo pegs lsenbaJ ayl •pouad umopinys ayl of aoiJd sAep 6uiNJonn (t Jnollo wnwiuiw a Jaaui6u3 ayl of sunnopinys Jol slsenbei uallpm lie liwgns lleys Joloealuoo ayl 88 L006JM ' L LO 'a ao aaumO ayj Aq uo!joe ou yl!m alew!lso Aed ayj 6u!uanlaj ao} spunoa6 eq lleys uo!}eluawnoop ajeudoidde yoe}4e ao ajew �(ed 941 u6!s ol. aoloe iluo0 ayj jo aanl!e j •salew!l fed 6ulmollol ayj jo le}l!wgns jol pasn aq o} sa!doo ailew lleys aoloei}uo0 ay1 - lepwgns jol asn o} io}oeiluo0 941 aoi wjol ejewllse Aed a Alddns llp a ayl :SV0J03 31VINliS3 ,kVd 50' L - yjuow ayj jo pug 941 6u!peowd Aep Niom lsel ayj eq lleys a}ep ayj `pua� eam ao Aep!loy a uo sin000 9lep - 4o -Ino ay} uayM aaumo ayj Aq }uawAed — gIuow 6u'mOII0J ay} J0 43 0 L Q ' aaumo 941 o} a}ewllse Aed — y}uow 94110 4j o L •0 a 9 41 o} 9IewiIsa Aed — yluow 9qI JO 4 } g '8 alep }}o Ino — yjuow 9qI 10 pu3 V :o} paaaype aq lleys alnpayos buimollol 9y1 •olaaayl lejuap!oul pue yl!mejayl uo!loeuuoo u! NaoM Ile bulwaojaad pue slepejew Ile bu!ys!uanl aoj uollesuedwoo IInj al;nl!lsuoo lleys }uawAed pue aoud yoigm 'pajdaooe pue pallelsul JO/pue pajois `swat! ogpecls , aol algeo!ldde pue pa!�!juap! se `sanlen Jo alnpayos panoidde aaau!6u3 aye ul pa }s!i pue Iuawaaa6y 941 u! Umoys wal! algeo!ldde yoea aoj aoud wns dwnl ayj le spew aq II!M }uawAed :1N3WJlbd b0' I, - }uawnoop s!yl }o suo!}oas jay }o u y}jol las pue paq!aosep aay�nj se Ile `saoud I!un pagpep! ' ao/pue sanlen jo alnpayos ayj uo wal! yoea aoj uo!jaldwoo jo abelueoiad panoadde .aaau 01 6u!pa000e joealuoo s!ylaapun pewaojjad �liomjol pled aq Ilpjoloeiluo0 ayl :1N3AMjnSb'3W £0' L 'aaumo ayj Aq panssi si juawAed uegm awll ayj jo peaye Allueog!u6!s Naom dogs ao slepajew paaols awos aol luewAed lln3 ai!nbaa Aew aanpeooid s!yl }eyl pas!npe AIleo!�!oads si aoloea }uo0 ay1 •aoloealuoo -qns �(ue ao ao}oealuo0 ay} �(q I!Ioad jo jogel epnlou! Iou Ileys le!aajew paaols aol }uawAed Auy •apew aq II!m lepejew jo 96eaols ajpgo Aue aol JuawAed ON '91!s 941 woad. panowaa uaaq 6ulney se paaap!suoo aq lleys peilddns IOU s! ua!I 10 asealaa %06 a yo!ynn JOJ w91! Auy 'alew!I,se Aed sno!naad ayj aol slepajew paaols se p91s!l waI! yoea 10 %06 a01 sua!I 10 asealaa `ajew!lsa fed buimollol ayj yl!M •0 •96eaols u! swa}! 10 Isll •8 - (sallgwesse pa.injoelnuew jo paleopcIel ao sio}oealuoogns aol papnloxe sisoo uolleouclej aoloealuoogns) aain}oelnuew ayj ol. pled junowe ayj Aq paupialap se paaols wal! ay} jo anlen ayj paaoxa }ou Ileys 9010AUI a41 '96eaoIs ul w91! yoea J0 9010AUI •y :6uimollol ayj pa:p!wgns sey Jobe iluo0 ayj yolgm aol swa}! asoy} aol apew eq Ipm �aoM ayj jo aps ayj le ebeaols jadoid ui juawd!nba pue slepajew ao} juawAed le[:Ped :30`d OiS NI SId12131bW C1NV 1N3Wd1f103 Z0' I• 'Juawaa. V ayj u unnoys IOU JJoM 10 swaj! Iejuap!ou! a ayjo ao sisal ebe�leal jol apew aq II!m juaw�(ed a}eaedas ON ' joealuo0 ayj yl!m aouepj000e ui paldaooe pue pajaldwoo �joM uodn paseq eq II!m juawAed pue luewaansegW :1"31\139 1,0' L WHEIN30 - L il:]Vd 1N3WJlbd CINV 1N3ABbnS`d3W , 09 LL0 N01103S S L006 M L W „IIwgnsal pue aslna�j„ ao „panoaddy ION„ padwels s6ulnneip i Aue to Adoo uin}aa do poN iew auo Aluo anlaoaa IIIM aoIoea}uo0 ay1 - uoljoe aay}anj jnoyjlnn pauanjaj eq IIIM dwejs „panoaddy pue peNoayO„ s,jojoeajuoo ayj }noyllnn panlaoaa sbulnneip doyS - 6ulnneip dogs ayj jo Adoo yoea uo „panoaddy pue peNoayO„ peNjew dwels a Aq paleolpul se `Joloea}uoO ayjAq panoaddy pue parayo eq Isig lleys leAoidde sly J0la99ul6u3 ayI 01 pa:}Iwgns s6ulnneip doyS - uol}eollljuapl joefoid aleudo.idde apinoid pue `buinneip dogs yoea pajedaad sey yolynn walj jo aweu aleolpu1 - unnoys Mionn ayj ul slonpoid pue slepajew A4Ijuepl 'sjuewaanseew play uo paseq aae yolynn alou pue suolsuawlp nnoyS •algejdaooe se paleoipul sl waoj aaylo aaaynn ldaoxa 'eleos aleinooe of s6ulnneap dogs aaedaad - s6ulnneap adA4 aleldwal ao wel4ed len}oe aoj ldeoxe ` 98 x - ul tiZ ueyl aa6ael lou pue - ul L L x •ul Z /L -g ueyl ssal jou `shays alglonpoidaa uo aaedaad •s6uimeip dogs jo slseq se uollewaolu' ! peluud piepuels Adoo ao sluawnoop joeiluoo eonpoidaa jou op :uollewaojul paaedaid Alnnau IIwgns lleys aoloealuoO ay1 - s6ulnneip dogs paalnbaa llelo (saldoo (e) aaayl jo wnwlxew a of sluewaalnbaa unno sly jo} Aiesseoeu ' saldoo esoy} of uolllppe ul) saldoo (t,) inol 'lenoidde JOI a99ulbu3 ayj o} Iiwgns lleys `joeiluoo ayI 10 suollipuoo 941 41lnn aouewJOIuoo ul 'JoIoealuoO 941 `paaooJd o} aol}ON 941 a94e sAep (9t7) aAUA}Poj ulyllnn pue algeoljoeid se uoos sy :S1N3W3Un03H ONIM"(1 dOHS IVI13N3J V0' L - lepwgns jo Aao6elGeo paleolpul yoea ao} ulaaay payloads sluewaalnbaa lea9ua6 ql!m Aldwoo `suoljoas Mionn lenpinlpul ul pa}eoipui aslnnjay }o se jd90x3 :IeJ9u9O :SiN3W3?MOM 11V111Wef1S M30031VO 013103dS £0' L , - sisal 6ulllej pue 6uissed yloq apnloul Ileys slyl •a99ul6u3 9 41 0 1 pa}4Iwgns eq lleys s9loue6e ao sgel juapuedepul Aq bullsal jo sllnsai IIy - uoljoe Inoy }Inn peuin}aa eq , limn aolj}o s, ojoealuoO y6noayl ueyjaay }o saoanos woa} panlaoaa aae yolynn sle}}IwgnS - 6ullpuey pue le:41wsueal aol Ala}eijdoidde Ie}}lwgns yoea 96eN3ed •pallelsul eq of sl wall ayj aaaynn ajels Apselo Ileys Ie}}Iwgns yoea •a99ul6u3 ayj Aq paalnbaa se eq Ileys pasn wa}sAs 6ulmiew ay1 •sle}}Iwgns ' aayjo woaj jI ysln6ullslp of uoljewiolul aellwls pue aweu le:}Iwgns `aoloealuoogns 'aoloealuoO `alep `joafo.id A41 }uapl of le}}Iwgns yoea uo 6ulMaew luouewaad apinoad :sle}4IwgnS }o uoljeaedaad - sle}}Iwgns aouanbas pue aleulpa000 Alaadoid of amilej jo esneoaq pannolie eq limn awil 10 uolsualxa ON •aayloue yllnn uolleulpa000 aol paAelep aq jou lllnn auo jeyj os `Nionn jo shun 6uloepalul aol pue `�jonn awes ayj aol sle}4lwgns }o salao6aleo luaaa:lp aouanbas pue a}euipa000 Keys aoloealuoO ay1 •sie:}Iwgns ayj COI aaaul6u3 941 Aq awl} nnalnaa alenbape aol nnolle Ileys aoloeiluoO a41 Aq paAelep aq jou IIIM M ions ayl IegI os Nionn ay} jo eouewaojjad pm slepwgns jo 6ulssaooid pue uolleiedaid aleulpa000 lleys joloealuoO ayl :6uiouanbaS pue uolleulpa000 :S1N3W3bIflO3211V111Wens l"3N3J ZO' L - suolloas asoyj jo sluewaalnbaa ay} molloj Ileys suolloas jayjo ul payloads se sle:p!wgns aaglo - N ions jo }lun yoea ao} suolloas elgeolidde ul pue ulaaay payloads aie sluawaa lepwgns lenpinlpu ayl •sle}}Iwgns palelgi-N ions snoauellaosiw pue `saldwes , 'slenuew uol}on.ilsul `slenuew aoueualulew pue uoljeaado `s6uinneip dogs apnloul sluawaalnbei ieaau96 asegjAq palloaluoo sle:plwgns jo sedA4 ayl :SIN3W3UniD :1 JO NOI1d180s3a LO' L IV'd3N3J - L IHVd SiViinanS 00£L0 N0 1036 88 6 006J M Z l, 0 r r r r r r r •(elgeolldde IOU) NO11f1O3X3 GN`d S10flaObd - £ aMd Z lbdd •suoljlpuO0 lejauaO ayj jo EO'9 PUB ZO'9 `l,0'9 saloi:pyAq peiinbaa se joa}}a ul aie aoueinsul suoljeaado pajaldwoo pue spuoq 1eyj looid Ilwgns lleys ao}oe.iluo0 ay} juewAed leug 01 JOUd ' :3OWb inSNl NOliV'd3dO a313ldWO0 aMd aNOS 90' 1 r •sesod nd uollonilsuoo aol pasn IOU pue J99ul6u3 ay} Aq nna a01 sawl Ile le algellene `uolIlpuoo pooh ul poule}ulew pue ,,Ado0 paooq�l joafad„ peNjew Alaealo aq lleys sluewnooa PJooa - 8 1oafoid ssgyl 10 yoe3 •suoljeoljloads ay} 10 suop9s snousA yjIM aouelldwoo ul aoloei}uoO ayj Aq pa:4lwgns sluewnoop panoadde ' a pue `.SuO1Ie09ipOw joejjuoo jay }o :saapio play :siapio abueyo :sbuimeip dogs panoadde , epueppe `suolleoliloads `s6uimeip pe to Adoo quo a}ls -qof qyj le uleju!eW :S1N3Wf1OOa 90' l pajeolpul aslnnaggjo ssalun `paooai pue uol;ewjolul aol sl le:4!wgnS •pewjljuoo uaaq sey s}uawnoop joei Iwo ayj jo sluawaalnbaa yj1M aouelldwoo lljun 'jogfoid qyj uo asn sjl molle jo elep jonpoid Ilwgns IOU lleys aope.iluo0 ay1 - sbuimeip dogs yl1M snowAuouAs eq lleys sbuimeip uoljeopclej s,aaanjoejnuew `le}}lwgns slyj jo sasocl ind jod •J99ulbu3 ayj Aq aouaaajaa jo} algel!Bne `a}ls loafoid ayj le lepwgns pea joj elep jonpoid jo jas auo ulejuleW sluawailnbaj uoljeulpa000 leloads pue pq>lo9go uaaq aney yolym sjuawaanseaw plaij jo uol }e}ou `sleas pue slagel jo uolleolldde `sp.iepue }s qpm aouegdwoo `asn pue uolleolidde joj suollepuewwooaa paluljd piepuels spin}oepuew epnloul •joefoid ayj o1 algeolldde aie suolldo pue seoloyo yoigm mot's of Adoo yoea ' �iew pue 'walsAs io Niom jo llun yoea aoj le}}lwgns auo olul elep paalnbaa loalloO :ejea jonpoid J ayj Aq pajsanbaU swa }l i9gJ0 Auy •9 ' siluel 96mols le01wgg0 9 sbulleo011b' •ti s:poddns adld pa}eolaged _£ (slepajew pue s9dfi4 Ile) bu!d!d Z (slepajew pue s9dA4 Ile) sanlen .1, :6uimolloj qqj aoj pa14lwgns aq lleys sbuimeip dot's r r 891,006=1M ' L I, 0 •pajledej eq Ileys pue sleel pajaplsuoo eq lleys s}sa} ay} wojj buI}Insw sewe dwep Auy • sanoy 8t, aq Ileys buI}sa} 96e� eal Ile jo uoI}ejnp ayl •sal}llloej 941 10 uol}ejado 6uljnp palidde aq pinoo }et'} peat' of }e }s jo aanssaad wnwlxew ay} o} pall. U94M 96e� eal lie jo aaa} eq Ileys `ajaynnasla paI}Ioads eq Aew se 'bul}sa} a6ei eal o} }oafgns }ou we }et'} spinbll 6ulule }uoo }uawdlnba jay }o jo slassan aanssaad `a6eNue} Ilb :SS3N1HJ11 b31t/M 50' L •jeunn0 ay} Aq aslnnjay }o pezljoy}ne ' Alleompads ssown a }Is }oefojd ay} uo lepa}ew Ile ajo }s lleys jo }oej}uoO •s}uawele ay} woj} pa}oa}ojd aq Ileys }uawdlnba Ile uo suol}oauuoo oI}ewneud pue ollnejpAq `leolj10913 •uol}elle}sul apls }no jol papua}uI }ou sI yolynn aps ay} uo }uawdlnba mou Ile JOI 96ejo }s aplsul 'pajanoo apinojd Ileys jo }oej}uoO u011elle1sui o} joljd a }ps }oafojd ay} }e 96ejo }s wja} -buol Aiessaoauun azlwlulw o} se os salnpayos ifjanllap Ioj}uoO •sasseibojd Niom ay} jo eouewjo}aad ay} se s}Insaj Aplenb }say6ly 6uljnsul Agejay}'(sAelap buI}insej pue) 749y} 6ulpnloul sassol pue uol}ejolja}ap , `sa6ewep }uanajd Illnn yolynn sueaw pue spoy}aw Aq `s}uauodwoo pa}eoljgej 6ulpnloul `s}onpojd pue slelja}ew }oa}ojd pue ajo }s `aIPUeH :JNIIaMdH 13nl13a ion(] bd ti0• L •spjepue }s dlysuewNjom i j}snpul sa }n }I }suoo I }eynn }o a6pnf alos ay} aq Keys jaaul6u3 ayl •spjepue }s asoy} y }Inn 6uiAldwoo dlysuewNJonn }o algedeo bulaq }o pue 'Niom }o /Go6a}eo }et'} jo} spjepue }s �}Ilenb pazlu600aj pue algeolldde y}lnn jelllwe} 6ulaq }o }ua}xa ay} o} 'peljllenb -ajd aq Niom ay} 6ulwjo}aad jalle}suI jo uosjad , sepej} }o �Go6a}eo yoea }et'} }uawajlnbaj a sl }I •algeolldde ajaynn spjepue }s ISNb 6ulpnloul 'Niom jo }Iun yoea o} algeolldde se Aj}snpul ay} uly}lnn spjepue }s i4!lenb dlysuewNiom pazlu600aj qpm Aldwoo pet's jo }oej}uoO ay} `peg!oeds Alani}lugap ejow se }daox3 :30Nv jnssv �linvno co L •s uawnoo oej uoo a o s uawajinbaj a o uaw i n jo i i i ' } p } } y} } } y} } 3 Il.}I � } �.I.g. suodsaj }o jo }oej}uoO ay} anallaj lleys `s}lnsaj :podaj jo ezAleue Aljadojd o} jo s}sa} jo suol}oadsul a}enbepe wjo}aad o} 'jo }oej}uoO jo jaumo Aq pa6e6ua jay}aynn `saloua6e }sal }o empe} oN , •wns }oej }uoo ay} uI papnloul aq o} pazlu600aj aje saljo}ejogel 6uI }sa} }uapuadapul Aq saowas pajmbaj esoy} joj s}soo ayl •bul}sa} pue suol}oadsul }o uol}eog!jou sanoy 8ti y }Inn j99ul6u3 ay} apinojd Ileys jo }oej }uoO ayl •jaaul6u3 ay} y }Inn 6ul }sa} pue suol}oadsul alnpayos o} jo }ow1wo ay} }o A4I1lglsuodsaj ay} aq ll!m }I •slseq awl} Ilnj -uou a uo suol}oedsul wjo}jad II!m jaaul6u3 ayl •){jonn ay} jano Ioj }uoo leuol}olpsljnf 6ulney A}l}ue Aue Aq pajmbaj suol}oedsul jo s}sa} lie jo} elglsuodsaj aq osle lleys jo }oej}uoO ayl s,jo }oej}uoO ay} aq lleys suol}oedsul pue bul}sa} ay} y }Inn pa}eloosse s}soo pt' •f41 }ua pgg!:pao Ap9dojd a Aq pawjo}aad aq lleys suol}eol,}Ioads asay} Aq pajmbaj suol}oedsul pue 6ul}sa} Ile'pa}ou aslnnaay }o ssalun :SiS31(INV SNOIlO3dSNl bOd A-LII181SNOdS3b Z0' L +� •}uawaojojua }oej}uoO pue Ioj }uoo Aplenb o} 6ul}elaj sal }np s,ja9ul6u3 AIpow jo Apoads }ou seop uol}oes slyl •s}uawajlnbaj pa}eloosse pue 6uI}sa} pue NioM ay} jo suol}oadsul `o} pa}lw �(Iljessaoau }ou sl }nq 'sapnloul „Ioj}uoO X4!lenp„ wja} ayl •s}onpojd pajn}oe}nuew }o 6ulyslujn} puoAaq �jom ay} jo seouewjo}jad o} AIljewljd aje uol}oas sly} joj s}uewajmbaj ayl •ulajay pa}eedej }ou aje pue s}uawnoop }oej }uoo ay} }nogbnojy} pa}eolpul aje >Ijom ay} jo} s}uawajlnbaj Ioj }uoo Aj!Ienb oigioedS :SiN3W3bin03b d0 NOIldIbOS34 1,0' L , I`db3N3J — L J_bVd IOb1NOO ,kinvno Ibb3N30 OOt NOIJ_03S M006dM Z 'polJad uol}onJlsuoo eqj 10 JapulewaJ eqj 6uunp uolleJOuajap Jo 96ewep Inoyllnn ulewaJ ll!m ' 11 leyl aJnsue of ijom pellelsul Alnnau joeloJd pue `sayslug paJJew GiolsaJ `ajeolJgnl 'uealo `Isnfpy 'uolsloap leUll JOI J99ul6u3 ayl o} seoloyo Iy6lgy bullunow glgeuol}senb Jaja�j •paleolpul suolleolldde Joj `s}y6lay 6ullunow piepuels pazlu6009J- itJjsnpul le Vom jo spun lenpinipuI junow `pajou aslnuay }o se Id 9=3 :sly6l9H 6ullunolN 'uoljeaouajap }uanaJd of paJ se `� jom apledwoo -uou woil � jom }o pun yoea alelosl 'Niom aJllue ql!m uolleulpJOOO ul `Njom jo llun yoea Joj sllnsaJ elglssod lsaq aJnsua II!m yo!ynn uollaldwoo loefoid jo snjejs pue `Jaylee m palseoejol'aJnsodxe `A4!plwny `aJnleJadwello suolllpuoo 6uunp l.ionn llelsul uollellelsul yoea 6ulliels 10 dels leJ6glul ue se Njom ayj }o suolsuawlp pue sluawaJnseew rayoaJ lleys Jo}oeJluoO ayl ' 'pa}eolpul eslnnJaylo jou jl saoueJalol AJlsnpul pezlubom ulyllnn pue 'lanai pue gull o} anJj :pallelsul sl �l se N'om 6uunoes Jol spoylaw pue sgolnap u01109uuoo pue Juawyoe}}e apinoJd 'swgJl GAII0919p pue pa6ewep JoafaJ pue `uolleilelsul of Joud Alalelpawwl juawdlnbe Jo sleuajew jo wel!l yoea joadsu! lleys JoloeJluoO eqi 'sluawnoop joeJluoo eqj ul pa}eolpul sluewaJlnbgJ elgeolldde ueyj lua6uuls aaow Jo 1lolIdxe aaow age asayj Jual<xa Jang1eynn of `uol�ellelsul Jol suol�epuawwooaJ PUB suollorulsul algeolldde s,Jainjoelnuew yl!m Aldwoo `slonpoJd peinjoelnuew apnloul suolleile}sul aJayM :suol}onJlsul s,JaJnjoejnuelN :102i1 NOO killvnc) N011t/llb-LSNI ZO'£ •aalle}sul pue Joleougel ay} of algejdaooe Jauuew a ul pajoeijoo uaaq aney suolIlpuoo tioloelsllesun I!Iun l.ionn ayl ql!m peaooJd jou oa 'suoll!puoo Ajoloels (J99ul6u3 ayl pue J010eJluoO ayj of 6uilpm ul) liodaJ of pue `pewJO}Jad eq limn liom ay} yolynn Japun suoglpuoo pue `Niom ay} gnlaoaJ o} 91eJlsgns joedsul of �jom jo Thin Jofew yoea jo aallelsul pue Jojeougej ayj aJlnbei lleys JoloeJjuoO ayl :suolllpuoO jo uoljoedsul s,aallelGsul :N011dll`d1SNl �JOd NOUV` jVdMjd LO'£ NOunO3X3 - £ i2]Vd (algeolldde jou) sion(IMM - Z ibWd ' •pallslles eq lleys 6u pue uoljoalu of palelaJ sluawaalnbei }uew:pedaa ylleaH pue d3(1=1 J IIy •paulelgo uaaq aney saldwes g }es 10 sAep ON 1noesuoo orvq pun fuoleJOgel panoJdde alels a Aq unJ pue ue� ej aq lleys saldwes leol6olouajoe8 •sNuel IOOeN nnau gyj apnloul ll!m slyl •pgysnij Alluenbesgns pue uol}nlos euuolyo I/6w 09 e yl!m paloalulslp aq lleys uolleogloeds slylF Aq sluewaJmbei 6ulls9l Jo uolloalulsip of joafgns eslnnaaylo jou sl yoigm pawJO}Jad uaaq sey Niom ejegm 96eNue} IN :9NIlS31 1 9 NOliO3dNISla 90' L 88L006dM L W •sjeedde uo!lewjojui ay} ajaynn }aays i(jana uo papjooaj aq Ileys s6ulmejp ay} of sa6ueyo s109119j yoigm uo!jeuaao }u! paooa�j •unnoys sl wal! ue aiagm uo!leool fd;DAG le paleolpul uo!jewjojul piooaj pue pamalnaj aq lleys bulmejp y3e3 •s6uimejp piq leud io ayj uo paj ui pe�jew eq lleys uoilewjojui pjooeU •le:4!wgns uo!laldwoo le!luelsgns ayj souls pajjn000 aney yolgm sa6ueyo Aue joellaj of joloejluoO ayj Aq pas!naj aq Heys s6uimejp pjooaj ayl `luawAed leu!,J 01 JOUd •sbulmejp ayl 01 uo!lewjojul pjooaj lie j91suejl 01 a99u!6u3 ayl jol awll a}enbape molle lleys joloejluoO ay} alnpayos }oafojd a 6u!dol9n9p ul •uopidwoo le!luelsgns jo uo!l!puoo e osle si aseelaj s!yl •asn jol walsAs ayj jo asealaj jol luawljedaa yjleaH ay} of IeU!wgns jol pa.i!nbai aje s6u mejp pjooaU •j99u!6u3 ayj Aq paldeooe pue pa:4!wgns uaaq aney s6uimeip pjooaj I!Iun uoijeldwoo lelluelsgns ui aq of pajep!suoo aq jou lleys loafojd ayl :1b111W9f1S ZO•E •sioloeil<uoogns wojl pa}daooe aq ll!m uollewjojui s6uimeja pjooau ON •pallelsu �tllenjoe , Miom ayj sluesaidai � Arid pue a}ejnooe si pays!ujnl elep Ile jeyj u!eljaose pue s6ulmejp pjooaj palaldwoo ayl< nnalnaj Ileys jojoejjuoO 9q s6ulmejp pjooaj ayj uo papjooaj pue jdai! aq lleys swat! jay }o pue luawd!nba `sajn�xg `6uldld to uo!leool u! sa6ueyo Io spaooaj AI1ea :S(IU0O3U LO•E Noun03X3 - £ i2]Vd •uolleool pue jagwnu le!jas `lapow `add} duel •E •suo!Jena!a aseq luawd!nbe Ilb - Z •loj}uoo lejuoz!joy liv • L I :uo!}ewjoJul bu!m011oj ay} mot's Ileys sbuimejp pjooaH :Iuawd!nb3 b •elq!6al pue jeau aq Ileys pue uo!lGewjojui ll!nq se joellaj lleys pue uoijonjlsuoo 6uljnp spew sluewnooa }oejluoO ayj woij sa6ueyo Ile mot's Alalejnooe pue Alloajjoo Ileys s6u[mejp pjooaj ayl :SJNIM - d(I (IU0O3U W7 sion(IOUd - Z iHVd •wnled sE)sn uo paseq aq Ileys suo!jenala iiv :AnjLva b0• L I •uo!lewjojui piag lie sluawnooa joejluoO ay} jo s6uimejp uoljonjlsuoo ayj uo �jew lleys joIoej}uoO ayl :Slb'IU31b'W co L saovuaS anll;el!l!geyaU pue ylleaH jo luewljedaa ep!jo13 jo ajejS •0 uoijelnba�j Ie}uawuoj!nu3 jo juawpedaa •9 sapoo . pue Iedlo!unw `)�unoo leool •y :spjepuels pue sapoo 6u!mollol ayj yl!m aouepj000e jo!jls ui aq lleys uo s6u'mBJ(l pjooa�l ayl :SNOIlV0l=llO3dS 4NV SGUVGNd1S `S340O 319V011ddb' M L I •s6ulmejd pjooal jo }as ajaidwoo a job. Aiessaoau uo!jewjoju Ile j99u!6u3 ayl 6u!ys!ujnl epnlou! Keys uoiloas s!yljapun pajanoo NJOAA ayl :N011dlb0S3a LO• L lV'd3N30 - L -LUVd SJNIM 'd(I (MOOMI OZLLO NOUO3S M006JM L - 05020 N0un03X3 — E i?]Vd (past ION) S10fldO ld — Z i2JVd •J ayj of algeldaooe sl Il pun paliels eq Ileys slenowaa ON •ajojajayl ainpayos pasodoad sly jo 6ulllaM ul a99ul6u3 ay} AAOU Ileys aoj0eajuo0 ayj `IeAOwaa ao uolplowep a jo juewaouawwoo of aoud sinoy gt, Iseel IV '3 •sallilloej 6ullslxe 941 ul NJOM pue suoljeaado yjlM aouaaajJajul plone 01 se os suol#eaado sly }no Aijeo lleys Jo}oealuo0 ay1 •0 •aaumo ayj of bul6uolaq Alaadoid Aue of ao `ulewaa of sa!l!I!oe3 ol; euop 96ewep .nedai lleys ao}oeiluo0 ayl '0 'o!.9eil o} aouaaapalul wnwlulw a ql!m palonpuoo aq lleys suoljejado py •pappied eq jou Il!m slepejew jo 96eaOIs ao juaweoeld ayl Aq Niom eqj of l!ueoefpe sAempeoi jo bul}on.gsgo ao bulsol0 '9 saanjonals Juaoefpe woaj pue of 96essed ales pue aaal pue `asn ayj yl!m aaajaalul of jou se os pue `sesneo aayjo ao sugep bulllel woil }lnsaa ly6lw yoigm saanlea} }ueoefpe pue joaaayl sluedn000 'sa in;onals o} Ainful ao 96ewep luanaad 01 NJOM lenowaa pue uo!l!lowep ayj ajnoaxa lleys ao}oeiluo0 ay1 •y SNOI11aN00 90f ML - payloads aaojaqulaaay se Ideoxe suoljeaado jueld jo uolldnijejul ou aansua of swell algeolldde aayjo pue eolnaas jo uollenulluoo `saolnaas tieaodwal `J}o -lnys aol uolleulpa000 apnloul eouanbas uol}eaado pue luewdlnba `spoylaw pasodoad ayl „slel}lwgnS„ pall4ua u011096 qj!m aouepa000e ul ` j ol Ilwgns ileys aoloealuo0 ayl :S ZO• L lesodslp jo eoeld UMO s�o}0eajuo0 ayj 01 91ls ay} woaJ panowaa aq lleys pue fjjadoid s,aoloealuo0 , ayj awooeq `aa9ul6u3 ayj Aq pasealai uagm `Ileys lesodslp aol paleu6lsep slelaalew 11V '0 •uolleool ails -go elgeldeooe ue }e swajl paysllowap lie jo asodslp Algellns ileys aoj0eal.uo0 ayj `leaaua6 ul •joefoid ayj aleld woo of paalnbaa jo SBUIMeaa 941 uO UmOgs se `JOaaayj suollaod jo seoueualindde ao `juawdlnbe leolueyoaw `}uawdlnbe ieoploale `sllnpuoo `buldld `sllem `aan}onals 6ull<slxa Aue 96B AIBS ao JO asodslp pue anowaa Ileys aol,0eajuo0 9 q_L '9 6ulnieN6uldld snoeuelleoslW sNue1 96ei0lS gjpoiyoodAH wnlpoS bullslx3 :aae joefoid slyj uo panOwaJ .ao/pue paysllowap swaJl ayl leaau96 ul y >ibOM JO NOI1dR:J0SM LO' L - 1"3N3J — L iHVd N01111OW30 OOOZO N01103S 886006JM Z - 090Z0 Ile `Njonn uoililowep a4l jo uoilaidwoo uodn 'salelnwnooe 11 se suoileaado lenowaa pue uoilllowgp ay} woaj buglnsaa sugep Ile alts loefad a4l wal gnowaa Ileys aolowwo0 au :dnNV310 90T - aoloealuoO a4l Aq paiiedaa eq Ileys `lenowaa a4l Aci paleanaJ seoepns pe6ewep a94lo ao p9dd14o `saeos 'salo4 ane4 4OILIM pue Ulaaaq payloads slenowaa a4l jo Aue Aq pasodxa aae 4o14nn 'saooll jo seoelanS :)2iOM UVd32d VOT •J99ul eqj Aq pgalnbei se 6ui66nld pue buiddeo `buipno apnioul ilegs 11 •Nionn a4l jo uoilaldwoo a4l aol paalnbaa jo unnogs se seoueue:pndde a94lo pue luawdlnba '6uldld 6uilsixe jo r 6Uln0waa pue 6uilluewsip to lsisu0o Ile4s slenowaa leOlUe4OaW :SIVAOVV32A IdOINVH03VV COT •jaumO 94l 01 lsoo ou le jaumo a4l jo uoiloelsiles a4l of paoeldaa aq Ilegs `uoilezuo4lne aadoid lnogl!m panowaJ seoueug:pndde pue 6uldld `luawdinbe Auy :1VAOV\I3�J a3ZWOHinVNn ZO'E •uolleOOl panoadde ue le alls}}o M `swan panowaa Ile to asodsip Apecloid llegs jo l o e il uoO •sainseew do -uealo (aalennpunoa6 pue Ilos a4l of uoileuiweluoo buillnsga AUe 10 6ulaolluow Jo/pue uolleipgwaa gnilOe buipnloul) waal 6uol pue (saanseawaglunoo pue 9suods9i Inds 6ulpnloul) waal:pogs a4l 4log aol alglsuodsaa Alleioueuy play aq osle Ilpioloealu00 •swelsAs 6uldld a4l alenoena �(lagdoid of ganilel pue eou96116eu s,aoloeiluo0 M a4l woaj buillnsai Inds leolwa4O � u'e aol algell plan aq lip aoloeiluoO 'pajinbai sl builnpa4ps pue uoileclalue elgelins ing j94loue of duel quo woa} leolwa4o aajsueal of elglssod si 11 - duel a)( clwe 01 SN99M leaanas ailel Aew li pue saw!l Ile le tioluanui algelins a uieluiew lsnw aau a 4l 1e4l g eNel Ileys aoloeiluoO a41 •alglssod aq lou lip 6uV dwe Alln3 •sdwnd 6uilsixa a4l q inn alglssod se quel ay} woil aluo1400dAq wnlpos 4onw se gnowaa IliMaaunnO 941 uolleollllou gouenpe alenbape to ldiam uodn •uolmowep o} aoud 6u aOUe�tanuOO pue sNuel a6ejols aluol4 q wnipos 4loq 6u1lenoen9 pue bUj4dwe Ailnl jol elglsuodsai eq II!nn joloeiluo0 ay} swelsAs 6u �(ue 6Ul 01 Loud '>liom q4l alaldwoo of pailnbei se Jo s6UlMeip ay} Uo lenowaJ JOI p9leU61s9p we leyl s5luel q4l jeau 6uldld }o suoi:pod pue s)luel 6uilsix9 94l anowaJ of paalnbaa aq Bien aoloeiluoO a41 '3 •paalnbaa ssqul46i1- a9lenn aol aainloelnuew Aci pgpuawwooaa se lnoa6 6uiNuugs - uou 4linn papy pue sleualew snoauealxe 10 paiealo aq llegs bullseo pue sangals IIeM 'aaaui6u3 ay} Aq paleolpu se io 's6ulnnejd ay} uo unnogs se pue 'suolleoyloadS ' asa4l jo uoiloes algeoiidde aapun payloads se `seaae luaOefpe a4l 4olew of pagoled eq ileys seoelans pa6ewep'p9solo aq ilegs s6uluedolooi pue Ilene einlonalsiadnS •seaae lueoefpe a41 431ew of pa4Oled aq pegs sassaoaa a4l pue eaae pagsluy 6uipunouns a4l molaq 4oui quo Alalewixoadde of panowaa aq Ilegs slioddns j94lo pue slloq jogouy •paalnbai ao payloads asinnja4lo ssalun 6uldld pue seinlonuls luawdinbe 94l 4linn panowaa aq llegs saogoue pue 'slelseped `s:poddns IIV a uoile� ado snonuiluoo ui lueld a4l ulejulew of pau6isap eougnbas a ui saoueuglindde pue 6uldld `luawdinbe `sainlonals a4l jo IenowaJ 94l 4linn pgaooid (legs aoloeiluoO 9 41 'O aoloe.iluoO a4l to asuadxe a4l le paoeldaa ao peiledaa aq Ilegs sa6ewea 'pauielai aq of aae 4o14nn aanloruls pue '6u `luawdmba 6ullsixa bui6ewep plone of suoilneoaad Aresseoeu lie ailel lleys pue ieuuew a�llluewNaom a ul sauossaooe pue luawdinba Ile gnowaa IIe4s JOjOealuo0 941 '8 r •paoeldaa sl duel a4l Illun paloauuoosip ueaq se4 `•ole `sioiluoo ' 'luewdinba of aamod ouloale 1e4l pue i4clwe sl 6uldld a4l 1e4l A}uan Ile4s pue panowaJ aq of swali a41 01 /(l!wixoad a4l ui ao paleloosse �(enn �(ue ui luewdinba lie pue 6uldld Ile jog4o llegs joloeiluoO 94l '�laonn bulouawwOO of JOI d b IV'd3N3J I,OT 99LO06JM E - 050Z0 - Apapio pue leau uealo }jal eq pet's sesivaaad eqj pue panowei eq pet's ]Jos liana 10 siagap pue alsem `juewdinbe `slepejew 99 6 006J M 6 6920 •eaae 6u!6els paleu6!sep ayj 01 pajoijIsaa aq Ileys slep9jew Ile jo a6eaojS •91!s ayl punoie ssaooe ielnolyan Jo ue!aIsapad loulsaa io aa6uepue Iou lip leyiaauuew a ui paaois eq lleys ad!d :1N3WdinID3 (INV SIVI2131dW 30 30V�]O1S 90'l, •slagep aayjo jo pues `Isnp jo 6uipp ao 6u!nnolq algeuo!loefgoluaAaad o} sdalsAiesseoeu ayl e� el IleysaoIoealuo0 ayl :30NVN31NIVVY 311S 50' 6 •suoi eoi loads esa inn of uoo saaan oe a i .� .�. yl yl. I• .13 suoi ona sui .� � � � nuew y� ua m y aaa u.6u3 ayI Aj!}ou pegs ioloealuo0 441 •s}uawnooa joealuo0 asayl of pue suo!lonalsu! s,jaanjoejnuew 9qI y }!nn aouepa000e ui pallelsui eq lleys juawd!nbe pue sleuajew IIV :dlHSNdWAiOM t0' 6 pegioads se jo apoo `piepuels e 01 waojuoo }eyj �JoM ayj ui pajeaodaooui aq of slepajew pue juawd!nbe lie jo saaanjoelnuew ay} 10 }s!l a a99u!6u3 ayj of I!wgns lleys aoloealuo0 ayj `NiOM 10 }Pels GqI 01 Mid '8 quewdlnbe ao le!aa}ew yons ao} spiepuels algeo!Idde pue sluewnooa joealuo0 ayj yl!nn Aldwoo Heys pue aainjoelnuew a jo jonpoid piepuels 941 aq Ileysjuawd!nbe pue slepejew `sbu!nneip ay} uo unnoysao pa!j!oads as!nnaayio ssalun y :1N3lNdinD3 (INV SIVIU31b'W CO* 6 •suo!lelnbei pue salni Ju9wuaano6 leool Ilb' 'I •(S0) spiepuejS le!oaawwo0 9oaawwo0 jo juawliedaQ sems paim •H •suo!}eo!l!oedS leaapa3 •0 '(10(i3) suo!leog!oads uo!lepodsueal }o Iuew:pedaa ep!ao13 •3 '(O1HSVV) slelo! -O uolle:podsueal pue AemLIBIH 9WIS 10 uo!Ieloossy ueo!aawy •3 '(` mmv) uoljeloossy gi0m JejeM ueopawy •Q '(ISNV) ajnj!jsul spaepueIS leuo!IeN ueo!aawy •0 '(Nisv) sie!ialevy pue 6u!lsa1 aol �}a!oos ueo!aawy .8 , •sapoo ledlo!unw pue �4unoo `leool •y •spaepuels pue sapoo 6ulnnollol ayj yj!nn aouepa000e }olais u! eq Ileys Joealuo0 s!yl aapun )poM ayl :SNOIlb'0I3103dS (INV S(IUV(INb1S `S34O0 318b011ddV ZO' 6 •s6ulnneip r ayl uo unnoys se pue u!aaay q:pol 19s s}uaweiinbei ayj yl!nn aouepa000e ui aogel pue juawdlnbe `sa!iddns `sle!aajew Ile 6u!ys!ujnj jo s1s!suoo uo!joas slyj .iapun NaoM :NOIldluos3a 60' 6 - l"3N30 - 6 IWd SJN11113 (INV 3dld 069ZO NO1103S 99 L O06J M Z 1, 9Z0 r - uo!l!puoo 1eu161ao J 01 w941 aaolsaa `pa6ewep a ie A941 aseo u! `Ileys pue sa!j!l!jn 6u!}s!xa 9s941 01 s96ewep aol apsuodsai eq Ileys joloealuoO ayl - papeau se sa!j!I! }n 6upixa ay} 6u!loaloid pue 6upool u! aouels!sse Aaessaoau 941 aol abuea.ae pue uo!joruisuoo of jo!ad �4!1!jn 941 joeluoo lleys ao}oealuo0 ayl *paajuejen6 jou si syjdap pue suo!jeool 941 Jo Aoeinooe ay} Inq `sueld ay} uo unnoys aae sa!j!pn 6u!ls!x3 - uo!jesuedwoo Inoyj!m aojoeajuo0 941 Aq pajolsaa eq Ileys A941 `96ewep jo aseo u! `pue Ainfui woaj pajoajoid r Allnj pue pg:poddns AIlnJaaeo aq Ileys `saanjonajs jayjo pue sad!d `salod `j!npuoo `sjuawaned se yons sjuawanoadw! 6u!}s!xe IIy :sa!l!mn pue sa!i!I!oe3 6ugs!x3 10 uo!1091wd 'y 090ZO u01139S 41!nn aouepj000e u! uo!j!lowap Ile wao}jad 11eys ao1oe4UO0 ayl - NO I JOIN 3 C] 60'E NOun03X3 - E ltlyd 'Ja)laed ao Auedwo0 6ui:4!3 pioJnneaO Aq peinjoelnuew se � ola6emS aq ileys s6u!}}!1 agnj Ile `s6u!nneip 941 uo paiou as!nniayio ssalun :s6u!}}!3 egnl 'Z M •suo!jeogioeds le!jajew yl!nn waojuoo Ileys pue ad!d 6ugoauuoo ui pasn le!aa}ew awes }o aq Ileys >lools eldd!N 'a99u!6u3 941 jo uo!ss!waad le!oads y }!nn jdaoxa pasn aq jou Ileys s4l6u9l esol0 - pai!nbai aslnuayjo ssalun s416ual jjoyS :saldd!N ad!d pepeaayl - I, :s6u!}}!3 pue adld snoeuellaos!IN 'e r 'lenoidde sd99u16u3 9 41 of joafgns pue uoljeo!Idde 941 aoJ aigel!ns aq lleys sbuydnoo uo!suedxa jo lepa}ew ayl - uo ! suedxe lewaayl joj ajesuadwoo of aainjoelnuew Aq paj!nbaj se sbu!Idnoo uo!suedxa Iiejsu1 pue ap!noid Ileys jo}oealuo0 ayl 's6u!nneJp 941 uo p91eo!pu! se jdaoxa pasn aq Ileys iajawe!p you! -Z ueyl a96aei ad!d Ond Ju!of paplann Juanlos ON - ialem algelod aol leas 3SN ayl Jeaq Ileys PUB `99L 6 VUSV ui paq!josa.ad se pe liew eq Ileys edld IIV - qcl (4 jalloos aq Ileys sa6ue13 'paleo!pui as!nniayjo ssalun 08 alnpayoS aq Ileys s6uipq pue ad!d o!lseld Ond IIV ' I. apeaO ` l, ads j `0nd ao} t L W1Sy jo s}uawaambaa 941 qm wjojuoo Ileys le!.aaleW 'L9tZ - Q AiSV ' qm waojuoo Ileys s6u!}}!J 19NOOS '99L 6 W1S`d jo sluawaj!nbaa 941 41!M wjojuoo Ileys ed!d 0nd IIV :s6u!:4!3 pue edld Ond mod pa6ue13 pue paplaM JuanloS - I, :suo!jeo!Iddy ad!d IIewS snoeuellaos!Vy PUB uo!lnq!jls!Q ajpolyoodAH wn!poS jol sbu!}4! pue (0 ^d) ad!d 9p!aoly0 IAu!AAlod 'b' :SJN11113 aMd 3did 60'Z sion(]O2Jd - Z ll:ib'd •f}!J6a1u! wajsAs Ileaano 941 6u!opoes jnoyj!nn `swajsAs 6u!lslxa `01 pue `Jo uo!}oauuoo 941 alepoww000e of tiessaoau saaldepe jo suo!l!suej} `sbu!}}!j Aue Alddns Ileys ioloealuoO ayJ `uo!l!ppe uI 'ao!naas juauewaad ao Ajejodwaj olui peoeld eq o} war<sAs 6u!js!x9 941 nnolle o} swajsAs }u!ea;saa tiessaoau Aue Jo uo!jelleisui pue uo :J s!noid ay1 jol alq!suodsaj eq Ileys aoloealuoO ayl - suo!jeool snoaawnu u! s9nlen/s6ur4q/6u!d!d 6u!�s!xa o� uo! }oauuoo aye sapnlou! �oafoad s!yl Nldid JNIlSIX3 LO' 6 r 98 6006JM £ of elglsuodsaa eq llegs aoloeiluo0 ayl •u0lleuen a 01 `6ulllann ul `saaa6e Alle011loeds a9aul6u3 ayl ssalun awll auo le palsel aq llegs cull to laal OOZ uegl aaow ON •lenoidde s,aaaul6u3 ayl jol 6ullsel of aolad nnollol of sasodoid eq uieped 6ulls9l ayl a9aul6u3 ayl of llwgns (legs aolOeJluo0 ayl •aaaul6u3 ayl Aq geal aol uolleulwexe llwjad of pasodxe Allualogns eq llegs s6upg pue adld •lunowe Aue to sleal elglsln ou aq llegs uopelpo e6geal algeldaooe ay} `swalsAs 6uldld apea6 anoge jo aalawelp gout -£ ueyl ssal adld ao3 •aaaul6u3 ayl to aouesaid ayl ul palonpuoo aq llegs sisal ainssaid pue abemeal :lsal a6e�ea-i •0 •uolslnaadns alelpawwl s,aaunno welsAs aqj i9pun eq llegs pue walsAs ayl to aaunno ayl ullM aoloeiluo0 ayl Aq palaldwoo uaaq aney slu9w96ueaae aalle Aluo spew aq llegs suoll0auuo0 •s6ulnneip ayl uo unnogs se saulledld 6ullslxe 01 suoll0auu00 aNew llegs a0loeiluo0 ayl :seulledld 6ullslx3 01 suO409uuo0 •8 •sueld ayl uo unnogs sluawaalnbaj ayl of 6ulpa000e pau6lsep aq llegs s:poddnS •pe:poddns Allnl aq llegs swelsAs 6uldld IIy •6ulnneip dogs ayl 4llM palllwgns aq llegs slemalul :poddns paalnba�l •Ienoidde s,aaaul6u3 ay} of }oafgns `paalnbaa aisgm u6lsap mill to slaoddns leuollippe ppe pue i9inl0elnuew edld ayl qpm s:poddns paleolpul ayl to Aoenbepe ayl walluoo of peuollneo Alleogioeds sl aoloeiluo0 ayl s:poddns paleOlpul ayl ueyl ssal lou lnq aaanloelnuew ayl Aq papuawwooei slenjalul le pe:poddns eq llegs teals sselulels pue &1=1 `Ond LIOUaaI pue 9pea6 anoge IIy •paleolpul aslnnaaylo aae s:poddns wnulwnle Jo laals ssalulels dbd paleOlagel ssalun sNoolq laoddns 919aou00 qj! papinoid eq Ileys s6u1:4q pue sanien Ile `buldld g0u9al pue 9pea6 -9noge jo3 •isd o 096 l Aluo alenbape aae s6ulnneip ayl uo unnogs sllelep Noolq A4lnea6 pue lsnayl ayl leyl peuollneo sli0loeilu00 ayl •walsAs 6uldld ayl ulealsaa of paalnbaa se sMoolq A4lnea6Jo lsnjyl asn llegs i0loealu00 ayl `s6ulnneip ayl uo unnogs aaaynnao `epseel lou sl walsAs lulejlsaa leoluegoew e uoluldo s,a99ul6u3 G Il ul 'aaayM •Ienoidde s,a99ul6u3 ayl of loefgns pue suollelnoleo V 01 6ulpa000e aq llegs pauleilsaa aq of slulof to .iagwnu eqi •a.inssaid lsal pegpeds ayl le fi4pB9lul walsAs ayl ulelulew of Aiessooeu se eulladld ayl uo s6ul:4l1 woal Noeq ael se paalnbai se ao/pue paleolpul se pasn aq Ilegs slule ilsai mod •sin000 uogoaalp ul 96uegO Ie011aan ao leluozlaOq a Jayne aaagm lulod ayl le s6ui:411 pue 6uldld apea6 nnoleq Ile uo papinoid aq lleys sluleilsei lulof `wnwlulw a ly •pa6ueq se paleu6lsep sl 11 ssalun s6nlebeVy yllnn pauleilsai aq Ileys Ond 0060 II`d 'leolueyoew aq lleys swelsAs luleilsaa Ile 'unnoys Alleollpoads eslnniaylo ssalun pue `leaaua6 ul •swelsAs 6uldld luewuleluoo algnop uo adid luawuleluo0 ayl aol ldeoxe ` 09 6 ueyl ssal eq ainssaad s!yl IIIM aseo ou ul •a inssaid lsel r pal loads ayl puelsgpm 01 paulealsaa aq lleys swelsAs 6uldld IIy :swalsAS lulealsaN 6 uidid 'b' •aaaulbu3 ayl Aq pano idde sl uollellelsul youail lane sselun `gouaal /Gp a ul peoeld aq lleys 6uldld IIy •luewdlnbe 6ulaalennap algellns apinoid lleys aoloeiluo0 ayl `youaal ayl to wolloq ayl anoge sl uollenala aalennpunoa6 ayl aaayM •aulladld ayllo uolleaado ayl aapuly pinonn leyl leualew u619aol aaylo Aue pue slew flews 'poonn `lalp `aalenn algelod -uou to , � ijua ayl lsule6e edld ayl l0alo.�d of uollon.ilsuoo bulanp uollneoeid liana asn lleys aoloe iluo0 ayl ' 6Z£Z4 AiSy `L£ 'oN IenuelN 30SV - ad!d aPPOILIO IAu!AAlod 'L •uaan06 lleys suollonilsul s,aainloelnuew ayl 'spaepuelS W1S`d ao VMM`d ayl pue suollonilsul s,aainloelnuew ayl uaannlaq slslxa lollluoo a li •spiepuelS W1Sy jo yMM`d elgeolldde ayl qpm pue suollonilsul s,aainjoelnuew ayl yllnn aouepa000e jolils ul palielsul pue palpueq aq Ileys edld ayl `uolleollloads slyl to suolloas.iaylo ul ao s6ulnne.ip ayl uo palou aslnnaaylo ssalun :JNldld sn03Nb'7I130SIVV 4NV 31IN071HOOd.IH Wf11aOS d0 NOUVI iSNI ZO'£ r 99L006JM t L 9Z0 1 r r r r •a ayt Aq panoadde awea} owll a uigl!m suoljejado sly wojj 6uglnsai s Ile pue slelaajew pa#eneoxa ssaoxa `slelaa}ew ssaoxa Ile anowaa lleys Jobe iJuo0 ayl u011ipu03 jeau a ul ilaoM eqj jo alls eqj ule}ulew llegs ao}oealuOO 9 41 :dnNy310 90'£ •:poddns ayj jo A}la69}ul eqj 6up paedoef anogl!m uoljoeajuoo/uolsuedxa lewjagl of anp l~uawanow adld lelxe molle of pellelsul aq (legs s:poddns adld IIy . aaempjeq SS 9 L£ pue slaNseb euaadoeu bulsn s:poddns o} padwelo eq Ileys 6uldld IIy - 6ullslxe gotew (legs :poddns IIy - seouelslp papuawwooaa aaan}oelnuew adld eqj uegj aa}eaa6 ou aae uoigm slenaajul le pe:poddns AlInj eq Ilegs 6uldld apeJb anoge IIy :S121Oddf1S t0'£ •a99ul6u3 ay} Aq panoadde aweal aw a uigl!m ue6eq �laoM aaojaq jsgj of lenbe uol#lpuoo a 01 ioloea}uoo ayj jo asuadxa ay} le paaledaj ao peoeldaa aq llegs sainjonils eoejjns pue A:padoid yons `spien6ales algeuoseai pue lensn Aoldwa of amllel g6noaylao `aaeul6u3 ayj jo uolloaalp ogpeds eqj ao seoueulpio ledlolunw `smel a}els `sluewnoop joeatuoo eqj 10 sluewe imbai ayj Ino)Ujeo of aanllel gbnoayl ao Alajeaagllap jaylaym joloeiluoo ayj Aq pagjn}slp ao panowaa `pa6ewep uaaq aney `swell Aed se paleu6lsep jou sainjona }s eoejjns pue Apedoid .iayjo ao seoual `itaaggnjgs `saaal `sNjemepls `JuawaAed ajauM :Alb3dMid dMd S3unio uis `S3ov=iuns a3JdWya 30 NOIlb21O1S3b £0'£ •aaumo 941 oI tioloelslles aoinos ja}em elgelod a wojj eq Ilegs aalem ayl - aoloealuoo eqj Aq paysluanj aq llegs 66lysnlj pue 6ul }sal aol paimbaa aajeM :6ulysnid pue 6ullsal aol aajeM - 3 •jajem jo awnion 10 aolnos algeps a jo A4!I!gel!eneun of anp saulladld awos uo paalnbai eq stew bulysng aol 6u leglr paslnpe sl a oIoeJIuo0 ayl 'J9UMO ay1 o1 tio}oejsljes aojnos aajem algejod a woij aq llegs aajem' ayl - aoloeatuoo eqj Aq pegslujnl aq Ilegs bulysnlj pue 6ullsel ao} paalnbai aa}eM - puooes aad }} 5 jo adld eqj ul /}loolan a ainsul Il!m 1eyj 6ulysnIj aol pesn aq llegs mog wnw y - algissod se pegsng �(lg6noaoyl se aq lleys aulledld pajaldwoo jo uoljoas yoea `jsat a6ejeal eqj 6uimollo :saulladld pa}aldwoo jo 6ulysn13 .Q •joloequoo ayt Aq uaNe} aq llegs suollneoeid A49jes algellnS seb:Jain /Gp a 4l1M 6ul6and Aq aajem Ile jo paiealo Alalaldwoo aq llegs 6uldld peal leolwayo IIe `saoueaeelo leol6ololaaloeq pue 6ulysnIj `6uljsaj a6eNea1 Ile jo uoljaldwoo uodn Iuewajinbaa slut A}sl }es of saoueug:pndde jo 6u1nlen Ajejodwaj Aue apinoid r r M006JM L L 990 leuollounl AlIn} welsAs ay} 9� ew pue slueuodwoo welsAs snolaeA ayl loauuoo of tiessaoau sialdepe pue suolun 'sbulllll snoeuelleoslw 6 ulllelsul pue 6ulpinoid aol alglsuodsai aq lleys joloeiluo0 ayl :SJN11113 snO3Md1130SIW LO' L 'leolwayo ayl anlaoaJ of Apeaa pue ajaldwoo sl welsAs ayl leyl uolleogllou to ldlaoaa uodn r sNuel Mau ayl of eluolyoodAy wnlpos AIddns ll!mjaumo ayl 'aluolyoodAy l.o uollonpoalul ay} of jolad jalem yl!m palsel AlInl aq lleys walsAs uolleuuONO Mau ayl :JNUl2la /JNIlS31/S1VOIW3HO 90' L aleulaolyo of )(}lilge ayl P u o} P aimbaa se a lll sui p ue Pi I a filly e a ddns e s . luewdmbe pue 6ulnlen'6uldld fueaodwal 'leuo spew sl wals�(s mau ayl lllun leuol}ounlAlinj ulewaa lsnw wals�fs paa} aluolyoodAq wnlpos 6ullslxe ayl leyl peslnpe Alleog!oeds sl aoloeiluo0 ayl aoueldaooe aol J99ul6u3 ayl pue aaumo ayl Aq pannalnaa eq IIIM alnpayos slyl •uollonalsuoo jo luawaouawwoo of jolad loefoid slyl aol l.iom jo aouenbas pasodoid ayl sauglno leyl alnpayos uollonalsuoo pallelap a lenoidde jol.11wgns of paalnbaa aq 11!Maoloeiluo0 ayl queld luewlee it aalem ayl Aq uollonpoid leolwayo ul uo ue asneo lou of pue alglssod se uoos se aolnaas olul paoeld aq ueo 11 Illun fuel ayl lsal pue loauuoo of 6uiNiom aol alglsuodsaa sl aoloeiluo0 ayl `paoeld uaaq sey Nuel Mau ayl aouO •sanoy fit paeoxe lou lleys paoeld sl Nuel Mau ayl Illun peuleip 6u Nuel ay} woaj asdele of pamolle awll ayl allsuo sI Nuel 96eaols Mau ayl Illun panowaa aq of lou sl juel ayl •lenowaJ JOI paiedaad pue paloauuooslp 'paump aq lsnw panowaa aq of Nuel aq l 'algeldaooe aq lou lleys papinoid leolwayo ayl ul uolldn.ualul uy queld luewleaal aalem ayl of elpolyoodAy wnlpos jo peal peldn.ualulun ue epinoid of aapio ul Ieuollounj pue paloauuoo aq sAemle lsnw sNuel ayl jo eu0 •Allelluenbas paoeldaa pue panowaa aq lleys sNuel ellaolyoodAq wnlpos 6ullslxa oml ayl :JNI1f1a3HOS 90 •leuollounj walsAs aillue ayl 9� ew pue sluauodwoo walsAs snolaen ayl 1 09UUOO of Aiesseoeu s6ullll1 snoauellaoslw 6ulllelsul pue 6ulpinoid aoj elglsuodsa.i aq lleysaoloeJluo0 ayl :SJNIlll3 snO3Nd1130SIW t O* L 0 AollelseH 'lauolN `OZ Aoll`d `3and `Ond 'uoldal `OndO `dHJ - elljolyoodAH wnlpoS •saloua6e tioleln6ai elgeolldde Aq suolleolidde aalem elgelod aol panoidde aq pue sleuejew 6uimollol ayl woal peleolagej eq lleys ellaolyoodAq wnlpos ql!m loeluoo legualod ao loeluoo ul swell Auy 'sbulmeip ayl uo ao /pue uolleollloads ayl ul gjjoj las aie sluauodwoo welsAs snouen aol. sielaalew uollonalsuoo oljloadS NOIlOf1b1SN00 30 Sl`d12:O1bW £0' L - pun ao Algwasse ayl jo aainloelnuew ayl Aq paalnbei se deed luauodwoo Ile Ilelsul pue yslwni lleys joloeiluo0 ayl 'llun ao AIgwasse ue llelsul pue ysluanj of aoloeiluo0 ayl aimbei suolleollloads pue sueld ayl aaayM :SllNn X10 S3118W3SSV ZO'L •welsAs 96eaols ellaolyoodAy , wnlpos ayl of i(llleuollounl IInj aaolsei of Nuel ssel6.aagll ayl aoeldaa of paalnbai suolloeuuoo pue sleuglew lie 6ulllelsul pue 6ulysluanj sapnloul uolloas slyl aapun paaanoo JJOM ayl :3dOOS LO' L 1"3N39 - L IUVd SANVI 3E)V'dOlS SSVIM:1381d OL990 N0003S 99�006JM Z ' ol. seleu!wel ssel6aaq!l leuoll!ppe jo aq Ileys aa� al leinjonals ayl •suo!lelnoleo ssauNolyl, aleu leinlonil~s ayl ui pepnloui aq jou lleys ssau� olyj slyl •pa!ldde aie sjeAel leinlonals eqj aao�.aq pa n Alejeldwoo aq lleys aaull a.nlue ayl •sseuNo!yl wnw!u!w you! -96 6 lelol lleys saaAel lew O ayl snld aal.ueq uo aauu! ayl •anoge paquosap se aq lleys ulsaa ayl •jualuoo ssel6lueoaad 0£ ol: 9Z a yl!M Nolyj you!-990.0 wnw!u!w `lew ssel6 -1 ' pueals paddoyo aouno Z ao Z/ I,- 610 saaAel O N ueyj ssel jou Aq pannollol eq Ileys jalaaeq uolsoaaoo aauu! ayl •l<no palloa Alajejedas Wei yoea yl!m u!saa ayj o }ui palloa aq lleys ssel6 jo I!an ayl. `saaAel Ile ul - A4!a6alui leinjonils al4owoad ol< paia66el.s aq lleys s}ulof paddelaanO •sayou! -Z jo wnw!u!w a paddela9n0 eq lleys spof Ild •aauieq uolsoaaoo 10 uolleolagej aol elgel!ns eq lleys slew pueils paddoyo ui siapulq sulsaa •pasn bu!aq ulsaa ayl, yl!nn slinsai }seq ayj 6uln16 AIJUG,s!suoo se `6u!lunn u! `Jaanloejnuew ulsai eqj Aq pepuawwooe i se aq pays pasn saxenno!u!}}eied pue san!I!ppe loaluoo -aino `sIsAleleo `sl4uewaoaojulai ssel6jaq!l II`d •sleualew panoidde da3 6u!sn pajnjoejnuew `uisaU •(WIGIOdg) eu!l!uelAylaw!Q /ap!xOJed IAOzuag aq lleys wa}sAs aino ayl •aal.ajeq uolsoaaoo eqj jol pasn sulsai ayj u1 san!}!ppe ou eq lleys aaayl •leolwago puelys`d Aq ZZ6 uajaH Jo leo!wayo nnoa Aq gt,-I, 6i, eueNeiad `J91s9 lAu!n a aq lleys ulsai ayl sau}snpul uolbulling Aq painjoelnuew se snxaN aq Ileys Ilan 6uloe}jns aalseAlod o!1!ydoapAq -uou `o!I<ayju�(s ayl •�lolyl4 I!w 0£ of OZ aq Ileys aauaeq you -ulsaj ayl •ssel6lEueoiad 0 6 olr u!se i juaoaad 06 jo o!lei a u!el4ulew of palldde u!saa yl.!M Ilan 6u!oe}jns ollayl jo sjeAel ONAq pannollol apps ssaooid ay} uo ssel6 -0 10 aaAel 610 6ullslsuoo aaujeq yo -u!saj a eq lleys ja!ajeq uolsajoo aauu! ayl •aa�(el IeinjonilGs jol III lanai pue .iauieq uo!saaoo aoI II laAal £99Z IN1S`d aq Ileys f}!lenb aleu!wel ayl •aoa!d auo ui pel.eu!wel aq lleys :p!Ns pue sn!pei alNonuN bulpnloui peat' aa!}ua ayl • 6 3WS`d 41P aouepa000e u! la!NS IeJ159jul ue yl!nn peplow aq lleys Alaleiedas pal<eu!wel speaH - Ala' }eiedes peleu!wel aq lleys ao hays ay1 y }!nn AIlei6alut paleulwel eq Ileys speaH •66Z£ W1S`d yl!m aouepa000e u! aq Ileys speay woi4oq pue dol, ay} to sn alp onuN ayl •66Z£ W1SV Aq paj!nbaa se ssauNo!yl� wnwlu!w e aney Ileys swo:4oq le13 •laapuew aylr waj hays 94110 Ienowaa ol~ aoud do l:l!nq aq lleys (aoe}ins aoua>Gxa pue jaAel leinjonils 'jeAel jo!aalul `aoejjns aauu!) days leoupullA( 94110 ssauV'Ll G aall;ua ayl saleulwel ll edA_L aq lleys pays leoupu!lAo ayl }o uolloaa!p dooy ayl: u! laal g 6 ueyi ssal �o slenaa1 u! le hays leoupullAo ayl, ui spuoq tiepuooes ou aq lleys aiayl •Ilays iapullAo ayj u! (uolloaa!p lelxe u!) sl4u!of leo!lJan ou eq Ileys ajayl •Iauuosaad aoueua}u!ew jo jy6lann bui:poddns jo elgedeo aq lleys Nuel 10 doj ayl pajlnbaa aje saa!nn:poddns ao sdooy `sq!a '6u!oejq Ieuaajxa ou leyl Os pau6lsap ' aq Heys sNuel ayl •sjol!q!yul nn elgel!ns u!eluoo Heys duel aauul pue u!Ns aal4no ayl •ep!ao13 ylGnoS ut uo!lellelsu ap!slno }ueuewaad jol elgel!ns pue pal<elnsui eq lleys sjuel •u!aaay pa!�!oads se pue s6uimeap eqj uo unnoys se eq Ileys sauosseooe pue sl!elap `suolsuew!p Ilb' '66Z£ W1S`d yl!m aouepa000e ui dol; payslp pue wo:poq leg aq Ileys sjuel, ayl •algel.deooe aq jou ll!nn uo!lonil;suoo dooy paddoyo •ssaooad bu!pu!nn juawep jo do -Ael puey ayl: 6u!sn palonil~suoo aq Ileys si uej 94 •sluewaj!nbaa 6 3WS`d y3!nn aouepa000e ul peen oelnuew seen l:! 6ulwj!luoo dwel.s a jeaq lleys glue} y0e3 'pap!noad aq lleys uollelnsui ayjaano u!Js an!Ioajoid db3 ilo!yl you! -9 6/£ y •wo}loq ayj>4daoxe saoe}jns Ile uo uollelnsu auayjalnAIod „Z /6 wnwlu!w yl!nn p9a9n00 aq lleys sjuel 94-L •(Ilennap!s ' Iy6!eals) y6!y '9l, `aajawe1p :4 06 :smolloj se suolsuaw!p leulwou y }!nn suolleb 09L`g jo fi}!oedeo leulwou a aney yoea Keys slue} ayl •3 o0Z 6 o} do sainjejadwelr le a}uolyoodAq wnlpos %9 6 - %q 10 96ejols aol algel!ns eq lleys sNuel ayl -sNuel a6ejols el!jolyoodAq wnlpos d2j:j `pawop `leo!laan (Z) ON Ilel:su1 pue ap!noid lleys JOl3ealuO0 ayl :((13UniD3U Z) S>INbl IbOIW3H0 >ilflg 60•Z sion(IOad - Z lbdd •suo!l.nl!lsgns ON •sselbjaq! j puowe!Q jo saulsnpul Nueltseld Aq painloelnuew aq Ileys sNuel. ayl :S2J3bf11od=inNb'W 3lgbld300V 90' 6 M 0069 M E - 0 6 990 • 9noge ylaol las yoeoadde ay} a.a of 1y6p 9yl samosai lnq aanpaooad 91sua911e ay} a9plsuoo II1M - 1991 - 1 1 61 - 1 3 91 41 •p9.u91aad sl 9leuialle 9141 Aqm sw.i91 elgelllluenb ul uleldxa Ileys le111wgns pue aanpaooad pesodoid 19 141 •uo1leaapisuoo aol a99u16u3 19141 of aanpaooad eleuialle 1941 llwgns (legs aainloelnuew 19 1411u9n9 slyl ul •yoeoadde eleuial1e ue spu9wwooaa i9inloelnuew 19141 ssalun Aldde Ileys aanpaooad pagposep anoge 9141 •suollelnoleo pal }loads Alsnolnaad 9141 yl!m 6uole i9au16u3 914} Aq M91A9a aol 9lgellene spew 9q Ileys suollelnoleo 1941 •salliedoid Iewa9yl paleulwel snld awnlon 9leu1wel uodn paseq poiaeuibu9 aq Ileys `awll 6ulploy pue 6uldwei 6ulpnloul `polaad 9anolsod ay1 •paino 6u19q saleulwel ayl of jooys lewa941 plone of ainlejadwel polaad ploy 19141 woal uMop pue of do p9dwei eq I1e4s einlea9dwal aanolsod ay1 •3 •9no e q 14pol 19s yoeoadde ay} annbei of 1y61j 19141 sanaasai 1nq aanpaooad 91eu.ielle 19141 aaplsuoo II!Ma 91 41 pgaaelead sl el:eu.ialle ay1 Aqm sw.ial 9lge1111uenb ul uleldxa Ileys le111wgns pue aanpaooad p9sodoad ay1 •uolleaaplsuoo aol a99u16u3 9141 of 9anpaooad aleuaal1e 19 141 1lwgns (legs a9anloelnuew ay} luan9 51141 ul •yoeoadde eleuaalle ue spuawwooai a9anloelnuew 19141 ssalun Aldde lleys aanpaooad paglaosap anoge 9141 •anoge payloads slaeyo aanleaadwal 6ulanolsod 91 41 yliM 61 - 10 1e a 991 - 1 1 61 - 1 3 ay} Aq M91n9a aol elgellene spew aq Ileys suo1lelnoleo awnlon aleulwel •awnlon eleulwel uodn paseq paa9eul6u9 aq 11egs polaad PI 1 to uolleanp 1941 •ano4 6 to wnwlulw a aq lleys polaad ploy aanolsod 1941 •d •ss91 sl a9n9y3114M 3 saaa6ap 09Z ao ulsaa a141 10 aanleaadwal uollaolsld 1e 91 41 p990x9lou Ileys aanleaadwel aanolsod •aaleaa6 sl aana14oigm sseooad ay1 to 9anleaadwel 6ulleaado 941 ao 3 s9aa6ap 08 � to wnwlulw a le luewdlnbe 9141 aanolsod 11e4s aaanloelnuew 941 •0 •siluel 9141 to luewd1gs of aoud a991-1161-13 ay1 Aq M91naa aol algellene spew aq Ileys sa inleaadwal iie bui ino 1 pego ao paooaa snonulluoo y •IenueW W'8 O 9 141 ul papnloul aq Ileys uollepaooei Ilelo sllnsa�j •sseooad 6ulano aallue a1416ulanp slenaalul 9lnulw 0 L le papaooai Allenuew aq Ileys 9anleaadwal pue 9w11 9yl ` s901nap 6ulpaoo9a o11ewo1ne yons aney lou aaanloelnuew ayl pinoyS •p966o1 aie saanleaadwel ay1 leyl yons saolnap 6ulpaooaa aanlea /ewll 141!M peddlnbe aq Ileys saanlonals /su9no 6ulanolsod •9 •aaanloelnuew ulsai ay1 Aq p9pu9wwoo9a se aq Ilegs bulano lsod aolaalx3 •a9anloelnuew uls9a ayl Aq pepuawwoo9a se lu9wuoalnu9 weals ao `ale loo a ul polonpuoo aq IIe4s 6ulanolsod aola9lui V •sluewaalnb9a wnwlulw se p9pinoad aae Molaq paulllno sainpaooad 9141 •aaanloelnuew ayl to �4lllglsuodsaj a41 aq pet's ss9ooad aanolsod ayl to ssaoons 9 41 •Molaq paglaosap se salll11 sa9anloelnuew le paanolsod eq 11e4s salaoss9ooe dHJ pue sNuel Ilb' •anoge pagposep se aalaaeq uolsoaaoo awes 9yl yllM p9a9noo aq 11egs s6ugj pue dol ao silent � ue119141 u99M19q slulof pasodxa Aue `uolllppe ul •xeM aleulleaed uleluoo pue anoge paitioads se aalaaeq uolsoaaoo aauul 9141 ul pasn leoo 14sluq u yllM p9a9noo aq ileys `salzzou `s96ue11 `a9noo `s spua ao sa6pa pasodxa 11V '191!14M 19q Ileys leoodol 9141 •ssel6 lueoaad 0 � of ulsaa lueoaad 0610 o11ea a el le of palldde aq Ileys pue anoge paglaosap se 9q 11e4s ulsei 9141 `eino ulsaa 1!q!yui lou Ileys pasn aagaosge 9141 `aagaosge 19101nea11n ue 6ululeluoo leoodol paleulleaed a eq Ilegs yslull ui� s aplslno 91 41 •ti89Za W1Sb a9d 1461aM Aq lueoa9d 98 }seal le 101u91uoo ssel6 a6ea9ne ue aney (legs sNuel 9141 `sluawaalnbaa anoge 9 141 0 1 Uoillppe ul •wa9141oxa aleulwel 9nlssaox9 plone 01 ua�e1 eq Ileys aaeo JO b'Wd /Od9 a9141!a aq Aew aaAel leinlon.ils ay1 ul wa1sAs aano ayl •aplxolued Auowllue lueoaad 9•L ao 9plxolal Auowllue lueoaad g to uolllppe 9141 yliM 6ullea peaads awell I sselo e 9neq lleys ulsa�l •leolwayo puelysV Aq Z66bd 1 - 10 4 9 H ao `1e ploggoieU Aq bd00E6 ban uoia `leolw94o Moa Aq 140 �q aueNea9a se yons a9lsalAuln p9leulwoaq a aq }legs u ay1 •lueoaad 0V 01 98 10 lualuoo ssel6 a 9A814 Ile4s pue `sse16 -3 ad�(1 6ulsn ssauNoigl paalsap 941 ana14oe r I 996006 -IM V 6 990 pue le}}lwgns aa}}e anisaype ue asn Aluo lleys ao}oea}uoo ayl - glue} ssel6jagl} ay} o} siaploy elgeo wnuiwnle jo azuojq puoq }snw pasn aq o} sanisaype ayl - sJaploy algeo anisaype 068/609 sa OOR:13 aq Ileys sjaua }se} ayl 'papinoid eq lleys siaua }se} nnaN 'lenowai glue} 6uunp pa6ewep }ou }i pasnaa aq Aew sleuiwaa} p pue 6uilgeo 6ui}sixa ayl - palle}sui -ai pue panowaa aq }snw }ey} wa}sAs uoi }oa}oid 6ulu}y61l a sey glue} 6ui}sixa y oe3 W31SJlS JNI4Nf10aJ ZO'Z - a}eldaweu pa}elnsdeoua &3=1 alge }ins a apinoad j , s.iaua }se} SS 96£ 'sje� seb auaidoeu pue aanoo y }inn Aennuew p96uel} apis youi -t Z pue saanoo y }inn Aennuew pa6uelj do} youi -t7Z apinoad '3 - sueld ay} uo unnoys suoi }eool ay} }e glue} ay} o }u1 paplann eq lleys 6uidid leuaa}xe :poddns o} s:poddns &13 .a •pa6uel} aq Ileys selzzou II`d 'dlb 3WSd jad pa}assn6 aq Ileys jallews pue a9}awe1P youi -t salzzou III/ - sueld ay} o} 6ulpj000e pa}eool /pazis pue pa6uel} aq Ileys suoi}oeuuoo 6uidid jo} salzzoN .0 ue oea ao a inoid a e s s6n 6ui i �I } y } P P. g II y I .�.I SS 91,£ ino} }o wnwiuiw y .8 •eija}1ao u6isep peoipuinn leool }aaw o} wa}sAs unnop -a1} glue} ay} }o Aoenbape ay} Appeo lleys epiaold }o a }e }S ay} ui pasuaoil Al}uaaano pue Alaadad a99ui6u3 leuoissa}aad y - uoi}eile}su1 sly} }o slie}ap ay} }un000e o}ui 9� e} Alaadoid lleys pue oimeb aq }ou lleys wa}sAs 6u ayl - epelpo Ajo}eln6aa peolpuinn leool ay} A}si }es II!nn }ey} uolyse} a ui s lue} ay} aanoas o} a}enbape eq lleys wa}sAs unnop ai} ayl •aaennpjey paainbaa Ile pue saoyoue builgeo's6nl 6uipnioui uaa}sAs unnop -a!} SS 96£ d d - saiaossaooe 6uinnollo} ay} y }inn papinoid aq lleys glue} Wei }uewdigs o} aoud pa}daooe pue pa}oadsul Alaadoid seen }uewdinbe Ile }ey} uoi }e}uawnoop ysivan} pue }uampedap aoueansse A4!lenb a uie}ulew lleys jain}oe}nuew glue} ay} `Alleuoi}ippy - a }is ay} o} }uawdiys o} aoiad aoue}daooe Jo} J99ui ay} o} pa}}iwgns eq lleys eoin.ias pesodoid ay} ao} glue} ay} }o i(}ilige }ins ay} o} se uoiuido Ileaano pue }uawaainbaj anoge ay} y }inn aoueildwoo uo uoiuido pue 6ui }sa} ay} }o slsAleue saain}oe }nuew u1sai ay} y }inn aay }a6o} 6uilsel siy} }o s}lnsa� - uoi}epuawwooe i sdain}oe}nuew uisai ay} }o }ueoied A}auiu }seal }e lenbe }snw 's6uipeaa xis 6uiulewai ay} }o uaNe} a6ea9ne uy 'pa }euiwila }sannol onn} pue }say6iy onn} ay} y }inn uaje} aie aoejjns yop u1saj a }o s6uipeaa ual - aassaadwi loo ie8 e y}1nn pa}sa} aq Ilegs slue} ay} 'spiepue }s buian}oe}nuew anoge ay} y }inn aoueildwoo wai}uoo of - aino }sod o} aoiad pew.ao}jad aq lleys ilaonnaa ao saledaa dogs II`d 'f - pajno }sod aq osle Ileys spuiiq pue sJanoo se yons s;DuOssaooe d2J3 asool Ile `aanannoy alno }sod 6uunp slue} ay} wa} p9now91 eq lleys spuilq pue sJanoo &ld II`d '1 - pal}ioads saouejalo} leuolsuawip ay} o} pa}lwil aae sa6ueyo leuoisuewia •ssaooad ay} wo j }Inse i Aew }ey} `6uiNuiays pue 6uidienn se yons `sa6ueyo leuolsuawip eziwluiw o} pe:poddns Alaadoid aq }snw }uawdinbe ayl 'H - sa}euiwel ay} }o siaAel aolaa}xa pue joiaa }u1 snld eoe aauui ay} ao} pal }loads se slanal }oa}ap lensin wnwiuiw ay} }aaw lleys aino }sod ay} woa} s}Insaa }ey} 6uiNoejo Auy !D - uoi}oadsui leUi} o} aoud eoeld axle} lleys arno }sod d 881,0063M 9 L 990 •uol}aldwoo lellue1sgns aol uoljeolidde o} aoud leoiwago peal eqj 4llnn pa}sal eq ilegs welsAs a41 •sleoiwego jo ldlaoaa jol Apeaa sl uaalsAs eqj 1egj aoljou ua}}lann aouenpe sAep t L jseal le apinoid llegs joloe.iluoO a41 peldeooe aq Minn ebe� eel elgls ON - Alluenbesgns in000 llegs leoiwego 4llM 6uilsa} Ajoleuaal}uoO •aajem 4jIM palsal aoueuaao}jad pue palsal ueaq se4 w9jsAs eqj aalle sleoiwego paaj a4l Alddns lip aaumo 9 41 :JNI -Mi C OT •uoil!eagln ajeumle of Luawdlnba lie Isnfpe pue u6ile Alaadoad :iN3WNJITd'S NOIlb218In Z0•E •Lnoa6 hulas -uou jo 4oul- L uo gels a uo eq of paleolpul juawdlnbe lie ile}sul •ienoidde saaauftEl eqj oLloefgns `suollepuawwooei s,aain}oelnuew a4l 4lInn eouepa000e lolais ul palleisul eq ilegs luawdlnbe aa4lo pue sdwnd IIV :1"EIN3J LO•E N0I1f103X3 — £ 1b]Vd •uaajsAs eqj jo Apleuoljounj aol saoueuelindde a94jo lie pue `sleupial ale `algeo 6ulpnloul `6uljslxa 4o}ew ol nnau qpm peoeldaa aq 01 We anoge pagpeds jou slueuoduaoo IIy •a99ul6u3 9qj WOJJ Ienoidde 88 L O06J M L 'uogoalas a01 a99ul6u3 ayj of pepwgns aq ileys sioloo elgepene 10 saldweS - aldwes yslug yoea jo Jew yoea aol uol}eolldde pue leU9jew ayj 10 6ulIsll a apinoad 'ao}oealuoa ay} jo A}lliglsuodsaa anlsnloxe 9y1 sl sjuawa mbei iayjo lie ql!m eouelldwoo - Aluo ajn}xaj pue aoloo }o nnalnaa s,a99ul6u3 aol seldwes }lwgnS :bulluled `saldweS '8 •asn ao} pasodoid ieuajew yoea aoj suoljonalsul uoljeolldde pue slsAleue lagel juled 6u1pnloul uol}ewiojul leoluyoaj s,aaanjoelnuew jo saldoo 17 llwgnS :6ulluled :ejeo s,aaanjoejnueW 'b 'OOELO uol}oa pm eoue a000e ui a e s s e iw n S y p q II y I �l. q S •Slb'lIIW9f1S go - L - uol}onalsuoo bulanp pabewep uaaq aney }eyj `puhl ul `siagel aoelda�{ - siagel adid Ile ilelsulai pue anowa�j :slagel adld 'a •sajeid aanjeiouewou ao `aweu `buljea aouewaotaad `uoljeoljl}uapl juewdlnbe Aue ao `IenjnW tioloe3 pue sepoleaogel ,sialpm9pun se yons `slagei paalnbaa -apoo Aue aano juled IOU oa - pajeolpul asihuaylo ssaiun `6ulluled yslult aimbei }ou IIIM s )jeys uej pueao }ow `saolnap 6ulsuas `sa6eNuls `sa6ei{ull `sioleiedo aadwep pue amen se yons `s:ped Ieoploale pue Ieolueyoaw `sjlun 6ul}eaado jo s}ied 6ulnolN :slegel pue shed bulleiedO '8 - suoljeoyloads esayj jo suoljoas i9gjo ul papnloul aae ao `l.iom ysluy palidde -plait ayj toped se papnloul IOU aae Niom jo salaobaleo 6uimoilol aq 'y :a3af11aNl ION JNIINIVd t70' L •Ienoadde s,a99ulbu3 9y1 01 109[gns `.iaanjoeinuew aayloue `paweu sl euou jl io `aaanloejnuew paweu aay}oue azlign Keys joloealuoo ayJ `Iou s! J! di •Ienoadde 6uimerp dogs jo awl} ayj le joa}ta ui Illjs eq Isnw Ienoadde slyl •asn slyj aol salouebe Ajo}eln6aa ayj of algeldaooe Allug uno aae aajem aigejod ql!m }oeluoo aol ulajay payloads s6ul}eoo ayI •panoadde aae s6upoo ay} 1eyj 6uilels jain}oe}nuew ay} woaj uoljeoyl]Jao a99ul6u3 ayj of }lwgns Keys joloea}uoo ayI - asn aajem aige}od aol uo110910ad ieJu9wuoalnu3 jo }uew:pedaa eppo13 jo alels ayj Aq panoadde aq lsnw suolleolidde aalem elgelod.iot pesn s6u!IeOO :NOII`dal31litl3O S,b32iniov=inNVVY EO' L - .a99u16u3 ayj Aq pajoaias eq Keys sioloa • Ienoadde JOJ a99ul6u3 9y1 01 pa}}lwgns aq Ileys suoljonalsul uogeolldde pue uo aoejans `salnpayos 6upoo s,.iainjoeinuew ayI - aaaul 6 u3 ayj �fq panoadde (s)aaan�oejnuew ayj jo slonpoid aq iieys sjuled pue sbulleoo II`d :1"EIN30 ZO' L - Naom slyj o} }uensind pa6ewep saljllloet 6ullslxe ao `joealuoo slylaapun palielsul pue pallddns swat! lie 6ulleoo pue uoljeaedaad eoejans sapnloul �aom ayI Bulppq past Ieolwayo lueoefpe ul luawuleluoo ayj uaann}aq pue ulseq juawule}uoo 941 aplsul 6uldld Ieolwayo 9pea6 anoge Ile ol sbulleoo Ile Aldde of juawdlnba pue `slooj `aogel `sielaajew Ile j0 6ulysluanl ayj sapnloul suogeogpeds ayj to uoljoes slyl ul pecIposap N iom ayI :3dOOS 1.0 1, 1` EIN30 - L IbHd SO N LI-V00 00960 NOII036 99 LO06AM Z - 00860 r oawaul - I, - pajeolpul aaaynn `algeldaooe aae saain}oelnuew 6ulleoo 6uinnolloj ayl .d :S2JM:jniovj 1Nt/W 318`dld33ad 607 ' sioncimm - Z ii jvd - abuea ayj Aq payloads sl aoueaalol ayl - abuea payloads ayj 4l1M aq lleys sIs91 Ile `u9n16 sl ssauNolyj jo a6uej a ajegM -wnwlulw ayj 10 %091, eq llegs wnwlxew ay} `aaanjoe}nuew ayj Aq pa}eolpul jou sl wnwlxew a aaayM - pepaaoxe aq jou osle Heys ssaujolyj wnw spinjoeinuew GLIJ `JanannoH - junowe wnwlulw ay} paeoxe lleys sisal Ile payloads We sasseurigj wnwlulw 9 aa4M - ssauplyl wly Aap paalnbei ayj pol slas uolleoyloads s141 :S30NVd3lO1 90'l - suollonalsul pajuud spinjoelnuew }uled ayj Aq pepwaad asimiayjo ssalun 'seoejins lam ao dwep 01 JO ' %96 spaaoxa /f}lplwny anljelaa 9y1 uaynn ao'jsiw ao 1 6oj `ulej ul juled Aldde jou oa .a - suollonilsul paluljd sp injoeinuew }uled ayj Aq pepwiad r 9simi9gjo ssalun = 1 s99169p 96 pue =1 saaa6ap 9t, uaann}aq aie saan}eaadwel iie bulpunw ins ayj pue pajuled aq of seoe}ans jo ain}eaadwal ayj uaynn Aluo sjuled pauu141- Juanlos AIddy -9 - suol;onalsul pajupci spinjoelnuew juled ayj Aq pe:4!waad aslNUay }o ssalun = 1 saaa6ap 06 pue =1 s 09 uaann}aq we sa.injeaadwal ile 6ulpunaans ayj pue pajuled aq of seoe}jns jo aanjejadwal ayj uaynn Aluo sjuled eseq- aajenn AIddy - y :SNOIlIaNOO 801' LO' l, jaayS A}ajeS spinjoelnueW •jagwnu pue aweu aoloa - suollon.ilsul uolleollddy 'suollonalsul 6uluulyl - sjuanjljsuoo alolyan pue juaw6ld jofew aoj `awnlon Aq s}ualuoa •aweu s,aaanloejnuelN - aainjoelnuew jo alep pue aagwnu Tools spinjoelnuelN - algeolldde jl `jagwnu - oadS - pad •Ielialew 10 9114 ao aweN :uollewaojul 6ulnnollol ay} pue `lagel pue aweu s,Jaanloelnuew 6upeaq saauleluoo pue se6eNoed pauadoun pue nnau `leul6lao ul ells gof ay} o} slepa}ew Ile Janllaa '8 - ease 96eaols ul 6uplows ou'coeds palell}uan `tip Mann a ul aauuew Alaapio uealo a ul slonpoid juled aio3S -y :3JMAOlS aNV Al 13n113a 90' 6 r r 88 6 0064 M £ - payloads aaagm walsAs uolleaedaad leasoaoyl a 10 anlsnloxa 'aaanjoelnuew auo woaj aq lleys sjeoo a}elpawaajul pue '}eooaano 'aawlad ayl g 'sllwll papuawwooaa u!4l!M Aluo asn pue 'aaanloelnuew juled ayj Aq panoadde saauulyl Aluo asn 'sleoo 4sluy ayj se aaanjoelnuew awes ayj Aq paonpoad juled Jeooaapun apinoad •l, •suoljnjgsgns pasodoid Aue a01 a99ul6u3 ay} of eouewaopad jo ajeogpeo s,.iainjoeinuew PUB elep leuajew ysluand 'a99ul6u3 ayj of elgeldaooe uagm Aluo asn aol paaaplsuoo aq Aew 'sluawaalnbaa anljejljuenb u aa_.lp 19A 'suol leaapad algeolldde }o sluawaimbe i anljejllenb bulleoo ay} 4l1M �tldwoo 4o14M sl,onpoad s,aaan}oejnueW •£ •swnwlulw asayj paeoxe ao jaaw papinoad sleuajew jeyj aaanjoelnuew juled ayj woa} uol}eoyllaao ual.}laM a apinoad •slelaajew }uled aol �genb elge}deooe wnwlulw ayj gsllgelsa suoll<eogpedS leaapad z •saaanjoepuew aayjo jo slonpoad l.ualenlnba jo uolsnloxa ayl o} paalnbaa aae saaanjoelnuew peweu ayj }o slonpoid ley} Aldwl 01 papualul IOU aae sleuajew ao saoloo a}eu6lsap o} pasn seweu Aaejaudoad - - algeldaooe aq IOU ll!m }onpoad 9pea6 -js9q 'paepuejs a se uoljeoyl}uepl s,aa.injoeinuew ay} 6uiAeldslp IOU sleualeW •saaanjoepuew sleuajew juled algeldaooe Aq paanloejnuew Alieln6a i s6ulleoo to sad } snolaen ayl jo epea6 fi4llenb lsaq ayl apinoad •y :Ainvno lVN31bW £0•Z - swap snouen uo paalnbaa aq Aew saoloo leaanas jeyj paslnpe aaylanj sl aoloealuo0 ayl •aoloo bull:slxa .ino yojew of ijessaoau sl 3l saleolpul aaaul6u3 ayl aaayM saoloo piepuels -uou jo asn ayl< aalnbaa Aew s141 - pasn eq lleys aaaul6u3 ayj Aq paleolpul se aoloo spaepuel.s Aalsnpul 'aoloo a ajeu6lsap IOU seop `dMMV aaayM •suolleol;rlsselo VMMV aad papoo aoloo eq lleys sadld IIV :6ulpo0 aolo0 Q •saaylo Aq pawlad sajeajsgns 4l1M swel:sAs 6ulleoo payloads bulsn swalgoad paledlollue Aue jo 6ulpuM ul a99ul6u3 N1 41 •paalnbaa se awed -aa pue saawud alglledwooul anowa�j •pasn aae sleoo ewlad apledwoo aansua ol'asn aol pasodoad sleuajew 4sluyjo sollsualoeaeyo uo uollewaojul ysluanj'sapealaayjo woallsenbaa uodn - salealsgns snouen aoI W91SAS sbulleoo lelol jo fiq q jedwoo aansua 01 papinoad aq of aae sluled awed 4o14M ul suol eoyloods esayl jo suolJoas a9410 Malna�{ •pasn sluled awed payloads 4j1M algljedwoo aae uol4M sleoo ysluy payloads apinoad :uol}eulpaoo0 l.ulsd •0 - Ilene ayj jo do} ayl, of aoloo puooes e pue Ianal aooy anoge jaaj xis Alajewlxoadde of aoloo auo :slleM bulppq aolaajui lle uo pasn eq II!M wal.sAs aoloo -OMI a ley} paslnpe sl aoIoeaIuo0 ayl •pajeolpul aslMaayjo ssalun ssol6 -pas aq lleys (sso16 'ssol6 -lwas `ley) walsAs 6ulleoo eqj jo usluy ayl •paleolpul aolnaas pue salealsgns ayj ps of sadfi4 algeolidde '6ulpej -uou 'sand :4sluld pue slu9w61d aoloO . B •Malnaa a01 seldwes bulaedaad U94M saoloo anlle}uasaadaa asn •paluled aq of seoejans aoj sdlyo aoloo ysluan j IIIM aoloealuoO aqj '�aoM buluul6aq 01 aoud •`d :S3HSINId aNb SbO1O0 ZO•Z 99LO06JM V panlonu1 sapeaj 941 u1 pall!Ns uawjjonn Aq swal! panowa.a ayj llsIsuiaa `eaae jo coeds yoea 1 jo bullu!ed jo uollaldwoo 6uimollod •seoe}jns lueoefpe pus swat! ayj jo 6u!luled ajaldwoo ayl ao} `tiessaoau J! anowab 'suo!teaado bu!lu!ed pus uo!l<eiedaid eoe}jns of aoud uo!loa}o id pa!ldde- aoe}ins ap!noid jo `paju!ed- yslu!l eq of jou pus eoeld ui swat! ael!w!s pue `sarn}x!i 6u!Iy6ll `saleld `seoe} ins eu!yoew `seposseooe ajempjey ajempjeq Ile anowaa AlInjaas0 '8 'sbu!leoo o!lsewnl!q yl!m swat! Ile of pa!Idde eq Keys sdols ae1 '(an!}eivasuoO) anlJOla}saa aaow ayj si uo!u!do s,a99u!6u3 ayj ul yo! wa}sAs ayj asn r `AMP watsAs uoljeaedaid aoejjns s,jajnloelnuew pepuawwooei pus pagpads ay} uayM u011!puoo aleilsgns aelno!ped yoea jol `pamoads uiaiay se pus suoltonatsu! s,jajnloelnuew }uled ayl yl!m aouepj000e jou }s u! sainpgooid 6uluealo pus uoi eaedaid wjo}jad :Iejaua0 'y :NOiib�AVd3bd 3ov=iuns ZO'£ - wig ju elgeanp a jo uo!lewaolul ayj of leluawijlap as!mJaylo suoll!puoo ao `seoe}jns pa}lnos `aanls!ow eseai6 `aleos `Isna `}a!p nano ju!ed jou oa '0 •eaae jelnoped �(ue u!yl<!m suoll!puoo pus seoe}jns ay} jo eoueldaooe s,.ioleollddy ayj se penaisuoo eq Ipm N iom bu!luled jo 6u!petS '9 •aoleo!iddy ay} of elgeldeooe aauuew a ul paloaaaoo uaaq aney suoil!puoo �jojoejsljesun 1!lun Ajom ayj yl!m paaooid jou oa 'Njom ayj jo uo!laldwoo Alow!t pus jadoid ayj of Ieluew!jlep suo!l!puoo 10 BUIP nn u! a010eatuo0 ayt AMOu pus palldde eq of s! Aaom 6u!}uled yoigm aapun suo!l!puoo pus seaae ayj au!wexe Isnw aoleollddy •y :NO1103dSNl 60'£ Noun03X3 - £ i2:Wcl ' jeoo aad sl!w 5'Z of lsnbe ssauNo!yl wig Aip wnw!u!w a yl!m II Pla!yS eJnPu3 VL06 S91 JGS Oawaul e :jeo0 ys1u1 j '£ jeoo jad sl!w 0'ti of lenbe sseuNolyl wl!j tip wnw!u!w a yl!m ou!loxod3 pl!n8 -!H gg sa!aaS oawaul e :jeo0 a}e!paw.iatul -Z - jeoo jad sl!w 0'£ of Ienba ssauNo!yt wig Aip wnw!u!w a yl<!m `Oulz MO L6 - 06 oawaul ' 'seoejjns wnulwnle jo OndO `Ond `db=I `seoe}jns laals sselu!els `p9z!uenle6 6UIISIX9 ao nnau 01 palldde aq jou lleys leoo jawed ay1 - palldde uaaq sey Jaw!id ay# aa:4e paNlneo eq lleys ole `spuel6 aauletaa `sa6uell IN :aawlad • 6 •JeOO ys!u!} ayj AIuo 9AI909J pus paueelo amssaad aq Ileys ad!d 6u!ls!x3 s6ul�eoo �o uo!�eo!ldde ol< aoud - dS OdSS jad 6u!uealO juanlos pus pa!�laeos eq Ileys seoejjns OndO PUe `Ond `dw `1991s sselulets nnau Iiy - ('ola `suolleo!agej Iejaw `sleNoeaq `I!npuoo `s:poddns `semen `sbuillg `adld paunq -uou `'a'!) swell pa6jawgns -uON 'Os!W 'b' :SW31SAS JNIly00 t0'Z 88 1, 006J M 9 ul bulleoo uo uolssnoslp ajow jol suolloas jay }o pue sbulnnejp ayj of jajaj lleys joloejluoO ayl •6ulleoo 6ulnnbaj sluauodwoo Aa� fipuapl of sldwal4e Isll slyl - Molaq pagljosep sluauodwoo ayj Ile jeoo lleys joloejluoO ayl :JNI -LVOO JNianO3b S1N3NOdVVOO 90'E •uolssnoslp jay}anj jol 80' 1, `00860 uolIoaS aaS •jajnjoelnuew 6ul}eoo �(q papuawwooaj se `paleolpul IOU jl `jo pa}eolpul se ssourigl will tip lejol a ysllgelse of `ajej 6ulpeajds papuawwooaj s,jajnjoepuew ay} ueyl ssal IOU le leuejew yoea AIddy :ssaurlyl 6ulleoO wnw!u!VV 'O •jeoojapun ayj jo uolsaype jo ssol jo bui3j!I asneo IOU saop }uled jo jeoo jayjoue jo uolleoildde ayj pue `ajnssajd gwnyl alejapow japun Af oljs 1a91 jo wjojap IOU saop will sla,91 jl ajaynn of paljp sey aided lqun jeooaj IOU o4 jadojd }lwjed 01 s6ulJeoo anlsseoons uaann}aq awll jualogins molly •8 •uol}ejoljalap eoepns luenbesgns ejolaq pue uollejedajd ja:4e elgeogoejd se uoos se 6ulluled jol pajedajd asimjaylo jo paleajlajd `pauealo uaaq aney leyl seoejjns of Ieljalew leoo -lsjlj ayj Middy •y •pawjo}jad uaaq sey luaweoeldej iluej a6ejojs leolwayo ayj jade jn000 lleys salj!Aljoe 6uljeo3-9j IIy :JNIlNIyd JNiin(13HOS 90'E - Aejdsjano Isule6e joalojd Allnd of pue j99ul6u3 9y1 10 u0113elslles 9qI 01 Aejdsjano wojj pajoalojd aq Ileys saoejjns }uaoefpy •palldde Aejds aq lleys aided IIy •sooejans leg 10 jegj 01 Jualenlnba ssauNolyl wig fijp a anlaoaj sjauaisel pasodxa pue `splann `saolnajo `sjeujoo `sa6pa 6ulpnloul `saoe}ans Ile Jeyl ajnsul of uollua:4e leloeds an1O •eouejeadde pue joloo `ysiull wjojlun to sl wll} lined ayl lllun `lined }o jeoo leug ayl gbnojyl mot's suolllpuoo jaylo jo sulels `sleooaapun uegm sleoo leuolllppe AIddy •palldde 6ulaq leljalew jo 964 pue alejlsgns ayl jol palms lsaq sanbluyoal pue sjoleolldde ash suopajlp s,jajnloelnuew ayl yl1M aouepj000e ul lined �(lddy :N011b'OI1ddy t O'E •6uisn ajol.aq Ieljalew ayl ideals `AJessaoau Jl pue will ayl anowa�l •leljalew ayl olul will aoejjns ills lou oQ •slepalew ayl jo uolleolldde ay} 6upnp pajlnbaj se ills pue `fillsuap wjojlun jo ejnlxlw a aonpojd of uolleolldde ajoleq slepalew j1lS 'O •enplsaj pue sleljalew u6lajoj jo aajl. `uolllpuoo ueelo a ul lined jo uolleolidde pue 6ulxlw `96ejols ul pasn sjauleluoo uleluleVV •sjauleluoo pajanoo AIly61l ul asn lenloe ul lou slepalew ajolS '8 •suolloajlp s,jejnloelnuew ql!m aouepj000e ul sleljalew 6ulluled ajedajd pue x!VV •y :N011b�lyd3�:id SIVIbOiVVV COT •paysem ajnssajd aq lleys saoejjns Ond bullslx3 •s6ulleoo 6ulAldde of jopd p9gpeos 6 - dS OdSS of 6ulpj000e pajedajd aq lleys seoelans Ond m9N •luanlos paseq wnelojlad -uou algeldaooe ue ql!m slueulweluoo eoejjns pue Ilo jo aaj} ueelO :saoepnS Ond 'a •saoepns paluled- Alnaau `lane oluo llej lou ll!m ssaoojd 6uluealo ayl wojj slueulweluoo leyl os bulluled pue 6uluealo ayl wej6ajd •6ulue913 leolueyoaw o} joljd aseaj6 pue Ilo anowa�l •sluewleajl ooepns jo lined buiAldde ajolaq paluled aq of seoepns uealO 'O M 006dM 9 •jeoo snolnaad ay} pajdaooe sey a99ul6u3 eqj Iljun palldde 9q iieys sleoo 14slull ao alelpew.ialul ' ON 's901A9p gojejos jo o �(q elgeanseew �tlgeuose9j jou sjeglo ao s6u'leoo snoillluewao jo ssaui{oi14l ay} aanseew of peiiddns eq Ileys luewnilsu' algel'ns j914lo ao gldep l!d ajnseew o} eolnap V sassaumoi14l 6ulIeoo 10 uolleulwielep 9141~ a ol 96e6 IIw fup ollau6ew }sal -oaolW ao ia}awoole ue pue 96e6 ssaumoly} a�ool a 91is eqj le elgellene 9ney Keys aoj0eJjUO0 9 141 :JNI1S31 90'£ •jaanloelnuew ayl Aq papuewwoo9a es'nna914lo sselun polaad buiAip inoy Z� wnwlulw a j9}le palldde 9q Ileys s1e00 anlssaoonS 'algeysin6u'lslp sleoo snoljen 914l anew o} palull eq Ileys IeOO 14oe3 - uees 9q jouueo II os jeoo snolnaad 9qj aanoo A19191dwoo iieys slued jo sjeoo anlssaoonS •d 'seoepns paluled peoelop jo pa6ewep lie ajolsaj pue do -gonoj `sapeaj jaylo jo Miom jo uoljaidwoo ay} IV ' 3 'suo 6uiluied jo uollaldwoo aa}}e `Mionn alayl jo uol}oaloid aol sjaylo �(q pap'noid s6uiddeim 9n110a}ojd Ajejodwal anowa�j 's9yslu.1 pajuled -Almou }oeloid of peimbei se sub's Juled 19M„ 9pinad 'Q •a 991 - 1161 - 1 3 Aq pa}oaaip se do pagonolao palu'edaa pue paueaio aq Ilegs}uied jo seoejans pa6ewep `ijonn 9yj 10 eoueldeooe ieUil aaoja8 'J99u'6u3 a14l Aq pajoeiip se pa}uledaa pue }}o palselgpues ao pedeaos 9q Heys 9AII punoj bul}uled 'yslulj pue ajnlxa>l 'aoloo UI UO1je1jen pue sdel `sanenn `sdlap `splon `s96p'a `sung woaj 99.ij eq Ilegs seoepns pegs'ull 91 41 •uolleolldde of jolad paxiw pue `paiails `pajols Alaadoid eq iieys pue sueo pauedoun uI a}ls 9qj 01 paJ9nl19p aq iieys juied IIy '8 •suolleogloads 9sa14>l jo sluawailnbaa ay} o;l wjoluoo Aa14j je14} os suoljejado 6Uljuied pue uoijeaedaid aoejans sdoleougej eqj aleulpa000 pue A4!lou �(liadoid of /4!1!q!suodsai s,aojoejjuoo a14j aq Ilegs }i •y :10bUNOO Jlligvm LOT '6u!pl!nq lueoefpe eqj pue ulseq eqj uaangeq ulseq juawu'eluoo eqj 9plslno pue u'seq juawu'eluoo eulaolyo eqj episul sbul�I1 pue 9did OAd bu'pnloul aaaynnasl9 payloads jou NJOnn Ond 9pe16 anogy IIy 'S •(poluled eq of 6uid'd uo ldeoxe Iaels ssalu'els 9 �£ bu'pnioxe) sa914senn pue slloq `slnu IIy 'b - ola `s:poddns ed!d '£ •seoueua:pndde pue 6Uln1en 9pea6 9nogy Z 'oja `sa9j9w `sanlen `sbuilIg `edld 9pea6 anogy •jeoo 14slulj 9qj Aiuo 9n1909J pue paueaio einssaid aq IIegs adid bul}six3 •s6ulieo0 jo uo'leo'Idde of aoud � - dS OdSS aad 6ulue913 }uanlos pue P911peos aq Ileys seoe}jns Ondo PUe `Ond `&1=1 laels ssalulels nnau iiy '('oj9 `suo'jeougej Iej9w `sj9joejq `j'npuoo `s:poddns `sanlen `s6ul}jij `ad'd peiinq -uou `'a'') :swell p96aawgnS -uON snoeueliaosilN '`d •p'q aseq a14j u' pepnioul 9q Keys sw9}sAs buileoo lie aol lsoo 91 41 'Isil sly} u' pepnloul jou sl golynn uollsenb ul well Aue 6ulw90uo0 J 991 - 1 I 61 - 1 3 91 4} }oe1 iieys IOIOBJIUOO ayl 'paleoo eq IIe14s swa}! Ile 'leaaua6 88 L 006J M L i r - seoe,pns payslulj 96euaep asuvuay }o jo yojejos o1 jou ejeo 6ulsn `6uldejos pue 6ulysem Aq panouaaj aq lleys juled pejapds - seoejjns pejapds -}uled jay }o pue ssel6 mopuim ueelo lleys joloejluoO ayj `Njom 6ulluled ay} jo uoljaldwoo uodn - Aep vonn yoea jo pue ayj je sbej pue sueo `yslggnj `slepajew juled papjeoslp Ile 91ls ay} WOJJ anouaaj Ileys jojoejluoo ayj `Niom ayj }o ssoibojd ayj 6uljna •dn -uealo Ile job Juanlos 6uluealo pepuawwooaj s,jejnloejnuew ayj asn lleys joloejluoo ayl dn 23T •6ulleoo of joud paNlneo eq Ileys •ol.a `sjanoo amen `slauuoq amen `slloq `sjnu se yons joeluoo Iejew- of -lejaw paleoo -uou aney yoly^^ seoejjns IIV - NIneo y L eN!S yl!M s6ul}eoo jo uoljeolldde of joljd 6uldld uo sebuell Ile NIneo •j99ul6u3 ayj Aq pajoajlp se do payonol jo pajuledej pue peuealo aq Ileys juled jo seoejjns p96ewep `>ljom ayj jo eoueldaooe leUll ajola8 •j99ulbu3 ayj Aq pajoajlp se paju pue }jo palselgpuesjo pedejos aq Ileys anlJoajap punol 6 ulluled •yslulj pue `ajn}xal `joloo ul uolleljen pue `sdel `saneM `sclup `sebplj `sunj wojj aajj eq lleys seoejjns pays!u!j ayl :,Ainvno N�IOM L L'£ - pepuepl Apedojd pue pauedoun aq Ileys sued •joefojd slyl uo pasn joloo pue 6ulleoo yoea }o:penb auo qpm jaumo 941 Alddns lleys joloejluoO ayi :dn 0 L'£ •j9aul6u3 ayj of algejdaooe se `6ulluledej pue `6uloeldaj jo 6uljledaj `6uluealo Aq abewep Aue loejjoO - Niom 6ulyslu!j pue 6upied Aq ebewep lsule6e `}ou jo paluled aq oI jaylaym `sapejl jaylo to NJOm }oa1ojd :NOI- LO31Obd 60'£ 991,006=1M 1, - pajoafej aq Illnn ydeAejed siyJ 10 suolslno.id ayj o} �Gejjuoo pa.iego juawdinb3 •sjajnjoelnuew ajejedas Aq paysiujnl 6uieq jiun Aue jo sjegwnu bolejeo pue seweu ayj ql!m 6uole palsil eje slepajew Ile Igun pgnojdde aq jou Ilion s6uinnejp doyS - (s)asod ind papuajui sp jol juawdinbe ayj jo uoijejedo jadojd pue a }es ayj aol paa aq �(ew se suaali Iejuapioui yons pue aaanjoelnuew juewdinba ayj wojj sueld ayj uo pajou os jo suoijeo!j!oads esayj ui pauaeu suaal! Ile ulelgo Ileys aoIoea}uoO ayl :2J3bfllOb'3nNb1A1 31-11 WO21d (13Nidl9O 39 Ol NOI1dWb031\11 ZO'£ - j99ui6u3 ayl 10 uoiIoeIsiles ayl 01 peg!oads)ponn ayl punoje luiod pue yoled `jiedaj `dn esolo `punoje l!lAIlnjajeo Ileys joloejluoO ayl - jajnjoelnuew ayj jo suoil<onil<sui ayj qj!m eouepj000e ui pallelsui aq Ileys juewdinbe IIb :JNuno1 jJ dNV SNOUV `SNOIlb'4Nf103 60'£ NOunO3X3 - £ l�:!dd - paloafaj Alleoijewolne eq II!M Albuipj000e pedwels jou slepajeW •uoijeoijijan plan Apeaj jol pedwels os eq Ileys SS 196E jo SS 96£ aq of pagioads sjaysenn pue slloq `s }nu IIb' :1331S SS31N1`d1S ZO'Z 'j99ui6u3 ay }Aq panoadde aq lleys sainjonals builsixe o}ui sjoyoue 6uioeld jo pogiew eu - sazis pjepumS sams pailun jo pue Ino ueolo aq lleys speajyj IIb' 'slloq 941 10 lejew ayj se fqilenb awes ayj jo s1nu leuo6exay pue sjaysenn yjiM papinojd eq Ileys pue `uoluido s,j99ui6u3 ayj uo Alelos paseq `pazis eldwe jo eq lleys slloq joyouy - slloq joyoue 6uilsixe to esnaj alelilioej o} paleoijgej aq lleys duel - laa }s ssaluiels g 6£ }o eq Keys sNuel a6ejols ssel6jagij ono} ayj jol s1loq jogouy •laals sseluiels 96£ jo eq lleys sjuawele lejnjonjls jo died jaylo jo sa}eld aseq uwnloo job siloq aoyoue `(jagui6u3 ayj Aq of pgej6e se) suoi}oauuoo }uawow uwnloo jo jeays p.iepuels job pajinbaj si builloq jay }o ajaynn jd9ox3 '(00860 uoiloaS gas) buileoo panoadde ue yliM pajeoo aq lleys ajajouoo pue Ajuosew ojui ll!nq jou eje }eyj Njonn lejew jo sjoyoue 10 sljed - Aelep pione of auaij jedojd ui s6u uo panoadde pue saleldwel `s1loq joyoue yons uielgo of joloej}uoO ay} jo A}iligisuodsaj ayj aq Ileys 11 - joloejl:uoO ayj Aq paysiujnj aq lleys quel ay} 10 uoilellelsui jol pajinbej s6uiMejp uoijeool pue `sajeldwa} Iloq joyoue `sjloq joyoue IIb 60'Z sioncimm - Z lbbd - w9jsAs abejols pue peal alijolyoodAq wnipos ayj jo uoilelleisui elgejado `alaldwoo a joj seoinjas iJessaoau lie 6uiwjojaad pue juawdinbe pue slepejew Ile 6uiysiujnl 10 sisisuoo uoijoes siyl japun pewjojjed aq of �jonn ayl MI1dRiOS3a 60'6 1b213N3J - 6 lbb'd WtON30 - 1N3WdinO31VOINVHO3VY t 001.56 N011O3S ' 881,0063M Z •paalnbaa ao 'pajou aslnnaayjo ssalun 6uldld 1 ayj se awes ayj pue paAanuoo bulaq spiny ayj ql!m algljedwoo eq lleys uoljonaisuoo jo slepaielN quewdlnbe payloads of 6uldld umoys 10 uol }oauuoo ay} GIRIloe} 01 swa�l p91e19a JayJo Jo sanaals `sjajdepe `saojoauuoo `s6u!}4y Ile apinoid lleysaoloeiluo0 aul :SNO1103NNO0 iN3Wdinc)3 tOT •Ja9ulbu3 ayj Aq paulw.ialap se `suolllpuoo `Aoua6jawe jo `lewjou aapun pezlleaa aq pinoo yoigm psay olineipAq ollslleaa wnwlxew ayj o} palsal aq lleys `seilil oej bulule}uoo pinbll elglssod ao `6ululeluoo pinbll Ile `tiejluoo ayj of aaaynnasla pay ssalun •aaumo 941 01 esuadxe leuoi ppe ou le ao}oealuo0 ay} Aq pawaojjad aq lleys paalnbaa juawdlnbe 6uljsaj Jo/pue saolnap Ieloads `.ialem `lonj `aamod `aogel `aouepua}ulaadns `Ile pue `Aue 6ulpnloul }oealuo0 s14j aapun payloads juewdlnbe to `pailnbaa jl `6ullsal9a pue bullsal IIV :JNIlS31 COT